The URL can be used to link to this page

Browse Search

Home My WebLink About640133.tiff/ 4 Cep/ %�.11-22,W 7,0`z. '7\;!„, SPECIFICATIONS FOR THE GENERAL WORK INCLUDING PLUMBING, HEATING AND VENTILATING AND ELECTRICAL WORK FOR OFFICES REMODELING FOR THE WELD COUNTY COURT HOUSE AND WELD COUNTY SERVICES BUILDING AT GREELEY. COLORADO FOR WELD COUNTY, COLORADO CLAUDE A. NASH AIA ARCHITECT DENVER. COLORADO OK] 1 T<Ac, I T€ i DATE: AUGUST 19. 1964 COMM. NO. 1127 SET NO. 1. 1_ 640133 I27 INDEX INDEX TO SPECIFICATIONS C U C C C. I rir C I C SECTION A - PART 1 NOTICE TO BIDDERS PART 2. DOCUMENTS AND REGULATIONS 1-1 PARY 2 PROPOSAL FORM 1-2 PART 146- ALTERNATES 1-2 -2 SECTION B - PART 1 AGREEMENT FORM PART 2 GENERAL CONDITIONS OF THE I-2 CONTRACT (A201 SEPT. 1963) I -I0 PAR' 3 SUPPLEMENTARY GENERAL CONDITIONS 1- PART7 PERFORMANCE/(_ABOR"MATERIAL BOND I-4 PART 5 CONTRACTORIS STATEMENT OF TAX PAYMENTS PART 6 SAMPLE APPROVAL MEMORANDUM I -I 1-1 SECTION C - PART I DEMOLITION PART 2. EXCAVATION I-2 PART 3 CONCRETE I-2 PART ,11 MASONRY PART 5 ROUGH CARPENTRY I- 4 PAGES PART 6 STRUCTURAL STEEL AND MISCELLANEOUS IRON WORK 1-3 PART 7 ROOFING, SHEET METAL AND WATERPROOFING 1-2 PART 8 METAL SPECIALTIES PART 9 FINISH CARPENTRY i-6 PART 10 'A;I; NCr4 NT, PLAIrEERING PART II GLASS AND GLIZING 1-3 1-3 PART 12 PAINTING AND DECORATING PART 13 FINISH HARDWARE I -{F PART ( REsi.A-I-E_N-T- FLOOR -FRG PART 15 ELEVATOR 1-5 SECTION D - PART I GENERAL MECHANICAL REQUIREMENTS PART 2 HEATING AHO VENTILATING PART 3. PLUMBING SEC.! FON E - PART 1 ELECTRICAL I-5 I-3 1-3 I-7 ai J, <, a ret, la A ,7 cen 101, and cap ::7-7,•••• rs3Lf. Park A � K % ri ltf.'3 Y °"' n 3.L:,aj..c fr.Tr Hall 218 .0 I:LY:.t${ :t`Yi u4.sJ :t ki'.:.l° (h) Type L f' ue 3 {'k:z 2he 3i ayp+ 4 fixtures sh©Mfl cm dwg 82. Par C9 7. ' A_1 ,' .c Material. 17 i;il 8A-�.�.g�....+��4. t +c+"^ �a:)QP°._1 t.'r1L.@.�. .. rti 'D ^�I ra,i7.S'tU'� cT.? �q. °i i Pars, 0^ r •:.?.' xl� a "`i Part, tt1."l fzi ca 1, Part C13, r C C C L 0 c C C C C C r L 1227 Cl 1 0," tinENDU14 #1. TO TILE PLANS AND SPECIFICATIONS VOi OFFICES REMODELING FOR 191E WELD COUNTY COURT HOUSE AND WELD COUNTY SERVICES !€J :D nG AT GRE,Ei:': Y, GO!Li-t.?S)r, ADDENDUM ;l1 'Asa iL , n< chaoL73r 5h,all be made !.n the ( .ur::� k;c:.e 1sc: L, t%m�; for the p: ) SHALL BE CHANCEL, 20 ' , �!N"' D Y r r,C 2W0 j:7 MST, �Affl P'.ACEo-f.'.JJ ..y SEPTEMBER 16, bjl�4H 2. The cu Jl tiun data for the Serviauv uuth j'1'P_+',n tc?i indicated in ArticLer;�; 86 otr !, �+ Supplementary General s .�ndiN :shall be changed to ion dosa not letion elevator tower tv elevator.terk. The bGoner desires useLlof thele Jantary 2, 1965. DRAWINGS NGS Dra:ain ( > . Finish Schedule rc 1: vi da;ete iprw tc ! c t„cc, at mart end", n! j35, rem=r°irs column, Dx.aving `1 Ynr txi t.r:l Plot Pi.am in :het od t.4xtonsibn of telephone service sho,.Ju, viee conduit carry to the Sher“Ds ns building and fbushaott lthrough the nce eBailera Rouse, tanard the Services Building, 24-6" below grade and 13L0" north of the south wall of the hytilding. Extend al? ci:id It 20. " e belts' grade zr., � tr�x�vgmdo attc! rnm,de f a: t net: cervice ecn31rr.errt (Tel. Term. No 1) to the east aide of the 3r jc e Builld'Ing 136-0" fraie; the an'n =ail. Remainder of outside service will be installed by the to e hone company' and is not a part of the uerk, Ur a:y.n4 S d.�- ttitare Schedule Type t r 2alE be Serhriagt STl —lal&R }?S°. in lieu c42 that shc'un, Drawing Si & S2.,. Doors D & G frame ! :� 1';.Itt ahall be Jamb b as shown on thee d sr r detiaii. �9 drawing S2. Drawing- S -j-- bird Floor Plan In Y9eu ':' telojttie ct1ndot sizes and runs shown provide 7" cm'ndvitt fri.. Tel, Term. .a nrr.:Pe tzaj..i. of Treasurer 33,3 and cc mect ti- i7 rg-,,!tists on the north H f "'? with 3,41" c :vldliyr,., Provide 1" ce d➢f It: 7 Tel , a0 h `rum the !mtmj, Revi x c ]i!3lt 4 ?..: r:,n to �>^.1.'to f.4u,., n bro Office jj.! a ri:x mgrs :: � � * • (� E:.x°,aide:1TeL Lt r r r r. r r r r r r r 1117 A0 —d SECT"tCN A -• PART NOVECE TO BEDDERS SEALED PROPOSALS A,i!1IIi..SSED TO THC COUNTY COMMISSIONERS, WELD COUNTY, COLORADO, FCR 7HE CONSTRUCTION OF OFFICES REMODELING FOR WELD COUNTY COURT 8-;OUS!'. AHD WELD COUNTY SERVICES BUILDING AT GREELEY, COLORADO, IN ACCORDANCE WITH DRAWINGS AND SPECIFICATIONS AS PREPAREO BY CLAUDE A., NASH, ARCHITECT, WILL. BE RECEIVED .SEPTEMBER IE, (964 IN TOE COUNTY COMMISSIONERS'': OFFICE AT THE ,COUNTY COURT HOUSE BUILDING, GREELEY, COLORADO, UNTIL 2:00 P.M. OICLOCK, MST, AY WHICH TIME THEY WILL_ QC-PU-BLITLY- OP-EN€D- A--NO-R£FD— ALOUD. ANY DID RF;CI:HYD AFTER CLOSING 'TdFI;. ABOVE NOTED WILL BE RETURNED UNOPENED. PROPOSALS WILL BE, RECE ITED ON THIS GENERAL WORK, WNICN WILL ;INCLUDE THE PLUMBING, HEATING AND VENTILATING AND ELECTRICAL WORK. A CASHIERS CMEC , CERTIFIE!, CHECK, OR ACCEPTABLE BIDDERS: BOND PAYABLE TO THE COUNTY OF WELD, COLORADO, IN TUC AMOUNT 0r NOT LESS THAN FIVE PERCEN', (5%) OF THE LARGEST POSSIBLE TOTAL FOR THE PRO- POSAL SUBMITTED, INCLUDING THE CONSIDERATION OF ADDITIVE ALTERNATES, MUST ACCOMPANY L'ACH PROPOSAL AS A GUARANTEE THAT, IF AWARDED THE CONTRACT, ThE BaoorH "W LL PROMPTLY ENTER INTO A CONTRACT AND EXECUTE SUCH BONDS AS REQUIRED., THE COUNTY OF WELD RESERVES THE RSGHT TO REJECT .ANY OR ALL PRO— POSALS AND TO WAITE ANY OR ALL FORMALITIES. PLANS AND SPCIFjcAT ioNS NAY B£ EXAMINED IN THE OFFICES OF TddE ARCHITECT AND MAT BE PROCURED AFTER AUGUST 2E, 1964 FROM CLAUDE A. NASH, ARCH1uCc:r, i&9 SOUTH PEARL, DENVER, COLORADO, UPON A DEPOSIT OF $2500 AS A GUARANTEE FOR THE SAFE RETURN OF THE PLANS AND SPECIFICATIONS WITHIN SEVEN / PROPOSALS„ 17) DAYS ?FT£R RECEIPT OF THE /S/ CLAUDE A. NASH, ARCHITECT FOR: COUNTY C0MMISSBONERS WELD COUNTY, COLORADO SEE a ON A to PART 2 u. D ME S :AND RE} +,.'`_ A .~ I ONS Dm, sfim;GY-DR'aoo5 TH : WOR:. or THE PROCI R: S- t THRCits 4m S- • -- 1ER'.. C_K'.si CS -1 -- Stec 9C ti 7 BU iL ;'Nw l",:+?P i Ht`f0SE C - o - A C-4 COVRT �. E 5-1 !ST i 0OR PLN, PEFIFCTEr CC iL r G FLN*, ,� XT.?RE 4 S-2 2NS FLOOR PLAN DOOR S'CHEDOLC, F`s'!'i zC'3k"', `rE 3L i NC, PL Am 4 .S-3 MLXRt.N 1 KE F .QOR ,1.R5FLOOR PLAN, 7o®fil. r W u o! DE,;_ 5-5 ELv`i� tOR EOJ 't..R 'R.k �C � E,.Z ATOP Towel .r.�.9.db?. a c� ELE`3tc 1oCR E.t{°.AlOkS 5-6 .`OMN ATION DEFAt.S STRCCT4RAL DLlAkS S-7 %k:CR'.Ms;: A; FLOOR FLANS CS— I ROOM r i m e sm S isyw�.at.t C —I 1S ' ri.oR PLAN C —t{ P.-_ R r % 1;,, 2Nn FLOOR Ft. /� h e C 7 P s•:.R i 1 Ai. 3R = FLOOR PLAX, RE F�.: c T .. sD C E !I LN b L,A. ki 7 Room C CTiONS: 2.'o SPEC i!F'$;c{a"i !ONS--aMZC of tCATIO4S L"QYER1NG b'3?₹' .NT RZ WORK OF THE PROJECT ;:.RC .z..S HER:; i L4STO. EACH CONTRACTOR rs stRt'Sl REFERRED To At.+_ ' Ca;Tioms QF Tv , SPTMCiF'ra'..n.YIONS, AS MAC MFL ENC( H S WtR.„ S E O N A -- (J ft)D.? NG O M4 T :Jib PART I — NOTICt TO BiDOCRS PART ;' — DOCUMENTS &N!' RE u3LA. ON:5 PART — PRoPO$AL. FORT PART '! — aLTZRA6,1TES SECT f oN F— .:014 -TACT s N ORMA f ao1 Pk•.R" I — .AOP,F tM:ENT rORm PART �.. .aEdYCR ^.`.. ti.S>4n t' r0N5 Or i'•FE CE?NTRk; . , RT 1 — C4€ +,;, Lv.?UKT.,..R GENERAL .;OMO T'ON BON r =• F w r X "j, 'el,L s . DOCUYE+O —t' AND R6 GU1e.4'S 4 i OvYS Yr � �� r h . n .� !C,. N '� S"''�C 7!C,ATIONS .SOP THE GENE --"4 WORK 4 PART 2 - EACAV T ION PART 3 — CONCRETE PART - s SO:RY PART 6 5 -' RO? +�H CARPENTRY PART - STRifcTURA STEEn. AN.O M Si L`i.LA UOUS IRON WoRK P4R" 7 - ROOFING, SHEc°7 Wvf4L AND W TERPROOF'its/is PART 8 - METAL SPECaA.T. s PART 9 ^ FINISH CARPENTRY gRT 10 -- L h cNG ND PLASTERING PRT w ? GLAS AND GLAZNO . PART I2 - P?i ! HT i NG¢.ND DECORATING PART }{s'i — FINISH HAR =y'"RE PART i-T — RESILIENT FO0R I NG PART I5 EI.CY!4OH SE,:T1ON D — SPEc i F ICA: IONS FOR f:sE mEcwN17,AL WORK PAR 3 — isCMl .asO L WCANAL Ml ! CAL REOu I REm N Y S P+.RT 2 ' E, T d NO AND EN1 5 A NG PART 3 - P3.IrMBAiO SECTON E — SPECIFICATIONS FOR THE ELECTR CAL WORE PART I •- ELEC,TRICS.L 3e EXAM;NATION +:7 I ONf OF CON D; T 1 {'tNS--EIEFORE S%rieMI T T I KG PROPOS9As:: S r0I@ HIS WORK, EAC SIODEii wlLL 9E MELD TO HAVE THOROUGHLY !IXAMiNFD HE DRAWINGS, SP.E IF!Ck1Ta0Ns ,ENO COP TRJ CT DOCUMENTS *MD, TO :4yb,,vt° XAMtNEO THE SITE IND PREMAiSES TO FULLY INFORM 13MSE:.F AS TO ALL XISTING CONDITIONS AND L IMITATIONS UNDER WN!C$ HE WILL BE OBL GED O WORK. 4, kNT ;RPRE` AT.ON OF Do MEN S-- I' AMY PERSON CoNT Mog..*T FNv4 SUSMITTII G A BID FOR TAL PROPOStD CO TRC T Ic N DOUBT ✓ S TO THE t KUNG OR INTENT OF ANY PART O> THE DRAWINGS, SPECiFICA; f?t4S OR O HE°R CONTRACT DOt:UmF,N S, KE k*Y S! Bm 7 70 1Hz ARC I Ttc7 3. tiR ! TE% RQi,4ESE FOR AN N7ER"RFTAT ION THERCOF, PROR TO SEvEINiT —TWO C.72 MOURe 0 Ts P -,:OR or v.a'N! m a OF •`fsl[•.f SifaLS t r r- R ' Q il! ';°." $ r' 'yi..: : ,. r :� rf R � r? H � ` '� Nyy = ? $ .: pF 4"s Ro-:S*O `' 3i.r ' R 'i RO:a;fF�T t_r.L i, 1`4 . ,, � A kr :. Ai — T Z R n t{ ., T _*: i O N v' ` r. J Oz._, .. '' a R r. �..i' "U '1?? k"2 " T ]. w I a 4 N ;Z {s 7 ;'E : f`Z i'27 A2-3 DCL', .4 NT$ AND PE ULA " ONS F CisES7S K LL 'iw o 'tRN ..;•.• n n x FOPM Q: cxVT TO ALL H0�0»RS or COH7ACT DOCUMENTS,. :uz ARCH!4.":C,N tOE? OWNER WILL NOT BE R.'.':Sk"ONS I R{> C FOR AN VERBAL OR OTHER- a>≤`- ERPRETat? tO OF THE DOCVN NTS. OR ''OR Mme:"C Cain _ €' ERR OF ADDENDA OR APPROVALS TO SAID HOLDERS OP COO a RAC T DOCUMENTS. AMT ADDENDA ISSUI DURING THE 7;mr OF SIDO;NG SH' LC BE AC P4O4,t,.EC?GED IR THE PROPOSAL S.MC) SHALL BECOME A. PART OF THE CONTRACT. 5. PROPOSAL —ALL PROPOSALS MUST S?. MADE ON aft FORMS OZREIN PROVIDED a.NV 54 ;Pc I TTa 5 i N A SEALED ENVELOPE. 34D CORMS SHALL )07 BE DETACHED FROM THE BOUND BOOK, BUT S41L'.. BE SLBMI TTEO INTACT (DUPLICATE FQRO$ icRE 1A..1ABLE ''OR TZ OiD ERA'S FIE.) ALL BLANK 5p.✓,cEe iN TI✓ FO€tm d :' BE FUL 1 FILLED, NUMBERS SHALE Sr sATo IN WORDS AND FN FIGURES i TH ALL aPr�^ATURES WRITTEN U LONG HAND. THE PROPOSAL SHALL CONTAIN N NO R. C. P I TtlLAT iON OF WORK TO f?? i ONt, fMTERL EWEA7ION OR #,I>TER, TEOPS. ARV OMISSION OF: ALTERATION TO, OR QUALIEgOkTION OF THE PROPOSAL OTHER THAN TAT PROVIDED ON THE PROPOSAL FORM MAT SE CONSIDERED CAUSE FOR ;): RE4ECT ION OP aenti. PROPOSAL, No Cn;L, ; >?.EPHONIC OR tEi.EKa'E?3.Fs: IC MODIFICATIONS OF PROPOSALS + ILL EE CONSIDERED TOE OWNER R .S.TR E HE RIGHT TO REJECT ANY fr:40 ALL SIDS AND WH•3t ALL FORtik•.s, I ; zS E:i;RtW I TH. 6. PROPOSAL GUARANTEE --EACH PROPOSAL MUST SE ACCOMP4NP £r BY A CERTIFIED CHECK, CASHIERS CIi'Cn OR BO BOWS ACCEPTABLE 1O THE OWNER fN1 THE AMOUNT EQUAL TC AT 4EAST FIVE PERCENT (5%) OF TOE 7ROPOSAL, PAYABLE : THOUT CONDITION TO THE OWNER ER AS A GUARANTEE THAT THE BIDDER. IF AWARDED THE CONTRACT, WILL PROs PTL1 EXECUTE SUCK CONTRACT IN ACCORDARC'. rdt` I' THE PROPOSAL ,fit IN A MANNER 6; NO FORT' REQUIRED Be THE CONTRACT DOCUMENTS. THE BfO SEC4Rh TY OF ALL BIDDERS EXCEPT THE 7m -arc LO -BES=T- W! r4. SZ RE7I1 RN _s_ PROMPTLY- N T_xR. y LO.. OPENING. 7. WI TfaR: WAL OF PROPOS LS --NO BID MAY SE WITHDRAWN AFTER TOE ANNOUNCED CLOSING TIME F'0R RECEIPT OF tI DS FOR A PERIOD OF AT LEAST TWENTY 2o) 'DAYS. '.::-ti k& . OU ANA, t- k p �P dB' l ip—A �Nb. &c '1 e. E 2 A ucnsv I.T.. id6 ��C ^'5 'A "�'�iiiy 4, P�,fjt` ( , farnn' r£�i . Er} p R VO ff li aC tiJ aA p r0:d y' ..�v M,TFR31t4, s f`AsL A iV i tm 15.e ,; 3 4a N 3 r.. 4's rf a'� a s {' 4 Ar_wrR: 3i 73K 2 G 4 u..a .__' d ACCoRt3ANC't:44fliTM AMOUNxy ua`__CLA.as t OR OCb e`d ; WORK FOR n : OLQw ?ia t r ut xfi • $Ufi C. SCr 7 _ e, PF P. TO c Are . r_aJ O. OT ?} .. W n r. :ACTOR FOO A... �ry T o.0 A tS ,k.ETEA TOTAO:. CEOVC >', 41C K.EOO x• 'f1 O#5 ^ O f-.. L: • .AY TO _P.6£ w,. u TEE 'otOOE ,. 'AOOZRE AGNEC EA'," NOM, A ACCI W 1 EAAH T St . 0 !"`a< RN "a SH AND i L 7P7 Aocs4cEr, ENE S huN::43:b: OF EREhig PRO0 U O,� OF TE CONTRACT Tprt,4b CMF!c£ o ORAOOn ACCOM,,PANA C4C. f i.@: HiTEC0 TAT TZ AgOUNT S -. .Oa Aa.. `i0 ONE £^i .auR '£k He OCCk S=A', . EC O f.D "OG 9t TO-. . . R`.C -Oz:. TOE O ,.N p u f PATALE E TO TEE COUNTY or ,'E,'r...di '.!S t 4':,;T kN tSCROI 1 H THE TE EflA SUSTA1M J -£ OF Tr il0 TO EXECUTE 7i MO y7E._ts % TE«6O0t eANED CONZRACT :a.,SO 2cw0, • /_. ir. T01 f `a.4 `r-. v ;e. N AECOT NG THE camY ,a1 TEM a ♦:?c,R� i '1 C'0., Y,jv� !+ 4 o- 1. yG Pi 4'OP s4,.: ~wcRM N''.wN9t-.:! ! . o t{4 )) 7 �1 �,. i �O�i. V `(`�N FT Y 7TY Y SR4 'ti, B COh9P .b , rR :':;aid „ Svcs B ,O•N Wait BE RT,AA FO :d S S°.P.iv -.tA?,CoMPE7ON OuCUP;.fit'c Y s',' T44' OW?!s- ON E AnD rH r epi `4OsnCE•] :5.+- 4. a'. REACT? COR :tj5S.gAIIt Ai. COMPL7hOS OCOUPANC a. Sr74 OWNER ON }0 7' t:. 8. SUSCOK?TRA TORS' . ;ASrw OF - *}t*NeA LL vpoy i`2,.;a cT 0 's ' ARr !��, S AFPF�OyA`< - , e7!RCO4— T R C O S R S i. its tk i �� : N ?, -- 3 i 6 f PRPRARED 7He 1 NtleRGNr $N1 S%r'5Ol?.'rCE t.N Jn A AD EN ..,vWITH 'm Ty51 S � � � ..�I�J. .r�L ."TN DOZR$ At, 0 7: ER �.�. i C :$ ! 9�. $ t [..iRN{ ROP y Y ai .. }�� {{�{ y, �yy ��yy STS p :. r' ii -'.! iY �yf a; � n , O � yi rty. /� 4 "t ► r= r r; .� :`�'D7Oct .. S.M '•0 �..!�B,d Si'>lF: i Ci..a'D. �" '.o G, rO;_cO*_'/RNC7�t +1i'�•5u7+CONIRiaC7OMS.. 5 6. 9. f'f5 yy,r., y '., N R 'A.t,!N71 YG 4.N) DEcORAr iG ro-.EC e'R kO F_. RE TO : em4•T THc .Aeuvc. F:N' gONED LaST MAY SE COr4SS�•EREE>. CASE FOR REJ .C;ON By THE 0WgER OF T IS PROPOSAL, 9. MME O° OF AWARD—_r09+4S3DERA a SON FOR AWARD or TDy CONTRACT 14'LL . BE MADE ON TE BAS'S or COMP�.ET JON TiN AND !..Oar PROPOSAL. ROWEICR. 7 ;E OWNER RESERV �S TN R4SNT 70 RCEC7 N OR :A=: L BkOS ANO 70 W VVE FORMAL!TiES J0„ EXECOT.oN or Pcopos, FO?',4--A.L,, BANK L.t4E3 CONTA 44EO ERN MUST 5E FLIED 9 N w TN APPROPR''i E 3 NF€lRMAT i ON. 41P4t'OPER ? Kc c... .TON OF T,H! S FORM 4:.Y .EIE CG'+fS DER .D CAUSS FOR 4 +" :Cr iOM s THE 0vN R, f.00 im07 40 f ." ... .. - - - . t . ;� ... 2 •. A4- 5ECT₹KN A - FART 4 ALTERI ATF:5 „Yk 04MER EM;` €`IFS FROPOSPL5 ri7; E7.4 ERN TL �, r3 04TL WORM R CF BELOW ALL Sclr':r3 WORK SFA'�L BC SS,a.t6al:ECT 70 APPi tC .SLE PROY$Sw►7NSy DETAILS OR M€;rHO:DS SH3 fE4 FOR *ORrt 4N T3}Y BASE FROPOSAF,1.TIRE OWNER RZSEi `'f F_:5 TH1 4G 'i TO ACE OR REJECT pie OR FoLLow!k% ALTERNATES.w VE R SECT T`. lY t lit. Of i.� ALTERNATE NO 1 —...THIS .:tLTC.RNA?C CON 4,iAIFA•:ES THE RimOVAL wr. F RsSER9 r;≥ T35E. P'RO1I'>>INC OF A NEW 0.PEN!h ; A T VESTIBULE • 320 INELUEs3Nt NEV LINTEL AT THE MEEZAK INE FLOOR Or THk SERVI CS BUILDING. SEE DWG. S-3 FOR EXTENT Or WORK ENCL' DE„ ALTERNATE f`,#! J n c' .p. — h: t ALTERNATE CON ,I, E M! P ;. A. T E S THE S U 8 S T 3 3'!40°?' ' O R Ot AN ELEVATOR FRC3.v I DCD Nu I Na r;ti„L En A MANUF riC Tik3r' R O T iER THAN OTES. ThE SP4 ,O SE STATED FOnih: r�.(.Yt''•`ei: "+ sly Vmc pRCpCS>Fk Fo mm SMALL SE THE DIFFER NCE IM COST, E3TI,ER PLVS OR sN?M:i,;:5 S�"'IEts TN SPECIF«t0 OTaS ELEVATOR AND THE E EV;TOR PROPO I rOR USE UNDER TeIBS A.TwRNATE. THE FOLLOWING tNFORmA? ION MUST LSo SE SUSM! ;E:D '✓<BI ;'iI iM S PROPOSA !N A SEPARATE ENVELOPE: NAME OF MANUFACTURER. �., LOCATION or meAREST SERVICE: F .i_:.Q ITT FOR Tiff ELev-ArrOR. COMPLETE DESCRIPTION OF T ELEVATOR PROPOsE„°',, i+c:ci'L`R.. ANl.'t IN YE FORM USED IN ir?E SASE S'REC,FIC TIONa ;.t :N ENUMERATION OF ALL • &RiaRCES FROM! THE SASE SPEC iF I — CAT 3OEYia 5o .Am $ 0UMERAT !ON CF ALL s; KAf] jES NEC iSArRT i N WORK TO 8C PL 4R ORMED UNDER THIS COU iRp.C T BY CONTRACTOR o7eEft TNN 3FE ELL"u&'.rOR SUPPLE: AND INSTALLER. r`" T C SZNsSE309< CONTRACTOR DESiRtEri "O SUSM;T THE ABOVE ST.?1"'E:;: DIF— rERiE;MllES Am COST ON M0R!r TRAM ONE ke?,P:UFAC"'ar^Ri'ER OTK ,R T: AN OTiS RE MAY DO SO By S'4B4>93rT;mel ON SEi+'r R'.TE ENVELOPES I!dFORM TPON ON IRE ABOVE k i;Z4+iS ALONS "A7H THE O FFERENCE IN COST AS C0#FAR O '?a OT IS FOR EACR OF THE kllx•N z° =:C URER�S Ti? BE CONSIDERED. ALTERNATE ° —`' Ns? AERNA: CONTEMPLATE ' RC ?Cri f 3:O31 PA A N1 u G or r, i. EXTERIOR SURFACES ES ''>'l*7 ARE PRESENTLY or ES�Y �IY .�: I?LLC ON THE SERv iC'S BUILDING AND TliT ARE f0T INCLUDED aN WOR : UNDER •"RE. BASE PROPOSAL. /� SESECT C — PART : 0r TX r �• CTION r� tSF `l S ;,. P' k 1 �' , t T ? �.. A! , S I�? ? ;C° �i .;. !+' E �i F c �,► -.a,� `.a �? !r OL ,0Y NG 'S�t.Yv'L..`.... Lam•.': %`-. y�'_ wOR. " A _ .. i%'i4i'}3'E "�` � ;}- i' � :7 � �`-f: � ,i T F � r N *' ;f 80tL0'PiNb MR 07 4Ol4 St $, !. U.U.. : c,r (A; (61 A4-2 ALTERNATES g A I N , e: a; ti's r' '+. 3 R WERE E N E C r i S A IUT , BEEN tFOSEO A„ O >:'.� INTING O'r 4L. ::itTER?OR WOOD, STEEL, S U CO ANO SAET T METk 4 . w:LkaNZ ¢ND PALk SN OF EXSING CA[,%3N4i OF yy JOINTS AS NE ESE R T 7OR idJ3ATER s 4HT JOB. R mOvA O?e1$Ti AN &c";7ING OF WINDOWS AS N ,LESS !i"• _ .r TER AL AND COATS $N: LL e:; AS FOLLO f S; WooD r: OE.TUCo r R I O R S 1Pi. t it ' y' e(, 7 f.'• L t COAT °SOUS Ps'. 's N7 s PRIMER EX REST Y WHErRE t4 EDED 'aUR BARE WOOD COAT HOUSE PA, I P 1 COT NO.XOi• R€`v LEAD Pf• i41R ( WHCn` Sa,Rf META r E S r vti,s's$ r't Dtk T HOUSE PA; }N"r STEEL ARO H;StiE : FpEO S IRON 4 !OAT 9 OxaORED ! tAn PRB;+r,=:R BARE OEYA:!_ is F:Xow•xP.t) ALL SURFACES SAAL BE CAREFWL•L'T PRE DARED WITH ALL LIME AND ROUGH SURFACES E==lu.IN .TE , SEA BASE SPECIFICATION FOR O'1ERt REQUIREMENTS UNDER THIS ALTERNATE. ALTERNATE NO. 4--1HU1 A!'l•r ATc CO TEM, E ,S THE DMIS`.iON tiN HE FOLLOWING .ROO S OF BRIO CEI!34GS b :dt,llOING DUCT EXTESrFB:CNS. I!i'dTdf DIFFUSERS, :'TG.,. APO SUBST''UIT ON ). T'+?F L FIXTURES F@s A IN SAME QUANTITY AS SHOWN coR TY ' A. 1'v, L FIXTURES S4LL w' CONNECTED WITWI7N WI REMOLO WALL, t3rCT AND CE4L IN?,; AREAS EC;POED BY THE OMISSION Or THE GRID CEILING $H3,•LL ety,' ?AE►gyp';rD AS SHOWN Dun SCHEDULED FOR WALL ARLAS IN THE SANE ROOM. FOLLOWING R0OsdS HALL BE INCLUDED IN THE ABOVE: COURT OUSE: FeRART 100; JUVENILE PROBATION 1l6; D;' ST OCT CQRT PROBATION 1i8; PROBATION STAFF II9 :43UNT AGENT 212; BLve CROS 2f; HALL 209; :a r' ti tti ti O g N S 5: O !4 2i7; H E;, ;. s G V Seven Hundred ._-F. y. »_:. OP rah 15, 1965 'January 15, 1965 One Wired fifteen Theasand n5,738.00 y r:.,. 8t S fi4G CAL COM.�.. r -. .. l Deputy Count r clerk MANION-CROPPER COR1STAT TION CC PANY THE AMERICAN INSTITUTE OF ARCHITECTS AlA DOC. A201 SEPT. 1%S ED. AIA DOCUMENT SEPT. 1968 ED. A201 THE GENERAL CONDITIONS OF THE CONTRACT FOR THE CONSTRUCTION OF BUILDINGS INDEX TO THE ARTICLES 1. Definitions. 2. Execution, Correlation and Intent of Documents. 3. Detail Drawings and Instructions. 4. Copies Furnished. 5. Shop Drawings. 6. Drawings and Specifications on the Work. 7. Ownership of Drawings. 8. Samples. 9. Materials, Appliances, Employees. 10. Royalties and Patents. 11. Surveys, Permits, Laws, Taxes and Regulations. 12. Protection of Work and Property. 13. Access to Work. 14. Contractor's Superintendence and Supervision. 15. Changes in the Work. 16. Claims for Extra Cost. 17. Deductions for Uncorrected Work. 18. Delays and Extension of Time. 19. Correction of Work Before Substantial Completion. 20. Correction of Work After Substantial Completion. 21. Owner's Right to do Work. 22. Owner's Right to Terminate Contract. 23. Contractor's Right to Stop Work or Terminate Contract. 24. Applications for Payments. 25. Certificates for Payments. 26. Payments Withheld. 27. Contractor's Liability Insurance. 28. Owner's Liability Insurance. 29. Fire Insurance with Extended Coverage. 30. Guaranty Bonds. 31. Damages. 32. Liens. 33. Assignment. 34. Mutual Responsibility of Contractors. 35. Separate Contracts. 36. Subcontracts. 37. Relations of Contractor and Subcontractor. 38. Architect's Status; Architect's Supervision. 39. Architect's Decisions. 40. Arbitration. 41. Cash Allowances. 42. Uses of Premises. 43. Cutting, Patching. 44. Cleaning Up. Copyright 1911, 1915, 1918, 1925, 1937, 1951, 1958, 1961, ® 1963, by The American Institute of Architects, 1735 New York Avenue, N.W., Washington 6, D. C. Reproduction of the material herein or substantial quotation of its provisions without permission of The AIA violates the copyright laws of the United States and will be subject to legal prosecution. GENERAL CONDITIONS OF CONTRACT AIA DOC. A201 SEPT. 1969 ED. TEN PAGES ® 1963 The American Institute of Architects 1785 New York Ave NW., Washington, D. C. PAGE 1 ARTICLE 1 ARTICLE 3 DEFINITIONS DETAIL DRAWINGS AND INSTRUCTIONS a) The Contract Documents consist of the Agreement, the General Conditions of the Contract, the Supple- mentary General Conditions, the Drawings and Speci- fications, including all modifications thereof incorpo- rated in the documents before their execution. These form the Contract. b) The Owner, the Contractor and the Architect are those mentioned as such in the Agreement. They are treated throughout the Contract Documents as if each were of the singular number and masculine gender. c) The term Subcontractor, as employed herein, in- cludes only those having a direct contract with the Con- tractor and it includes one who furnishes material worked to a special design according to the Drawings or Specifications of this work, but does not include one who merely furnishes material not so worked. d) Written notice shall be deemed to have been duly served if delivered in person to the individual or to a member of the firm or to an officer of the corporation for whom it is intended, or if delivered at or sent by registered mail to the last business address known to him who gives the notice. e) The term "work" of the Contractor or Subcontractor includes labor or materials or both. f) All time limits stated in the Contract Documents are of the essence of the Contract. g) The law of the place of building shall govern the construction of the Contract. hl The date of substantial completion of a project or specified area of a project is the date when construction is sufficiently completed, in accordance with Contract Documents, as modified by any change orders agreed to by the parties, so that the Owner can occupy the project or specified area of the project for the use it was in- tended. ARTICLE 2 EXECUTION, CORRELATION AND INTENT OF DOCUMENTS The Contract Documents shall be signed in duplicate by the Owner and the Contractor. In case either the Owner or the Contractor or both fail to sign the General Conditions, Supplementary General Conditions, Draw- ings or Specifications, the Architect shall identify them. The Contract Documents are complementary, and what is called for by any one shall be as binding as if called for by all. The intention of the documents is to include all labor and materials, equipment and trans- portation necessary for the proper execution of the work. Materials or work described in words which so applied have a well-known technical or trade meaning shall be held to refer to such recognized standards. It is not intended, that work not covered under any heading, section, branch, class or trade of the Specifica- tions, shall be supplied unless it is shown on Drawings or is reasonably inferable therefrom as being necessary to produce the intended results. The Architect shall furnish with reasonable promptness, additional instructions by means of drawings or other- wise, necessary for the proper execution of the work. All such drawings and instructions shall be consistent with the Contract Documents, true developments there- of, and reasonably inferable therefrom. The work shall be executed in conformity therewith and the Contractor shall do no work without proper drawings and instructions. Immediately after being awarded the Contract the Contractor shall prepare an estimated Progress Schedule and submit it for Architect's approval. It shall indi- cate the dates for the starting and completion of the various stages of construction. ARTICLE 4 COPIES FURNISHED Unless otherwise provided in the Contract Documents the Contractor will be furnished, free of charge, all copies of drawings and specifications reasonably neces- sary for the execution of the work. ARTICLE 5 SHOP DRAWINGS The Contractor shall -check -and -verify. all_field measure- ments and shall submit with such promptness as to cause no delay in his own work or in that of any other Contractor, three copies, checked and approved by him, of all shop or setting drawings and schedules re- quired for the work of the various trades. The Architect shall check and approve, with reasonable promptness, such schedules and drawings only for conformance with the design concept of the Project and compliance with the information given in the Contract Documents. The Contractor shall make any corrections required by the Architect, file with him two corrected copies and furnish such other copies as may be needed. The Architect's approval of such drawings or schedules shall not relieve the Contractor from responsibility for deviations from Drawings or Specifications, unless he has in writing called the Architect's attention to such deviations at the time of submission, and secured his written approval, nor shall it relieve him from responsibility for errors in s; -op drawings or schedules. ARTICLE 6 DRAWINGS AND SPECIFICATIONS ON THE WORK The Contractor shall keep one copy of all Drawings and Specifications on the -work, ingoodorder, available to the Architect and to his representative. GENERAL CONDITIONS OF CONTRACT TEN PAGES AIA DOC. A201 SEPT. 1963 ED. PAGE 2 ARTICLE 7 OWNERSHIP OF DRAWINGS All Drawings, Specifications and copies thereof furnished by the Architect are his property. They are not to be used on other work, and, with the exception of the signed Contract set, are to be returned to him on re- quest, at the completion of the work. ARTICLE 8 SAMPLES The Contractor shall furnish for approval, with such promptness as to cause no delay in his own work or in that of any other Contractor, all samples as directed by the Architect. The Architect shall check and approve such samples, with reasonable promptness, only for con- formance with the design concept of the Project and for compliance with the information given in the Contract Documents. The work shall be in accordance with ap- proved samples. ARTICLE 9 MATERIALS, APPLIANCES, EMPLOYEES Unless otherwise stipulated, the Contractor shall pro- vide and pay for all materials, labor, water, tools, equipment, light, power, transportation and other facili- ties necessary for the execution and completion of the work. Unless otherwise specified all materials shall be new and both workmanship and materials shall be of good quality. The Contractor shall, if required, furnish satisfactory evidence as to the kind and quality of materials. The Contractor shall at all times enforce strict disci- pline and good order among his employees, and shall not employ on the work any unfit person or anyone not skilled in the work assigned to him. ARTICLE 10 ROYALTIES AND PATENTS The Contractor shall pay all royalties and license fees. He shall defend all suits or claims for infringement of any patent rights and shall save the Owner harmless from loss on account thereof, except that the Owner shall be responsible for all such loss when a particular process or the product of a particular manufacturer or manufacturers is specified, but if the Contractor has in- formation that the process or article specified is an infringement of a patent, he shall be responsible for such loss unless he promptly gives such information to the Architect or Owner. ARTICLE 11 SURVEYS, PERMITS, LAWS, TAXES AND REGULATIONS The Owner shall furnish all surveys unless otherwise specified. Permits and licenses necessary for the prosecution of the work shall be secured and paid for by the Contrac- tor. Easements for permanent structures or permanent changes in existing facilities shall be secured and paid for by the Owner, unless otherwise specified. The Contractor shall give all notices and comply with all laws, ordinances, rules and regulations bearing on the conduct of the work as drawn and specified. If the Contractor observes that the Drawings and Specifications are at variance therewith, he shall promptly notify the Architect in writing and any necessary changes shall be adjusted as provided in the Contract for changes in the work. If the Contractor performs any work knowing it to be contrary to such laws, ordinances, rules and regu- lations, and without such notice to the Architect, he shall bear all costs arising therefrom. Wherever the law of the place of building requires a sales, consumer, use, or other similar tax, the Contrac- tor shall pay such tax. ARTICLE 12 PROTECTION OF WORK AND PROPERTY The Contractor shall continuously maintain adequate protection of all his work from damage and shall pro- tect the Owner's property from injury or loss arising in connection with the Contract. He shall make good any such damage, injury or loss, except such as may be directly due to errors in the Contract Documents or caused by agents or employees of the Owner, or due to causes beyond the Contractor's control and not to his fault or negligence. He shall adequately protect ad- jacent property as provided by law and the Contract Documents. The Contractor shall take all necessary precautions for the safety of employees on the work, and shall com- ply with all applicable provisions of Federal, State, -and Municipal safety laws and building codes to prevent ac- cidents or injury to persons on, about or adjacent to the premises where the work is being performed. He shall erect and properly maintain at all times, as required by the conditions and progress of the work, all necessary safeguards for the protection of workmen and the public and shall post danger signs warning against the hazards created by such features of construction as protruding nails, hoists, well holes, elevator hatchways, scaffolding, window openings, stairways and falling materials; and he shall designate a responsible member of his organiza- tion on the work, whose duty shall be the prevention of accidents. The name and position of any person so designated shall be reported to the Architect by the Contractor. In an emergency affecting the safety of life -or of the - work or of adjoining property, the Contractor, without special instruction or authorization from the Architect or Owner, is hereby permitted to act, at his discretion, to prevent such threatened loss or injury; and he shall so act, without appeal, if so authorized or instructed. Any compensation, claimed by the Contractor on ac- count of emergency work, shall be determined by agree- ment or arbitration. GENERAL CONDITIONS OF CONTRACT TEN PAGES AIA DOC. A201 SEPT. 1963 ED. PAGE 3 ARTICLE 13 ARTICLE 15 ACCESS TO WORK The Architect and his representatives shall at all times have access to the work wherever it is in preparation or progress and the Contractor shall provide proper facilities for such access and so that the Architect may perform his functions under the Contract Documents. If the Specifications, the Architect's instructions, laws, ordinances or any public authority require any work to be specially tested or approved, the Contractor shall give the Architect timely notice of its readiness for observa- tion by the Architect or inspection by another authority, and if the inspection is by another authority, of the date fixed for such inspection, required certificates of inspec- tion being secured by the Contractor. Observations by the Architect shall be promptly made, and where prac- ticable at the source of supply. If any work should be covered up without approval or consent of the Archi- tect, it must, if required by the Architect, be uncovered for examination at the Contractor's expense. Re-examination of questioned work may be ordered by the Architect and if so ordered the work must be uncovered by the Contractor. If such work be found in accordance with the Contract Documents the Owner shall pay the cost of re-examination and replacement. If such work be found not in accordance with the Con- tract Documents the Contractor shall pay such cost, un- less it be found that the defect in the work was caused by- a- Contractor employed as provided_ in Article 35,. and in that event the Owner shall pay such cost. ARTICLE 14 CONTRACTOR'S SUPERINTENDENCE AND SUPERVISION The Contractor shall keep on his work, during its prog- ress, a competent superintendent and any necessary as- sistants, all satisfactory to the Architect. The superin- tendent shall not be changed except with the consent of the Architect, unless the superintendent proves to be unsatisfactory to the Contractor and ceases to be in his employ. The superintendent shall represent the Con- tractor in his absence and all directions given to him shall be as binding as if given to the Contractor. Im- portant directions shall be confirmed in writing to the Contractor. Other directions shall be so confirmet orr written request in each case. The Architect shall not be responsible for the acts or omissions of the superin- tendent or his assistants. The Contractor shall give efficient supervision to the work, using his best skill and attention. He shall care- fully study and compare all Drawings, Specifications and other instructions and shall at once report to the Archi- tect any error, inconsistency or omission which he may discover, but he shall not be liable to the Owner for any damage resulting from any errors or deficiencies in the Contract Documents or other instructions by the Architect. CHANGES IN THE WORK The Owner, without invalidating the Contract, may order extra work or make changes by altering, adding to or deducting from the work, the Contract Sum being adjusted accordingly. All such work shall be executed under the conditions of the original Contract except that any claim for extension of time caused thereby shall be adjusted at the time of ordering such change. In giving instructions, the Architect shall have au- thority to make minor changes in the work, not involv- ing extra cost, and not inconsistent with the purposes of the building, but otherwise, except in an emergency endangering life or property, no extra work or change shall be made unless in pursuance of a written order from the Owner signed or countersigned by the Archi- tect, or a written order from the Architect stating that the Owner has authorized the extra work or charge, and no claim for an addition to the Contract Sum shall be valid unless so ordered. The value of any such extra work or change shall be determined in one or more of the following ways: a) By estimate and acceptance in a lump sum. b) By unit prices named in the Contract or subsequently agreed upon. c) By cost and percentage or by cost and a fixed fee. If none of the above methods is agreed upon, the Contractor, provided he receives an order as above, shall proceed with the work. In such case and also under case (c), he shall keep and present in such form as the Architect may- direct, -a_correct_account _of the cost, to- gether with vouchers. In any case, the Architect shall certify to the amount, including reasonable allowance for overhead and profit, due to the Contractor. Pending final determination of value, payments on account of changes shall be made on the Architect's certificate. Should conditions encountered below the surface of the ground be at variance with the conditions indicated by the Drawings and Specifications the Contract Sum shall be equitably adjusted upon claim by either party made within a reasonable time after the first observance of the conditions. ARTICLE 16 CLAIMS FOR EXTRA COST If the Contractor claims that any instructions by draw- ings or otherwise involve extra cost under the Contract, he shall give the Architect written notice thereof within a reasonable time after the receipt of such instructions, and in any event before proceeding to execute the work, except in emergency endangering life or property, and the procedure shall then be as provided for changes in the work. No such claim shall be valid unless so made. ARTICLE 17 DEDUCTIONS FOR UNCORRECTED WORK If the Architect and Owner deem it inexpedient to cor- rect work injured or done not in accordance with the Contract, an equitable deduction from the Contract Sum shall be made therefor. GENERAL CONDITIONS OF CONTRACT TEN PAGES AIA DOC. A201 SEPT. 1963 ED. PAGE 4 ARTICLE 18 DELAYS AND EXTENSION OF TIME If the Contractor be delayed at any time in the progress of the work by any act or neglect of the Owner or the Architect, or of any employee of either, or by any separate Contractor employed by the Owner, or by changes ordered in the work, or by labor disputes, fire, unusual delay in transportation, unavoidable casu- alties or any causes beyond the Contractor's control, or by delay authorized by the Architect pending arbitra- tion, or by any cause which the Architect shall decide to justify the delay, then the time of completion shall be extended for such reasonable time as the Architect may decide. No such extension shall be made for delay occurring more than seven days before claim therefor is made in writing to the Architect. In the case of a continuing cause of delay, only one claim is necessary. If no schedule or agreement stating the dates upon which drawings shall be furnished is made, then no claim for delay shall be allowed on account of failure to furnish drawings until two weeks after demand for such drawings and not then unless such claim be reasonable. This articles does not exclude the recovery of dam- ages for delay by either party under other provisions in the Contract Documents. ARTICLE 19 CORRECTION OF WORK BEFORE SUBSTANTIAL COMPLETION The Contractor shall promptly remove from the prem- ises all work condemned by the Architect as failing to conform to the Contract, whether incorporated or not, and the Contractor shall promptly replace and re - execute his own work in accordance with the Contract and without expense to the Owner and shall bear the expense of making good all work of other contractors destroyed or damaged by such removal or replacement. If the Contractor does not remove such condemned work within a reasonable time, fixed by written notice, the Owner may remove it and may store the material at the expense of the Contractor. If the Contractor does not pay the expenses of such removal within ten days' time thereafter, the Owner may, upon ten days' written notice, sell such materials at auction or at pri- vate sale and shall account for the net proceeds thereof, after deducting all the costs and expenses that should have been borne by the Contractor. ARTICLE 20 CORRECTION OF THE WORK AFTER SUBSTANTIAL COMPLETION The Contractor shall remedy any defects due to faulty materials or workmanship and pay for any damage to other work resulting therefrom, which shall appear within a period of one year from the date of Substantial Completion as defined in these General Conditions, and in accordance with the terms of any special guarantees provided in the Contract. The Owner shall give notice of observed defects with reasonable promptness. All questions arising under this Article shall be decided, by the Architect subject to arbitration, notwithstanding final payment. ARTICLE 21 THE OWNER'S RIGHT TO DO WORK If the Contractor should neglect to prosecute the work properly or fail to perform any provision of the Con- tract, the Owner, after three days' written notice to the Contractor may, without prejudice to any other remedy he may have, make good such deficiencies and may deduct the cost thereof from the payment then or thereafter due the Contractor, provided, however, that the Architect shall approve both such action and the amount charged to the Contractor. ARTICLE 22 OWNER'S RIGHT TO TERMINATE CONTRACT If the Contractor should be adjudged a bankrupt, or if he should make a general assignment for the benefit of his creditors, or if a receiver should be appointed on ac- count of his insolvency, or if he should persistently or repeatedly refuse or should fail, except in cases for which extension of time is provided, to supply enough properly skilled workmen or proper materials, or if he should fail to make prompt payment to subcontractors or for material or labor, or persistently disregard laws, ordinances or the instructions of the Architect, or other- wise be guilty of a substantial violation of any provision of the Contract, then the Owner, upon the certificate of the Architect that sufficient cause exists to justify such action, may, without prejudice to any other right or remedy and after giving the Contractor, and his surety if any, seven days' written notice, terminate the employ- ment of the Contractor and take possession of the premises and of all materials, tools and appliances thereon and finish the work by whatever method he may deem expedient. In such case the Contractor shall not be entitled to receive any further payment until the work is finished. If the unpaid balance of the Contract Sum shall exceed the expense of finishing the work including compensation for additional architectural, managerial and administrative services, such excess shall be paid to the Contractor. If such expense shall exceed such unpaid balance, the Contractor shall pay the difference to the Owner. The expense incurred by the Owner as herein provided, and the damage incurred through the Contractor's default, shall be certified by the Architect. GENERAL CONDITIONS OF CONTRACT TEN PAGES AIA DOC. A201 SEPT. 1961 ED. PAGE 5 ARTICLE 23 THE CONTRACTOR'S RIGHT TO STOP WORK OR TERMINATE CONTRACT If the work should be stopped under an order of any court, or other public authority, for a period of thirty days, through no act or fault of the Contractor or of anyone employed by him, then the Contractor may, upon seven days' written notice to the Owner and the Architect, terminate the Contract and recover from the Owner payment for all work executed and any proven loss sustained upon any plant or materials and reason- able profit and damages. Should the Architect fail to issue any Certificate for Payment, through no fault of the Contractor, within seven days after the Contractor's formal request for payment or if the Owner should fail to pay to the Con- tractor within seven days of its maturity and presen- tation, any sum certified by the Architect or awarded by arbitrators, then the Contractor may, upon seven days' written notice to the Owner and the Architect, stop the work or terminate the Contract as set out in the preceding paragraph. ARTICLE 24 APPLICATIONS FOR PAYMENTS At least ten days before each payment falls due, the Contractor shall submit to the Architect an itemized application for payment, supported to the extent re- quired by the Architect by receipts or other vouchers, showing payments for materials and labor, payments to subcontractors and such other evidence of the Contrac- tor's right to payment as the Architect may direct. If payments are made on valuation of work done, the Contractor shall, before the first application, submit to the Architect a schedule of values of the various parts of the work, including quantities, aggregating the total sum -of -the -Contract; divided -so -as to -facilitate -payments - to subcontractors in accordance with Article 37(e), made out in such form as the Architect and the Con- tractor may agree upon, and, if required, supported by such evidence as to its correctness as the Architect may direct. This schedule, when approved by the Architect, shall be used as a basis for Certificates for Payment, un- less it be found to be in error. In applying for payments, the Contractor shall submit a statement based upon this schedule. If payments are made on account of materials not incorporated in the work but delivered and suitably stored at the site, or at some other location agreed upon in writing, such payments shall be conditioned upon submission by the Contractor of bills of sale or such other procedure as will establish the Owner's title to such material or otherwise adequately protect the Own- er's interest including applicable insurance. ARTICLE 25 CERTIFICATES FOR PAYMENTS If the Contractor has made application for payment as above, the Architect shall, not later than the date when each payment falls due, issue a Certificate for Payment to the Contractor for such amount as he decides to be properly due, or state in writing his reasons for with- holding a certificate. No certificate issued nor payment made to the Con- tractor, nor partial or entire use or occupancy of the work by the Owner, shall be an acceptance of any work or materials not in accordance with the Contract. When advised by the Contractor that the work is substantially completed, the Architect and the Contractor shall within a reasonable time make a joint inspection of the work and if the Architect shall determine that the work is substantially completed, he shall then prepare a Cer- tificate of Substantial Completion, which shall be sub- mitted to the Owner and the Contractor for their execu- tion. The making and acceptance of the final payment shall constitute a waiver of all claims by the Owner, other than those arising from unsettled liens, from faulty work appearing after Substantial Completion or from failure to comply with Drawings and Specifica- tions and the terms of any special guarantees specified in the Contract and of all claims by the Contractor, except those previously made and still unsettled. Should the Owner fail to pay the sum named in any Certificate for Payment issued by the Architect or in any award by arbitration, upon demand when due, the Con- tractor shall receive, in addition to the sum named in the Certificate for Payment, interest thereon at the legal rate in force at the place of building. ARTICLE 26 PAYMENTS WITHHELD The Architect may withhold or, on account of subse- quently discovered evidence, nullify the whole or a part of any certificate to such extent as may be necessary in his reasonable opinion to protect the Owner from loss on account of: a) Defective work not remedied. b) Claims filed or reasonable evidence indicating prob- able filing of claims. c) Failure of the Contractor to make payments prop- erly to subcontractors or for material or labor. d) A reasonable doubt that the Contract can be com- pleted for the balance then unpaid. e) Damage to another Contractor. When the above grounds are removed payment shall be made for amounts withheld because of them. ARTICLE 27 CONTRACTOR'S LIABILITY INSURANCE The Contractor shall maintain such insurance as will protect him from claims under workmen's compensation acts and other employee benefits acts; from claims for damages because of bodily injury, including death, to his employees and all others; and from claims for dam- ages to property —any or all of which may arise out of or result from the Contractor's operations under the Contract, whether such operations be by himself or by any subcontractor or anyone directly or indirectly em- ployed by either of them. This insurance shall be writ- ten for not less than any limits of liability specified as part of the Contract. Certificates of such insurance shall be filed with the Owner and Architect. GENERAL CONDITIONS OF CONTRACT TEN PAGES AIA DOC. A201 SEPT. 1963 ED. PAGE 6 ARTICLE 28 OWNER'S LIABILITY INSURANCE The Owner shall be responsible for and at his option may maintain such insurance as will protect him from his contingent liability to others for damages because of bodily injury, including death, which may arise from operations under the Contract, and any other liability for damages which the Contractor is required to insure under any provision of the Contract. ARTICLE 29 FIRE INSURANCE WITH EXTENDED COVERAGE Unless otherwise provided, the Owner shall effect and maintain fire insurance with extended coverage upon the entire structure on which the work of the Contract is to be done to one hundred per cent of the insurable value- thereof; including- items of- labor and- materials connected therewith whether in or adjacent to the struc- ture insured, materials in place or to be used as part of the permanent construction including surplus materials, shanties, protective fences, bridges, temporary struc- tures, miscellaneous materials and supplies incident to the work, and such scaffoldings, stagings, towers, forms, and equipment as are not owned or rented by the Con- tractor, the cost of which is included in the cost of the work. ExcLustoxs: This insurance does not cover any tools owned by mechanics, any tools, equipment, scaf- folding staging, towers, and -forms -owned -or rented -by - the Contractor, the capital value of which is not in- cluded in the cost of the work, or any cook shanties, bunk houses or other structures erected for housing the workmen. The loss, if any, is to be made adjustable with and payable to the Owner as Trustee for the in- sureds and Contractors and subcontractors as their in- terests may appear, except in such cases as may require payment of all or a proportion of said insurance to be made to a mortgagee as his interests may appear. Certificates of such insurance shall be filed with the Contractor if he so requires. If the Owner fails to effect or maintain insurance as above and so notifies the Contractor, the Contractor may insure his own in- terests -and -that -of -the subcontractors- and - charge - the - cost thereof to the Owner. If the Contractor is dam- aged by failure of the Owner to maintain such insurance or to so notify the Contractor he may recover as stipu- lated in the Contract for recovery of damages. If other special insurance not herein provided for is required by the Contractor, the Owner shall effect such insurance at the Contractor's expense by appropriate riders to his fire insurance policy. The Owner, Contractor, and all subcontractors waive all rights, each against the others, for damages caused by fire or other perils covered by insurance provided under the terms of this article, except such rights as they may have to the proceeds of insurance held by the Owner as Trustee. The Owner shall be responsible for and at his option may insure against loss of use of his existing property, due to fire or otherwise, however caused. If required in writing by any party in interest, the Owner as Trustee shall, upon the occurrence of loss, give bond for the proper performance of his duties. He shall deposit any money received from insurance in an account separate from all his other funds and he shall distribute it in ac- cordance with such agreement as the parties in interest may reach, or under an award of arbitrators appointed, one by the Owner, another by joint action of the other parties in interest, all other procedure being as provided elsewhere in the Contract for arbitration. If after loss no special agreement is made, replacement of injured work shall be ordered and executed as provided for changes in the work. The Trustee shall have power to adjust and settle any loss with the insurers unless one of the Contractors in- terested shall object in writing within three working days of the occurrence of loss, and thereupon arbitrators shall be chosen as above. The Trustee shall in that case make settlement with the insurers in accordance with the directions of such arbitrators, who shall also, if dis- tribution by arbitration is required, direct such dis- tribution. ARTICLE 30 GUARANTY BONDS The Owner shall have the right, prior to the signing of the Contract, to require the Contractor to furnish bond covering the faithful performance of the Contract and the payment of all obligations arising thereunder, in such form as the Owner may prescribe and with such sureties as he may approve. If such bond is required by instructions given previous to the submission of bids, the premium- shall- be- paid- by the- Contractor,- if sub= sequent thereto, it shall be paid by the Owner. ARTICLE 31 DAMAGES Should either party to the Contract suffer damages be- cause of any wrongful act or neglect of the other party or of anyone employed by him, claim shall be made in writing to the party liable within a reasonable time of the first observance of such damage and not later than the final payment, except as expressly stipulated other- wise in the case of faulty work or materials, and shall be adjusted by agreement or arbitration. ARTICLE 32 LIENS Neither the final payment nor any part of the retained percentage shall become due until the Contractor, if required, shall deliver to the Owner a complete release of all liens arising out of the Contract, or receipts in full in lieu thereof and, if required in either case, an affidavit that so far as he has knowledge or information the re- leases and receipts include all the labor and material for which a lien could be filed; but the Contractor may, if any subcontractor refuses to furnish a release or receipt in full, furnish a bond satisfactory to the Owner, to indemnify him against any lien. If any lien remains unsatisfied after all payments are made, the Contractor shall refund to the Owner all moneys that the latter may be compelled to pay in discharging such a lien, including all costs and a reasonable attorney's fee. GENERAL CONDITIONS OF CONTRACT TEN PAGES AIA DOC. A201 SEPT. 1968 ED. PAGE 7 ARTICLE 33 ASSIGNMENT Neither party to the Contract shall assign the Contract or sublet it as a whole without the written consent of the other, nor shall the Contractor assign any moneys due or to become due to him hereunder, without the previous written consent of the Owner. ARTICLE 34 MUTUAL RESPONSIBILITY OF CONTRACTORS Should the Contractor cause damage to any separate contractor on the work the Contractor agrees, upon due notice, to settle with such contractor by agreement or arbitration, if he will so settle. If such separate con- tractor sues the Owner on account of any damage al- leged to have been so sustained, the Owner shall notify the Contractor, who shall defend such proceedings at the Owner's expense and, if any judgment against the Owner arise therefrom, the Contractor shall pay or satisfy it and pay all costs incurred by the Owner. ARTICLE 35 SEPARATE CONTRACTS The Owner reserves the right to let other contracts in connection with this work under similar General Con- ditions. The Contractor shall afford other contractors reasonable opportunity for the introduction and storage of their materials and the execution of their work, and shall properly connect and cordinate his work with theirs. If any part of the Contractor's work depends for proper execution or results upon the work of any other contractor, the Contractor shall inspect and promptly report to the Architect any defects in such work that render it unsuitable for such proper execution and re- sults. Failure of the Contractor so to inspect and report shall constitute an acceptance of the other contractor's work as fit and proper for the reception of his work, except as to defects which may develop in the other contractor's work after the execution of his work. To insure the proper execution of his subsequent work the Contractor shall measure work already in place and shall at once report to the Architect any discrepancy between the executed work and the Drawings. ARTICLE 36 SUBCONTRACTS As soon as practicable and before awarding any subcon- tracts, the Contractor shall notify the Architect in writ- ing of the names of the subcontractors proposed for the principal parts of the work, and for such other parts as the Architect may direct, and shall not employ any to whom the Architect or the Owner may have a reason- able objection. If before or after the execution of the Contract a change of any subcontractor on such list is required by the Architect or by the Owner prior to the award of the relevant contract, the Contract Sum shall be increased or decreased by the difference in cost occasioned by such change. The Contractor shall not be required to employ any subcontractor against whom he has a reasonable objection. The Architect shall, on request, furnish to any sub- contractor, wherever practicable. evidence of the amounts certified on his account. The Contractor agrees that he is as fully responsible to the Owner for the acts and omissions of his subcon- tractors and of persons either directly or indirectly em- ployed by them, as he is for the acts and omissions of persons directly employed by him. Nothing contained in the Contract Documents shall create any contractual relation between any subcon- tractor and the Owner. ARTICLE 37 RELATIONS OF CONTRACTOR AND SUBCONTRACTOR The Contractor agrees to bind every Subcontractor and every Subcontractor agrees to be bound by the terms of the Agreement, the General Conditions of the Con- tract, the Supplementary General Conditions, the Draw- ings and Specifications as far as applicable to his work, including the following provisions of this article, unless specifically noted to the contrary in a subcontract ap- proved in writing as adequate by the Owner or Archi- tect. The Subcontractor agrees — a) To be bound to the Contractor by the terms of the Agreement, General Conditions of the Contract, the Supplementary General Conditions, the Drawings and Specifications, and to assume toward him all the obliga- tions and responsibilities that he, by those documents, assumes toward the Owner. b) To submit to the Contractor applications for pay- ment in such reasonable time as to enable the Con- tractor to apply for payment under Article 24 of the General Conditions. c) To make all claims for extras, for extensions of time and for damages for delays or otherwise, to the Con- tractor in the manner provided in the General Con- ditions of the Contract and the Supplementary General Conditions for like claims by the Contractor upon the Owner, except that the time for making claims for extra cost is one week. The Contractor agrees — d) To be bound to the Subcontractor by all the obliga- tions that the Owner assumes to the Contractor under the Agreement, General Conditions of the Contract, the Supplementary General Conditions, the Drawings and Specifications, and by all the provisions thereof afford- ing remedies and redress to the Contractor from the Owner. GENERAL CONDITIONS OF CONTRACT TEN PAGES MA DOC. A201 SEPT. 1963 ED. PAGE 8 e) To pay the Subcontractor, upon the payment of certificates, if issued under the schedule of values de- scribed in Article 24 of the General Conditions, the amount allowed to the Contractor on account of the Subcontractor's work to the extent of the Subcontractor's interest therein. f) To pay the Subcontractor, upon the payment of cer- tificates, if issued otherwise than as in (e), so that at all times his total payments shall be as large in proportion to the value of the work done by him as the total amount certified to the Contractor is to the value of the work done by him. g) To pay the Subcontractor to such extent as may be provided by the Contract Documents or the subcontract, if either of these provides for earlier or larger payments than the above. h) To pay the Subcontractor on demand for his work or materials as far as executed and fixed in place, less the retained percentage, at the time the Certificate for Payment should issue, even though the Architect fails to issue it for any cause not the fault of the Subcontractor. j) To pay the Subcontractor a just share of any fire in- surance money received by him, the Contractor, under Article 29 of the General Conditions. k) To make no demand for liquidated damages or penalty for delay in any sum in excess of such amount as may be specifically named in the subcontract. I) That no claim for services rendered or materials furnished by the Contractor to the Subcontractor shall be valid unless written notice thereof is given by the Contractor to the Subcontractor during the first ten days of the calendar month following that in which the claim originated. m) To give the Subcontractor an opportunity to be present and to submit evidence in any arbitration in- volving his rights. n) To name as arbitrator under arbitration proceedings as provided in the General Conditions the person nom- inated by the Subcontractor, if the sole cause of dispute is the work, materials, rights or responsibilities of the Subcontractor; or, if of the Subcontractor and any other subcontractor jointly, to name as such arbitrator the person upon whom they agree. The Contractor and the Subcontractor agree that — o) In the matter of arbitration, their rights and obliga- tions and all procedure shall be analogous to those set forth- in- this- Contract; provided; however, that a deci- sion by the Architect shall not be a condition precedent to arbitration. Nothing in this article shall create any obligation on the part of the Owner to pay or to see to the payment of any sums to any subcontractor. ARTICLE 38 ARCHITECT'S STATUS; ARCHITECT'S SUPERVISION The Architect shall be the Owner's representative during the construction period. The Architect will make peri- odic visits to the site to familiarize himself generally with the progress and quality of the work and to deter- mine in general if the work is proceeding in accordance with the Contract Documents. He will not be required to make exhaustive or continuous on -site inspections to check the quality or quantity of the work and he will not be responsible for the Contractor's failure to carry out the construction work in accordance with the Con- tract Documents. During such visits and on the basis of his observations while at the site, he will keep the Owner informed of the progress of the work, will en- deavor to guard the Owner against defects and defi- ciencies in the work of Contractors, and he may con- demn work as failing to conform to the Contract Docu- ments. He shall have authority to act on behalf of the Owner only to the extent expressly provided in the Contract Documents or otherwise in writing, which shall be shown to the Contractor. He shall have authority to stop the work whenever such stoppage may be neces- sary in his reasonable opinion to insure the proper execution of the Contract. The Architect shall be, in the first instance, the inter- preter of the conditions of the Contract and the judge of its performance. He shall side neither with the Owner nor with the Contractor, but shall use his powers under the Contract to enforce its faithful performance by both. In case of the termination of the employment of the Architect, the Owner shall appoint a capable and repu- table Architect against whom the Contractor makes no reasonable objection, whose status under the contract shall he that of the former Architect; any dispute in connection with such appointment shall be subject to arbitration. ARTICLE 39 ARCHITECT'S DECISIONS The Architect shall, within a reasonable time, make de- cisions on all claims of the Owner or Contractor and on all other matters relating to the execution and progress of the work or the interpretation of the Contract Docu- ments. The Architect's decision, in matters relating to ar- tistic effect, shall be final, if within the terms of the Contract Documents. Except as above or as otherwise expressly provided in the Contract Documents, all the Architect's decisions are subject to arbitration. If, however, the Architect fails to render a decision within ten days after the parties have presented their evidence, either party may then demand arbitration. If the Architect renders a decision after arbitration pro- ceedings have been initiated, such decision may be entered as evidence but shall not disturb or interrupt such proceedings except where such decision is accept- able to the parties concerned. GENERAL CONDITIONS OF CONTRACT TEN PACES AIA DOC. A201 SEPT. 1963 ED. PAGE 9 ARTICLE 40 ARBITRATION All disputes, claims or questions subject to arbitration under the Contract shall be submitted to arbitration in accordance with the provisions, then obtaining, of the Standard Form of Arbitration Procedure of The Ameri- can Institute of Architects, and the Agreement shall be specifically enforceable under the prevailing arbitration law, and- judgment- upon- the. award- rendered_ mayhe_ entered in the court of the forum, state or federal, hav- ing jurisdiction. It is mutually agreed that the decision of the arbitrators shall be a condition precedent to any right of legal action that either party may have against the other. The Contractor shall not cause a delay of the work during any arbitration proceedings, except by agreement with the Owner. Notice of the demand for arbitration of a dispute shall be filed in writing with the other party to the Con- tract, and a copy filed with the Architect. The demand for arbitration shall be made within a reasonable time after the dispute has arisen; in no case, however, shall the demand be made later than the time of final pay- ment, except as otherwise expressly stipulated in the Contract. The arbitrators, if they deem that the case requires it, are authorized to award to the party whose conten- tion is sustained, such sums as they or a majority of them shall deem proper to compensate him for the time and expense incident to the proceeding and, if the arbitration was demanded without reasonable cause, they may also award damages for delay. The arbitra- tors shall fix their own compensation, unless otherwise provided by agreement, and shall assess the costs and charges of the proceedings upon either or both parties. ARTICLE 41 CASH ALLOWANCES The Contractor shall include in the Contract Sum all allowances named in the Contract Documents and shall cause the work so covered to be done by such con- tractors and for such sums as the Architect may direct, the Contract Sum being adjusted in conformity there- with. The Contractor declares that the Contract Sum includes such sums for expenses and profit on account of cash allowances as he deems proper. No demand for delivery costs, expenses or profit other than those in- cluded in the Contract Sum shall be allowed. The Con- tractor shall not be required to employ for any such work persons against whom he has a reasonable objec- tion. ARTICLE 42 USE OF PREMISES The Contractor shall confine his apparatus, the storage of materials andtheoperations of his workmen to -limits - indicated by law, ordinances, permits or directions of the Architect and shall not unreasonably encumber the premises with his materials. The Contractor shall not load or permit any part of the structure to be loaded with a weight that will en- danger its safety. ARTICLE 43 CUTTING, PATCHING The Contractor shall do all cutting, fitting or patching of his work that may be required to make its several parts come together properly and fit it to receive or be received by work of other contractors shown upon, or reasonably implied by, the Drawings and Specifica- tions for the completed structure, and he shall make good after them as the Architect may direct. Any cost caused by defective or ill-timed work shall be borne by the party responsible therefor. The Contractor shall not endanger any work by cut- ting, excavating or otherwise altering the work and shall not cut or alter the work of any other contractor save with the consent of the Architect. ARTICLE 44 CLEANING UP The Contractor shall at all times keep the premises free from accumulation of waste materials or rubbish caused by his employees or work, and at the completion of the work he shall remove all his rubbish from and about the building and all his tools, scaffolding and surplus materials and shall leave his work "broom -clean" or its equivalent, unless more exactly specified. In case of dispute the Owner may remove the rubbish and charge the cost to the several contractors as the Architect shall determine to be just. GENERAL CONDITIONS OF CONTRACT TEN PAGES AIA DOC. A201 SEPT. 1963 ED. PAGE 10 P w 190 ',(T S ScPp7.klm- EA.1,L BE I1 DE TO Ai L>_C. at THE ti !.. c 9 rO ., v r. {y ,.,TO ERTY _ GkEPSPC°US oR =SS,.OeNG" U A c,;NrRkL+,' sa N TEE EEEERAL S R !: e p5,`"^. TRADES. CON '. ,i.F' N OR PAT �� SI 'CF SIC -",.r DE ANA 9.m,i.` N 37 r 1 WO RA3 PELAVE I ' 1 OA WORP THE —Ova RA U4}0 r.. No RFSRONS B E..TRAR Ef. PIMP , `FO dS A.SSRMA3 G d'RCH TECT OR. OWNER FOP P SD OA 3R OVA f. CAT,, OHS SY THE ,...Pa... TRACTOR 'fl US RLEU..ORTRA7ORr DUE O 9u`x,.F OR kP- EGED ERROR Ft +*.R•M1 Pd14 i,. 1'�F` �S1 Cr ,, v Tvr3 i' AIRACT D FROM ARE ANY DAMAGE '4'G COSTS €oc ALL A4A4LASLF N C.O U' a Y <; DAMASE THA V E'ATH aR S It p,.E R^:vPOE!N FRG.A ."-OR T"A. C tTFS+ hoS .,WA CC.REAS AAP a.S .LSO RF'SROINSli$3LE FOR ORE TO Ne:S—U''Su. or !W1.= SYSTAk. FVE'_, Sa "',.'. SE D€:aARfE S"' €RF: {, WRGRz (H"A'a E Hots mP OUGE NORMAL GPFRA G !;OrN S''t THE WATER - her' ",)''fr-:'ice SEALPROr'6 ria',, FOR ALL WATER FOR S?JrI!.!F_'- P9iG PURPOSES REQUuPF.O BY ALL 3F;},nk_S, EE &°.C T rNeRc3.' FOR LiIGT ANC .POWER 'COO DU%"L.rr,NG PARROSCS WA CR IS Rr_:OU Rt:F1 • ALL TR;ARES. OWNER SHALL ROWPDA.AWD PX FOR ALL !m' FCFR'kCAF "r b S? hide 0Y ARAEAO • CAT OP3 O 7 VPPOF' f FAD NOT AS A AL?: TAE 3RECIT ✓ TAD TD SE EUR REQU REO. ^revk: %U:3 TRADE NAMES F:C ijE . Or PROi'. CV ". r "4'I !!CRS ARA 70E CONTRACTOR, , +n TORE.t r. N 5E. ONE RE TRE . UANDATORY AND F4NAL ARO DUET _.... asktir Ma Vr.R ANH-1..`. F eTHE: STE w eREDUCERS S€':A.E.FC REACH THE AR€.r .. ,r a ATTAR ADAM $i 4.'0_` h .. P OR 70 S4!. OTENIEG AHAE0 No EATPO E ANT ARTCRE OR V s i ..R Pt G .,. e ' _ r y b i ry i, e 'nic.4 ! ORp OR ROE ETRCflAT AN.TERT DR ERECTLOT OA T S€.k 9 Ar DFAZAENCE ED t,nT, o5 THAW 7A.E - i- MATERAL SPEC1F_ REDUCER E CONTRACTOR SHALT St {E OUT TAC r Fi bP 'g tea.°, F, AND DRALL PROVO`; `"'RO RiADLY -a"._ �,�` ea I BETTED Hd F_ '+. THRUST m' hit c£C''Rs!}S. SHAEL AVA7iHHA M USE A40 BE FREE TO ALL RADURING TAREOt MGT THS CONTRACTOR EVAALL T,. RESPONSUSTE ROD TTED ACCURACY AAR P4r RT'EF q0 r �✓ r , t'i C.E r e. P. �- BENCH PARR FROM. 44414.17541444. ALL GRADED MA ' S4 T4K En=. 44 ',€C YS ST.."'L '! OW rN SERECTS t?jt'y%x DG. HE H THE-, ni,.rE GA THE AR DIj1.7Ci,, FROM BANCi4 OARS, Ht E' S COH .. LEVELS . £ '�'Qg a.dz^.r n�"aAt rD f3. ., Gk�F5,Ru:S Aso !4 `�; 5°''yS 17544E 8Ufi I''d RF; AS NEEDED:. Q/AI�-IV TO 5 C Q .S S 'ROYALS E0 A. CONTRACTORS :AND SUBCONTRACTORS EMPLCEED ODOR THE WORT SHALT. AND IgLA RE R Qu RCA TO COnFO€:✓'4S 70 STATE AND FEDERAL LASOE: LAWS 4' `0 THE VAD OUS .CTS v48ENDATOp'Y 4440 SWPPLEMER ARY THERETO; ETO; AND TO ALL Ovn., _R TAWS 07x0 ir44CE3 AMP SFS2,A. REQU PEME?45p APP",. C.CR.CPLE nREREED ALA LABOR SHALL F PERaT `PisED :1W A GOOD AND WOREMsN6_.'5E MAN€,qER BY ME"CHA.NCS ST C. tD 7N THER !•5y.5P €'.C. `11''g TRE+DFS., M2CE,4:=rNUCS !s`h°OSt WORK ;S UNSATSFAaORT OR ACNS,DF'3=0 BY ThE .w.R;. ,pC1 TO RE UNE SE HOLED OR OTN!5Rw]SE OBJECTONABEE, SHALL iIMMEDIATR. I4' BE rpow TEE p..iORR.. u'os NOTCR DROP THE ARcs `E TO B.. r4R'_ ORD'Fs Fs ,:. v, Y s r. -' V? 4 64 p,a ze RE, EACH SHALL vsVERTY ALL MEASUREITENTS AT S r 'U 4) 44 G? f Ai C6 '„ SPONSEIBLE DOH THE 007575755.14755 OF c 'a"'„ No 7114775 CNS R75, _. OR COMPERE SAON WALL S'' i OWED O'S. ACCOURT DA .t `.r z t 7E we. WrER{ e.C,"CFt- 0 ]M N511 NS AS�� ,r e €a ;, `, r OA EAR D,y , OPERf.T "OH OF 14E. Cot.itpAc -firR OR O Aar =CE ,,'i'.w f li_c.A' S :D 74^. a.: s „P..`_ BE HARE TO ARTIO SUCH WR4T9L4a 401!F SHALL toy ac y%=n '"c ARCHITECT W9TR9N STAN TO AR"I '.t .._, IHc CrC'tk.ac, 5FAFHp OP `t.T, 5 SCa AR'l.. `sOR ,� ;l F' r 4; i'T' `a' 555E $.r ,"6t:is,-^JJURY OR z'4s$o-,Ce`.-. T O FAD CE .3; 'FOFIIIFt ALA NEW WORN .. 5`- Oti ¢.,-,xc -n r" � 4. 'w EC cOOCCAD, ,�ca ' .. r _ w`^C OR pc FToC, ITFIII. I4OR5 .5 SC5PENOAD. FOR 4OF R,r„i ti4 C4Co CONTRACTOR THALI. t Q y F. r O I F c' v c FFLOIAA COD ?HOFF r 'O E L 45 S yr,S 1 n AO a ; RO• OALOC., WHEN A't'. i oDIO n cr S TOE CO RR;I'C OR v .c SLOP HOO5ORDOEIip S48 6wr tO IC,! NG AODOI.ION.SFYiiFLL OE H:CRE TO P,RMF IT SHALL OE TAZ NOT1 OF F5F SUPRORFENDFAI T..A {si'iE ALL ,`Hy.s£ ,..EVELS,, EC, @CAD , BT TOE COH7RECTOR OR OWNER CO FACILITATE AA F:5 `�+"_' ' ffA niAFTIFER FF4 ARE ET -PLOT Or ROCS ci OF AP7 °,k ART/CLE S O eS I N40 c t?{6 S (TRA CG'S R SOALL BE RiAGE TO AR39c;t..C. 2 CERTIFICATES ia.'o CAii,r't "aiE. A:2O6.,5^r'Or CONTRACTOR'S LU-I,— DAFEATHA NSEARAEACEp S"L.aCOE-T rAc ' 'a' 5 L1ALROCATTA L ha§t. R .NC-,". C COMPENSATION, Var cLr N5LIEANLCAn AND PROPERTY DAMAGE SHALL DE r n EO WITH TOE ARmr, `C RI/OH i SE.dEW a cARnrn,„FaR O5 -"S Or TEE SION N'O' OF THE CONTRACT,. t31'-. 5ARRF IH5N G Jr NCI 000 Cc,p F FC5 ACC Ai0OOFLia HOT I L.555 „'itiC O N O F kw,U r oN N tR.. r, AOTY0 70 S ;EIP?? r, t • SEAn Er Or AR N W4 NEVER iH T' ,t :t DOC. ..NT3 S e° dt se .f..^ y K'£u r' "AS RQU?R'I:Dh3•" S !.. :%. i;'r kC£'Ss- a ORr$ OR 6Rf'.S`.S or I. APt. USED, T ;.VAC V E3s ,w C2 Eh OAT 74a ORDER, t R,C iCti. 04flREM.`=73, OR AL(.)';4g fv 4'•, OF '-r fsS APr. T!CI s P 'd eEN E;),� n TVw . S Ublia „ARIL` s'iOROS ` ;^rk rV'• t:'. Pf; bt& er1:!''..E't Lyn, " SA7 sFo.CIORmg'4 OR WO?t€3S OF LE EFFECT :4nu .5IP2F7< s4',..F=4�. OTWER4f^SCt A4I '+ ST sC4€- k.It N R5j4, "s&'aiL 4t, As Afi Exit _p ,. SUtFw8LEt ACC47 *:€3E.E; P R on ..AT! `. rc?oRY 1K Th.E ,s«. E.tLP n''•der" THE AACHiTECT, ARttCP.. 5 %-'-`DE&.. ART BE. MA 4F TO ART, 1HE OwNiZR RE."'.'e "z� Rt @''.'. �f aDU Qkh',.L r_ 'h— Elfl AS OP A C 4 ?F Ru E s';Y N* rS'::t N R .d ' .� , �' ' i' ?, !• � �"-;: (, a � � ;;: %=: i. '� L Fn `� R 4 Y, is gI 7HER EA M, t is Y r.` �`. NO a 'r , � ARCH IIC e _.w`° { OR SHA MAY CCO??.`A TRACOR AT CoMPLETAN .:e... €i V I spa' G ALL TE;MPDR.A S?%RY ALL $a PEAC mg UTS .UU STAINNO S AND SNALL ALNVA toNfi/ C,LRANj'aa> ...,d..n.6,`...,. a._.=., e.: - AL:i:.. CLEAN AND . D t.S.0 ALL SK a:' . a P ILET vPw CLEAhsI`G Or AL CLEAN ALL NEW FINTURZR i I RT ks,;n+ DUST, CLEANING AF'FE«"iS 17 OUST, DIRT, to Comi P.aW u."_ S P Uu. SOON CC,SIN G . _ L SA:''.. 5 _ SWt FP .4 l ., .,. &LL 7LOONS SwAUU. REMOE ALL RAAISS9 Or Bye To 'NORK 4M y _ F s S A 34c o M's ;L F, is s TO R,4CTO,R ,A ART CLzL 564 OR 8 H SUM SKALL tir E•RALS MD SURF ND e 550 iN :"0N5'IRN T 01 «'-`. .". *'• WORK 2f QL`. i 7D BI TX CONINAC f DCCU' N3cz .. - SUDCONl R © FORS AND cSUPP!I<R> 132€5 TO TN (0 TR4C. IO 44CM C';I'..fl TAX AS = CAR? DSC4RN`i134..E tiTt'.M. 73 F,r.CII'_.. 4%:M 5c,E CON`d I''OF S si. .ECR M.0 3rC S A S PARATE d TZ1F OF ee MSE Or NS AECORDS. 4 PAN 7IAO 5U LC'rr R., :i !:` 4 .4 TC v r' x SKA.A MI F 34i 5 i7 1N4 7 Ui T Of IN CO `RAC7 Nrct UPON RSQUMS'Y,, UT THE OWNER, TN COMTRaCTO,R 3€1Au-, dURN R 14 !PL. Ca7n 70 "Mc As{41t70;.`d 1 j': SALtS lax FORM is SHOWN flN SiEC'oN Bp N.ANT 5, NLypNEN1_,» EX C,uNE.G; U2). A . Sd 0* M,A?O:R:1,A,L.S AND $ii' . ,S TA,. WAS PAN, `evf„. a:VDUNI %.:r i ;py 70 J7{. M WAS OM 'nit1CM I:.T WAS PO • TE; ' L. CONY OF Sh %? EORt. 4NND LST TO OSi A N A. % rom:O OF _,M is C.(ONTRAC7OR S _ SF.N ON Wirer PAD, AND TN 1RANSM u- ON AL SS TAX FA,4' CP.RE 70 I11iS3'I7 f. N D !,1 Z P 7 Y Y., I'. , f. S O S E E717 i C �. S .0 MOST 0$d ,TAORT 17' aJ N R 044 Il casC, 07 d 44F : or TNQ F`.. tp U RAS i' v G €v: ey EEr .; N D 1+ G .i ISr CHOIIINUri,BC+5x1 ". eSi EOPOREE o +i ? ., 4 i vk R e r SHALL F ,.%' 'a; THE AMERICAN INSTITUTE OF ARCHITECTS F W U O AIA DOCUMENT SEPT. 1963 ED. A311 PERFORMANCE BOND KNOW ALL MEN BY THESE PRESENTS: that (Here insert name and address or legal title of Contractor) as Principal, hereinafter called Contractor, and, (Here insert the legal title and address of Surety) as Surety, hereinafter called- Surety, are held and firmly bound unto (Name and address or legal title of Owner) as Obligee, hereinafter called Owner, in the amount of Dollars ($ ), for the payment whereof Contractor and Surety bind themselves, their heirs, executors, administrators, suc- cessors and assigns, jointly and severally, firmly by these presents. WHEREAS, Contractor has by written agreement dated 19 , entered into a contract with Owner for in accordance with drawings and specifications prepared by (Here insert full name, title and address) which contract is by reference made a part hereof, and is hereinafter referred to as the Contract. PERFORMANCE/LABOR-MATERIAL BOND AlA DOC. A311 SEPT, 1963 ED. FOUR PAGES 1963 The American Institute of Architects PAGE 1 1735 New York Ave N,W., Washington, D. C. MT 'ZEUS ITEV 'OOQ dad NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION is such that, if Contractor shall promptly and faithfully perform said Contract, then this obligation shall be null and void: otherwise it shall remain in full force and effect. The Surety hereby waives notice of any alteration or extension of time made by the Owner. Whenever Contractor shall be, and declared by Owner to be in default under the Contract, the Owner having performed Owner's obligations thereunder, the Surety may promptly remedy the default, or shall promptly 1) Complete the Contract in accordance with its terms and conditions, or 2) Obtain a bid or bids for submission to Owner for completing the Contract in accordance with its terms and conditions, and upon determination by Owner and Surety of the lowest responsible bidder, arrange for a contract between such bidder and Owner, and make available as work progresses (even though there should he a default or a succession of defaults under the con- tract or contracts of completion arranged under this Signed and sealed this IN THE PRESENCE OF: I paragraph) sufficient funds to pay the cost of com- pletion less the balance of the contract price; but not exceeding, including other costs and damages for which the Surety may be liable hereunder, the amount set forth in the first paragraph hereof. The term "balance of the contract price," as used in this paragraph, shall mean the total amount payable by Owner to Contractor under the Contract and any amendments thereto, less the amount properly paid by Owner to Contractor. Any suit under this bond must be instituted before the expiration of two (2) years from the date on which final payment under the contract falls due. No right of action shall accrue on this bond to or for the use of any person or corporation other than the Owner named herein or the heirs, executors, adminis- trators or successors of Owner. day of A.D. 19 (Principal) (Seal) (Title) (Surety) (Seal) (Title) PERFORMANCE/LABOR-MATERIAL BOND FOUR PAGES AIA DOC. A311 SEPT. 1963 ED. PAGE 2 THE AMERICAN INSTITUTE OF ARCHITECTS A311 LABOR AND MATERIAL PAYMENT BOND THIS BOND IS ISSUED SIMULTANEOUSLY WITH PERFORMANCE BOND IN FAVOR OF THE OWNER CONDITIONED ON THE FULL AND FAITHFUL PERFORMANCE OF THE CONTRACT KNOW ALL MEN BY THESE PRESENTS: that (Here insert name and address or legal title of Contractor) as Principal, hereinafter called Principal, and, (Here insert the legal title and address of Surety) as Surety, hereinafter called Surety, are held and firmly bound unto (Name and address or legal title of Owner) as Obligee, hereinafter called Owner, for the use and benefit of claimants as hereinbelow defined, in the amount of (Here insert a sum equal to at least one-half of the contract price) for the payment whereof Principal and Surety bind themselves, their heirs, executors, administrators, suc- cessors and assigns, jointly and severally, firmly by these presents. Dollars ($ ), WHEREAS, Principal has by written agreement dated 19 , entered into a contract with Owner for in accordance with drawings and specifications prepared by (Here insert full name, title and address) which contract is by reference made a part hereof, and is hereinafter referred to as the Contract. PERFORMANCE/LABOR-MATERIAL BOND FOUR PAGES AIA DOC. AS11 SEPT. 1963 ED. PAGE 8 NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION iS such that, if Principal shall promptly make payment to all claimants as hereinafter defined, for all labor and material used or reasonably required for use in the performance of the Contract, then this obligation shall be void; otherwise it shall remain in full force and effect, subject, however, to the following conditions: 1. A claimant is defined as one having a direct con- tract with the Principal or with a subcontractor of the Principal for labor, material, or both, used or reason- ably required for use in the performance of the contract, labor and material being construed to include that part of water, gas, power, light, heat, oil, gasoline, telephone service or rental of equipment directly applicable to the Contract. 2. The above named Principal and Surety hereby jointly and severally agree with the Owner that every claimant as herein defined, who has not been paid in full before the expiration of a period of ninety (90) days after the date on which the last of such claimant's work or labor was done or performed, or materials were furnished by such claimant, may sue on this bond for the use of such claimant, prosecute the suit to final judgment for such sum or sums as may be justly due claimant, and have execution thereon. The Owner shall not be liable for the payment of any costs or expenses of any such suit. 3. No suit or action shall be commenced hereunder by any claimant: a) Unless claimant, other than one having a direct contract with the Principal, shall have given written notice to any two of the following: The Principal, the Owner, or the Surety above named, within ninety (90) days after such claimant did or performed the last of the work or labor, or furnished the last of the materials for which said claim is made, stating with substantial Signed and sealed this IN THE PRESENCE OF: { accuracy the amount claimed and the name of the party to whom the materials were furnished, or for whom the work or labor was done or performed. Such notice shall be served by mailing the same by registered mail or certified mail, postage prepaid, in an envelope ad- dressed to the Principal, Owner or Surety, at any place where an office is regularly maintained for the trans- action of business, or served in any manner in which legal process may be served in the state in which the aforesaid project is located, save that such service need not be made by a public officer. b) After the expiration of one (1) year following the date on which Principal ceased work on said Contract, it being understood, however, that if any limitation em- bodied in this bond is prohibited by any law controlling the construction hereof such limitation shall be deemed to be amended so as to be equal to the minimum period of limitation permitted by such law. c) Other than in a state court of competent jurisdiction in and for the county or other political subdivision of the state in which the project, or any part thereof, is situated, or in the United States District Court for the district in which the project, or any part thereof, is situated, and not elsewhere. 4. The amount of this bond shall be reduced by and to the extent of any payment or payments made in good faith hereunder, inclusive of the payment by Surety of mechanics' liens which may be filed of record against said improvement, whether or not claim for the amount of such lien be presented under and against this bond. day of A.D. 19 (Principal) (Seal) (Title) (Surety) (Seal) (Title) PERFORMANCE/LABOR-MATERIAL BOND FOUR PAGES AlA DOC. AS11 SEPT. 1963 ED. PAGE 4 7t UNDERElIn: Or g. . FD arc- U M 0* t .e. PROO € K.J g _ —.....�.,.....m ae..,e. 0 TANGS PROPRT a"V C ASfl≥ TC F:c.RFO M 7 COTRAI CONTRACIot SAW,`. 6: *RD OF.__Co..m 'E ati<u . n „ r a& 79A7 . E s v^ _ ;` e Cz m o a, 0 Cop - � "' 47 r i . _- z 3i -J is ae ND .', a .t 4 E. S 97^2 A±w :A vi COUNT, +';r ,BW✓c, FSreCZN .a C(j e,�ip AD 2T 3= VPZC 0 r f C w'f l 74.Y, !NDIC7Z0 AR -. QCTEDr e ._,tea..."SI A' Z... ZY tl s,. C. C 0RA CO COUNT v OF *AV FORGONG WS OF A. COORr..DO E $ ax4'i `' '1C. k V 4 u'. r ✓ , » ,. —77 -.;p e- CRTF* TAT C.00¶44$5.!, HE SP r, F>i [ -I"a Sz `w F "CAT ON r Ri_ Esrey �I? TAX R* SEN: *A '. 0 :3 o f C O P A .. .,fl T s{ SPFCFCD'`ea. 5 411'... MOT "r.., it R 5 _1 g .R.e' REASON OF "e61:n ,i ,AG rS, t��,. 1:5 ;ar SCCALL1C - . A '`°tiA 3(6 .$ 7 ARTtC7 .'4., fi�Co:.re }.r e,-. Fs ._ as SOE' cR .. . ,K nS^?4 �.. ;�, SC O 5 Any:;55S nEsk a Ow: OR SSUPk„_ ,.. flJR 1s.;, SCf E- ': G@( VARUc Ni...,b OF ., Vert 5i;Neg V4Ne APPROIED 304 'C+s TUE SPECE9 FORASH, 3'1 TZ C-CoN: Si.nC.:5O OR PPROSA5 t) 7 FO.L0iyiNG S a;r; n7 A t3+4 oRLcnmAkt "PARTICULAR CAR S'r MG ';S L NO OR 4, AS SUCK SHALL RC ADA0 P ROp-•,•e 'O• 'iHAS s R'AH %5 H"A`LO,. p Nk.'os' '~i`'A TOR wv i?.= ARE ? S OF - N : E X S — SK (H `i' u. OR $ CONTRACAz 0 ?R ?T ffiAP3Ain5 or AK `' 70 THS to. _Ps 7 rPUSSO TO ANT AART OF TSAC z v'40 RSTNOCy r Ps4C�... C ...,. OR � n .:. 'v� rP .. C; c io(°yr na aeb �5;"?"_. n u' : a.57 SR _ ES n ESS OUS5HO SOLLOW.1 Sz Dey,r AHO o _ ai $i k LL SC THE DIRECT R5 iA,..`$'F .., r CflMT2 .CTOR ANO ALL COSTS ARa 4�i64 R THS 4? `_ .. ,.. 3Yd r$ ecl3dt (, SHALL 4..'^ 9tt'4, r. n' � 7Th!S CONTRA C. P i„ 0"ER : _ REQUREO RUSTT ., TONTRO STRUCTURAL AROAS SAHA T 'OR 70 VHF, kR.._".Mw TAL AV C. ACE TO NO7 +.v.,. ... iC":"FaR STRMSTI. 0 AFEARANC 4. RCN xCI 6. WASaZ 7H CONTR.),CT ASS rS2C^ i 9 :T s ... L, .: w ., FROK •"rh< Cp u.2ty _r,,.ls a iB .' €awr jr T C: e€N7 or ":=R 5 S —'r R `v° fi'." , u'F s., SO' E JURG A! r. ,�aa r ( `7. No CCr aCfr 1 r S r;r RK POva D FRC44 K -, s IL � IU R1 �: 4 r' F TS ARCI`N"ti at , T S SAL P S5 a S '' c� ry ..1w,u y.e G �j tr$U .an> HR9ERa*g T RE,ROVD l Ln 9?£)FkPTCN BE PJVD VSON .._ STORED ON T `I S7 WNZRL IA SHALL SHAILL iEXZP;; fi '` P i 7ME AP.'R79A!. OF TIE CW_ 7ERALS TO CAVIOR eoiFoz AS FOAL GRADS1;R ._ C A 30 SkCrLL PR' : DF.. 30A^ Ru r O r'e'Yx YS ;i Nc; P CT S9:... AND R5rALL DRORN 3, RD:3)tRR £?t C__ t 'a 0C s v5i r d 1 ..,. C_.'. C '7C„ 3v)NU OTA- T&u "S F:.RT +ti ti Trt4 PROP ETC. ♦z AROR Ra aA N D R 5O4RDs A3 5 ';RO AND P + rt d G AC or SA@fl .. e'1A'T'S OR Rs'SO RMASL. U' MADE TO TC >RC: fF .. S7 fn ,`, 3a 'r'g' _. -- FLOOR C nPR .v. b"X *yi` ;OS•S SHALL xe�m e�, -�..8 � r a TO �-. � "R `z R` - $�a "~. C �, � e' y r t3 F AL !!:, C ,S R3 -� S 7Rua i N AL Or . aR 7ORMS AND SURY DC SNa 5In'RO WALL! W L i_ er PERMITTED WKScsr r, T 7 ?O"S POR w iOO7N fl E F au"gf. 6 k e °a S •�+ F e CJ9 s$ �.' e e„} d `ii "y9 '.. w,,� �"� ti_�z J. {� nr§ r, �'T USED TO Fi....k 00 PReP v PE R M T 7 D T O s . e',' na $8 ix OR F; t, R .. i•A R9 a i� e, �v a u a>g ' -. T g a) R S n^det.4 E'w S r1G F001,..^e :.4 MUST EC C. ar t L N TCCiR - OF SUCH F'On ist G'S AND .3' Si7 Ls o! L R—yfHEM E :i s✓'},T Yc°3 "3 HAS 5:.N CARRED TO THE ASS G ED ELqEVAT ON A QUAD: N SOLS £NG NEER #CC `'TAZLE Sd ?+ OWNER AND YRCM '.C`? tNSPZCT Ttst OPC^vi EXCAVATON AND SHALL P R,7iVd TE THE a4^v R : 'CT b kTH MN TTEs CONSrT.w.3."T ftO{y THAT THE S -,A tSN acorM1 Rre"k, .-w P oY. aMy" '�'.� IS $,r 3'i��,r uC PROPERLYr ACTUAL RATER ., EWmOst,RR "'Fp.» R ' _,0 3U:PpoRT r HC A s.OWAN4 'S n Tod 0r'1 G R AS J.LSRCdd R9 c CLADED N CONTRATORIS ' ' UL. S SHALL ,$:_ r, i— RsC':5 Or r, 1:1''„ :e '., .G R ALL S F`r U t 4 c 'AR ARP,; ,. S T O w!« TEE THAT OT N «.c or 07 47R;AtSL » FRO w ar a c ,: sALk » a a e wzT*e a:»wa aoas WORK DAM* ^ ~` a «: m:R e ...W. wc•C4De- g *,oeno'or TO:>eaG AT w caa« r» »» ``\\/\1...0 , ,. A, ,r , w,. _«m:.<.,.»ex »..,. en w« SORE w=,:. »rmw,c w..,//,:/w \/,co\ \ *s: S E » o<: y0 RESTS •077^ <v\o:« -,: v n . < \\/ /}^ ~ ��° � - .� © w.. „ _ »;z y » a m.mv »�-/� s..,.a. � WORK his s. 383 O-'` r?. ,. CONTRACTOR SHAL s F'LF.r'3PiJBR A€,.;L LAaOR. MA"' ₹'CR. AL ftNG SERA; i ES NECESSAR5' FaR THE COMPLETION OF A. CONCRETE' WORK; ACb SHO °9t'? ON ERA: GRAW; NGSs HR: N Sf*EC 3F I LO OR BOTH, {„ VOLLOWS FORMS FOR CONCRETE r a F OoT dd? Gs�y AND FOUNDATION WALLS. �y CONCRETE. i NS AL LA 1• 4ON OF !TENS EMBEDDED V N iRSST .LiLrAT 3:x°4 OF ALL FRAMNG, BLOCKING, SLEEVES, IH— SERTS;; A.44COOR . ETC. . AS FUFN e S iED BY OTHER TRADES. PLAT ORO s 5DE.WALS AND "= .AB. ON GR,kO v 9 $ _ _ { RR.?NFORC;wNT 6Nv`b.DO srG WELDED 'VRE MESRy. (G) pEXPANS 40 JOINTS. !ROT ALL SASE PLATES WITH "EMBCOR t.Rt:fa .(k) AL OTr ER 40R4 NECESSARY OR REASO.NAE Y iI c. ID Or,.iat. TO 1S PAR7. s e 20 PORTLAND P ?AE.N- ." P'�RtTLAND csmtuT CONFORM 't.O TM 3TA±nDAZD SPEC I F NC T SOH FOR PORTLAND CEMENT1° n� � g ►� = .- � O TYPE t., LATEST ?3k'~ JON). 3. WATERER- "' f ; E VSCO IN M ;,:NG CONCRETE SHALL BE CLE4N AND FREE FROM DEkLETER§OtES AFiOUNTS or ACRD, &.LKAL9ES, OR ORGANIC MATERIALS AND SHA'Ly, SE i7OT.ABL s iio ',OrCRETE AGGREGATES --CONCRETE •.kGGREGATES SHWA:_ CONFORM RM '70 THE tIENTA7 i E SPEC I�' IOATIOR5 FOR CONCRETE AGGREGATES" (A.S..T c.5 C`339 LATEST EDIT ION) 4 l 6 s CONTRACTOR S ALL pnov ciC ro HE ARCH$ TECt A CEaR iF CAI 0.F TaiE ASOVE CONFORMANCE FOR THE ?GG% GATE FROM AN APPROVED i NDEP"sy^DE% r a q. e : MG ABO RATOR2Y„ THE NAXN 4t M S9 ZE or THE AGGRGATE SHALL BE NOT LARGER THAN ONE' t rFTH OF TOE N tROWES3 DRMENS Ot BETWEEN .rOMS OF THE MEMBER FOR WN-iCs- TH COe,R r DS 'rO SE utED, NOR &RGER TAN V4 or HE M3N44'P' CLEAR S?'.Cj4G3 BETWEEW ≥* HEOROING BARS. 5" STORAGE OF MIAI R ALS--CEMENT AND AGGREGATES SMALL BE STORED N SUON A MANNER AS ?'O e 4ENT DETaR'80'3?..! TNON OR IN'a'*°.CuS fl$8O' f ORE. GIRT MA M7TER. Ae ?(fr�'.'�LR AL 'iH C HAS DETERIORATED O WH:CH AAS.BECO DAMAGED S.w,E".i_k )T CIE USCO FOR KCRETE AND SHALL S'y R+E4C4ED zRO;, ^'NE S"',: gd; c A[ E'•. aT;.T 5 VP o'e' ea F. PROVD0 t e r t'=' u24"s!E "'4 i; tl'a WELDAD STSZL R.505 PERFORCftD0 U0SA N55LL S5 ,N A "M E eeS d. °.k rb _ e _+ ? OF A— S ! •'drt`t r- �U. 'z`ti7 $ ,..� <+"� f _.-.. �i9 aC„ ^ND LOCAFCS &S S.,C3 K OD 5 cR9W:NG. , r&a 4r'.,WRLAD r k:' 555A OM5 FALL RCSA &DS NIST TOCTAARt SHOP E .ti Cti, r. -TDS ' .fl CONTRACTOR ORX5L S U' U :4 C TO 77 37, 5a ]"s`??•flr 1S'63 ,., IC C)aa'CG RC.?.1-1NCI E +7 ,.NSSM10 S, ORS S5A 0" ., 6_ C S C N ti RFNANS 0CC&IL5 OF &LL R '.,. N C O N s C M e tf w " IL 1. !; C X f . II Nrr G SrN a_IL N.: 'IN ti ,0 ,Na ., r. .A "KARCAL 07 5C MO Nr FRAC74SF COS sa Dt'A..,�+vr C. .. n ��S a �idC ,, ... . .fN!Fa '`.hCA s�r 8. SHALL NAT5 a. N b MOM %C> OCHER CON5RETt NAALL P S e r;. T 2Y� 0.C S, M&SH.RG, S „'RU';".T y=.d DE ,-, CRETE ,.S e!J.5'S . li OA 3000 ... 0f €+&o-? : SFG &ND CON" COM— R7QUI,REMFN75 FOR fi'.ENFOR5E0 &75S7 NC W r a)CI 9 (MACS .,." 7oF£k S'—PNOV DC ALL FORMS R:a_`1 RICC, FOR CCC Pa ,CR C%CCU:.I ON OF ALL CONORECS WORK ALL Cool 4 5 AND ro DDA ONS SHALL 8E w'QEi".'s"'Co„ FOR55 S,nM_L CONFORM 70 CHIC SCA5 SHAREp LWES &ND D 7MCP!S ONS OFF CCC M._',uLCZS Jt5 C&LACR FOR ON a^, 'r PLANS MC SHAT. G!C SU a,a na r !CC", FS 'ROM SSARFATC CC .: CS uN'N 15'UC tF .C, ,f' O PREZC' LOSNA% 5'F GRRO^.i, CW3 M0R11C' FORMS SHALL F:.'; TROPERTT SRACL3 OR 710 FOSC7A7R 50 &S CO MAIDTA S1 P05!51Q1 &NO Su&P1C FORM TC 5 :.0343 55! 5 FOOD . ti eT 6._ °t CONCRETE EO.C.ATADVIS FOR THE „G Me2('? NvscIo.0 or E. OR `„a`.'; id.... C0CREIL S,,. i4r CLEm. Nr ,z ALL wr RNS,, V_ .:d -itON T C TO BE F4LED H.. '. 0 HCP,r 4ET0000UALE t;' IIC:d% .?Et.°OS KER 70 fEEOW r..'. .! : OF 4i Nn Tear C:4 aR.' ERE .2.',.LI 07 B CEEANE0 OT tE the. FROPORT, :SAS ,e E.EGTE TO E!MEWT SU H AS 70 R0,fl 2: ., e , K700 r rH FORM .3 V ET0CS° OF P "C K ! XC' S.S. FR F TO ...0 .. T E,L*FR OE WORT TON 5" SAE TORS M&`i. S .._EL Sut. TMC; FEw AND tOR=;. R ,is : ! NOT SEGRe7r,“TE 0R CONCRETE eE zn_`..? AS M -C RL iA: i ,�'<,T E u.2pr 7. TE F NA POSTON 70 °fiC°a ',;a5 e�, .c ''£O,N '. ';7 Rr r,sD`„ -SG OP F O'flt.va CONCRC`. IflAE « _ - ? L%SaL T (ONEAMA WI aD Sx " O R 3; k +Q P ', €f ,. SEEL HOP S . f E i, tG aE of R'CvE SH,ar O DROPPEDrR •3 4W ES'a .1NO nEE?V7 R MM." aHZ TOPS 01 CE'a't S d 2J' 9`: BROU THE TRUE AHD ".c3C UP OTkEci KATE9 &t.S CONE:RER"dL,,. a. s,.A C'; AEHZ0 w ,% RE 35° XCCRE WH.r R' XV U . "t „c,R, TONS az ;s :t. T; 70 NSURD£: kGAINST ','a -=,.t y c "oc a: `s't`;SiYF - .�•;.�et �,,.r 'r ''d%_ g'ft !:aR AP'R0'€b. :, or iI=_ a di L'ri ARCH Ia •!!OSTAN E, AS: w CT0.R. 5 SEA ,. Ft APR..: E0 e ME A.R°;s. `-'P CRS "HOHNS RROTEDICO CRON 7DENFTURk iR:EPS FOR F TERoDO 0T a4".,' N CHETZ SHALL w'RFT N3, 4 ` . ` ne ': ,v, tw ._ t C . 5; . 4 t O D R ST ?F FORCLO AWA,T rRONr, TkS, SJH. r _'s e, �K ✓fu° ,,,+ i. `. t"f, C ICPL_,i'!'° W114 STRAiG 1 EDGES A3#'0 STEEL TROWEE iO SvRz'h5 RUt l.Ay CN FFORM ,:aD :R ,' �. �; TROWEL .s, 'cP OR n..,T.' FORM FRO S^DOWLTS c+....s.r,. 3, tis cr. WITH . 5'.Don r SURFACE .. PR / vC `.)O',.'s S445 JOHT FOR .. 4.. X .... OR ::ON_ k,• CO ICRET. Pr'• 1®ik :NO--AH T ORCRSTE W1I CU iS NO ¶OR"i r«'_., s SHORN TKE ?LANE O^s.. vt;,.a a.'r@ t4 ASO&' 3 0a''T ON ,..°.C.4wCN7 OR LtUUt OR H A OEFSOTMT xi > ;t :.' k_ SHALL HE CONSCRED AS 6? O "d' Cr R F: 'i:°' u NT2f OFT IHESSx?F'C t F t"CATN ONS FRO SHALL 0' N''. ?'Aw '„'* FROM THE TiO0 ":F T`. 4 CONTRACTOR RT HNS rApt 4ve RNLESS THSS ARCN EC GRANTS FERMp EES 011 TO, •PATCifl TA DECCFCTliE AR,A,., I4Y uf'rµ ,RAL^_L IC SONE IN ACCORDANCE RiTN TE APCH T e74$ i ?M$TGtLCTIO S ₹`SERN,9sN'ON TO PA`JCM ART SOCS!.. F.R i. SALL L E"Z HOT CON3s "-r'ER O A NIL L b° :R OF THE ACCHr7 CT'S R O C TO RtgORE COMPLETE REROVAL OF THE DE r'ae TIME W'ORR Sr' THE PATO ?UG E,O:RS NOT, gN '94S Or ;N«Oh„ „AT rSRACTOR b" RESTORE THE QCIALAND R PREARA1;i;E or S4"Rr,ACr „ • L5,. C004Ps R:}4vi0$& ."6 OTHER T9 a.''S .sTHISs CONTRACTOR S TC. p4O°;'r ALL OTHER CONTRACTORS SUFF CN RD"?:",MCE OF PLAtiNG CP'ZRAT OFS ₹O *L Os THEM TO ,.;LA..,r, ITEMS OT 4t.IR WORN TAT ARE TO RE <.UFn' DDED 'N THE CONCRETE. THS FAL* 4N _VOlt CONDU7p PPPkNG RNS, ETC. H'0wEVRRr THIS CONTRACTOR SHALL SET ALL ITEMS SVCD2 AS OLOf,YP.RG, FRAMES, SLREVES, ANCHOR BOLTS, HARDWARE, DFAHi3., IL TC.• AS MAT St F%RN �iSHPtD TO e°.I1 BT O '11R TRAVCS- WHO MC v 3;L_,?O S„+i.CrERN ST THE 10 05 LEFT 'H YH CONCRC E AROUND P'USCRTS et 'H S CONTRACTOR OR rOaS— LOCAAT ION Cr OF OTHER TRA,0415: ;PLET EOE4 OF THE '4OR.a' MADE gU 1N 5 _ . U i '7ACR 5 R ,.y t_, s it k;1 r, 7STS $EEA SE Y., T O E 5]C;..4 R ) .AN TAN-_ Rs .: HOR CPR FNt LAT A.. i 'S% S, THAN FOUR NA7M 7,9,7A 1i.git`..k7 K1'N s .e'TO .. IRE S",:FD=4i ANA OF TAST SMALL O, Cam` 'r `'s. BUT ! DAY i'37. EE MADE AND. REPORTED ID T9li AFICA9 ISE7 AS :' W' 9ND n *:."J C' £i `t' ENE :J `J u:.? STRENGTH Q..:- THE EONCR MUSK n.:: RE , l e c:D FOR 45 _ 'd'S ESC OP;s `BRKAA 9Nt , ALL SASES WHERE Ic F svR&se STRtNSTO OF 7MS C . N TRS FOR fSACH A SALON IRA -,_ aRCD $7MENGTO THE .,'COTM'COT SY:K'LL ERE R d u, ` . FO fi Qu f.'.'. _c OF THE SU K !D SHALL ESY', SHAUL g UI ARCW1 Yzc <, '.,.s `.'' F9 SNIP `r SHALL Dr-. A77. FEL GI AR NDEPSNOEF7 C ._ I. r•r: ,. , RE SUES TESTS 5 v,IA AE `N,F RACTOR SMALL HAT FOR N lL SPH ?A8c S ', FS'QLFES 74E OWNER, `R ISES ✓^:.0 _R _IDNS. REMOVED FROM TAS S!!'(!t 44oRR:• ALL SURPLUS MATKR'9AL N CONTRACTOR SNAAL ANS SEREST nC'KS WARRANT 1212 r „ GENERAL CONTRACTOR 84999DL NNE H4RESS DOES .xr,PKw,s.A&— ' T T AT .N 9:. *vs. t+. gi ns.UfKO SJNOCR Sr(. S FART MALL O,m ERSE FROM Et — FS... TS 6`' MATER./.,LS ANN .tCOR,a. kS P iF9El A ?UR TOO, OF ONE FROM THE. NAIE NE F 'a ' ERT `9 A `CC AS ASOYE PA' ItS FURTHER .1,u RFE i'9A.P 7SE7 MULL; A7 "N iE'IIR OWN P NSs , RIE,PA_IR AND REPLACE ALL SU'C'H DEFTEC M1 YU WORK, AND ALL OYMER WORK DAMAGED THCREST, WHICH BECOMES D'Ei ECT9WP DUR9 G INC TERM OF THE GUARAN —WKRR 2TT 1v IS GOARANTE—WARRAMPT NO -SS NOT 1;K _Y 70 DEFECTS rAQ'LcU S7 INS FK L&IR. _4 OF `oft WORK OF OIHSRS "sT SUCH DE— FECTS 1+R , HAPOSSRAZ TO DSI:KCT 't THE SUMS OF 7HIE EEXAPH H.a_ ON OF `rR r'„ WOR4 OF T5t OLC'v EZR5. fl&CLS t' DrATL NA7tRA F a ,, C[, OF A,,. " :a£aERCARl7 7HON"O 50 1W OW OWtD rNLYEML TFt TPIHL,LS H S s 6 W ,. C,. AN LTfatI,ON 0 4 0• R S MTR N S _, "=is0 r;_ CLEAN S.N i' r'€A 'L.E FROM AUTTKPOgg MA — —100k5 ^u5' YI'LE FY S'.'S. « CONFORM Try n p tC -» )1. ° n 'f: it F r LIED _ fl, Sh`A,c, CONFORM TO 7L E "S7ANDAR'C b... CA;7OKS Or $P t. A0S T f , 4 SN '_CDf' ON". 60 d4L —S m 7oR 95% TENS 9 `^, S'ffd E'S2OTH or OTTAWA SAMO, iY SMALL NOT ^ON' 4 ..,E- tLR SUS y, B57AIsv.S PI e:Efl 'LUG 5"tiE FO4IL0eH Na P ERCe.F4a6'aGES:• ;?-5 OF ' COAL ,9,1,ED L, G,R'„ 7m.s s j 0. ` CLAY U UMrS« Ac PY 3 OF SkAr:.Lr, Ati. 00 r,`!; p GRANS OR LAK c'[aR,`f I'TS 0V FJ'x "_`� F s4 -;i F ,n:!S^ R4 r. x,C,,LU,,.tn ,ALL MORTARN 3.1c BE KgGHT '4"4'"F'.zi a 4 7 1Y,. NO4ENs ,Y MORTAR SHALL BE USC? hR':vV't} ;eti 4 _ 3.'",V ~45;, y,N1/:.E£5 41,5 SKt "4 44P7 FOR" .h Sn CZKILT FART 7'?• 5 fins SAND. rRI;a?:!!xP 5R'u"R F1+O, n,. 07 Y MASONRY et,,'4 ,, ', 8 'C R8€ ING LATEST O 1. O 1:' L. CALAABAMPA, SAC 8' ISCAPPEU BA WADC 110 A E COMMON 5PrEK -S. ,.L cfroTO 90 WGERKVER ... Q F o R i4 i FO.TON", BTOCU. BUELL sr,. °_a" ARK OT ER 4O;, S AS S'CUNN ABO RIFTS iRE:O is ITS4. FACK cft'O S5r7E Kf) cGer; x7 tin $a:oRT R. ,^'7 NTS. iEY S?'f.,LAE, .RUE- tTto5O OM .',CFaFRk.°E $7A.'AGGREGATES f'xi sr. THOROUGHLY VrBPATBE TO INSURE 1n £ECWa VEINS 7ENTSRED SOCK O UNFORM COLOR, I r} BAUD ,, iD FORMS AND STEAM CURED, BLOCK VCR • .41:.1'' c'.aJ 7E,W Ic COR.:R`; EfousE SHALt SE CO ERETE. FOWWOAT fON b OC 9- ',MO AEA tGP4s 0; AAA R O THOUBABATA ErTA AND 1 ATG7 DRS ", U B Mr BA fI0Fj C SF W0 WALL RArN C°§'+ Sn(=A97'^ ,E:._.t,, NAV_S S-;iF.,_ u RJEn 4FORCZO STK W E'L OTS 'a"k RE JO6RT RF SR ORS_B N7 WNRCH SKALA 91 tfR O_WA. EEt° AS MADE Fay DAR-O-W,L PROOSCys t(C,.. Or Sect ^:USE,, N0?. RE NFORCE:MEi4T SKALA BE TkB PROPER I' DTri FOR Tar, M₹A;. i',L_ ARP SW,CLL BB PA6'D CORkT6NU,OUS EVERT 6." VERTrCALLT. L. S ENG 8R C w BEFORE U A, 1 t: G rO C.OLO Ww6Tf91ER> Do S1O7 LAY N 7FRFEFATURE {ETON F'REtl's P±G ONLESS SUCH „'EAT:NG or MA:..T.R k,:._ S r$ POSEPEO or AND TKS APPROVAL Or THE ARCHr7ECT ?S OSSA4a; t; GAL BRJCK A AMU a R SOST OR PEOTERLT Sc,CC t sD ANt?. '4111 OVE. a-'L't!.MSa COORSES SEA _.0 SF SKATE EXCBCO SilZP ,- SE .PROT p7;IO TO BED M r ; n:. A, fCAND FLOW7 WIN ST7F V IS a B .. a W'I JAN dN[A PROR A PR :.OV OF 7"; Al TO V lEW sNi Li'_ R. TORO e C1. NtCSSR1 CL ,Nk:ONO, *IT' ARCUTT SKAU. O. 0 TC .G L IL'F S. YS aC"0 • „ EAR , is ?..POSID O K €d. G:-. S7 SL Jo TAP Ri.MD. K S G , i S Jo FTC FRAfflUG VARRNT T.F. C V N :. cT o, yPOD mC ` G.• R .wt, F . ? LA .,9. 1dAS SNAIL 6E A+y,Q kg AN V 00 OED SO 7A7 t4TURK •3r, ZOIA0 $' Zf. SZ GINAP T.A&:a - S A5 , . €'^ 4 3. ZOO _ N a ZA0OZ ZNRS, 4040A tkti 9C r44 mOCNOr-.≤. rTii'•P9a eRAC , "rF'OZ. .. ,`t1_.!d°i� G 70 AO .. . _. C 4 7` s'Y „.i. tSr4 NE4EK. 4-4 - S^'M16t Zw;FisST EZ.ATOK Cif'' . ti `,. Ca f: Ct:'Fs iA •; IL ':!k -+.s'. ARw0 P.'3G Pd'.,CS C'' T?E MNUN 3k R' Ft S AssorAT?ot .:::DnR 5'i:.Q$z R£,.. S vs„-- .4 AR f,5 FRQOOC wD:., °'�'._._,.......x' ,, TRA4S7 CONDUC1 0A 14Z V7A07.",Z, SA AROAZO7r0 SO KCPA ON, ,C. £c.. MSA74,7, de . 54,-L 407 ..:0[+. I C PtROPEP. PANELS " Q c c 0 °EAR 40i SLALL I':.. RE li 'tfT+8 OANUEACCOES N &AOCORUAACk AS CO T ''= P ON a 0 T k% ,? a m...,5,, n.� , "r i'�. �. 4 l ₹Z ₹ ? F d ,.eAPPROYED F ,Q U L n NS7A.Lu3A 4N °-ep,'F. S ACC0Er,td "SC $,MK A+' VSCCTCPC S 444 ICC SilgucT ONS Oe 7RAMit I'G '" .. ..`F,au, G8;₹! •d i .-5 ., RE ER,EC7E<O $R,4, '' 3C C. W!J-,a LEVELS AND 0U.th 0NSi t d47RAR AL re ?OAMEEC0 ARO ADEQUATELY 0RACEDn rKn SZKS AND sn;.CC ;dsa OF JO CS.VYS ARO rR..MkVfs '>3 aNS F.R-" s r R ,_,s a k .f �.� e� '� / G N v E- O R �: 1. '� J (`s e_ RA FC RI ARE ef.JJ�ia Wf s'� Cb J,S� Fu t'q 83-o" MAN, SEE' CS SROK OR P &R, Trt'FS C© R S)E# SKALL NO ALL SHE :RdrMFC r. g:. ,�Sm De.C`u^. h7.:,;1, ETC., F: 4xs ,O 'C lPLG A PASSRCE Sk 'r ES, ..GF'E"4cr„S. ..i.„„ ,,i.. 'MEMBERS SKALA SE SUE LESS .C z o - 50SNOOK? ON ! .�i :,i: ASS . : r : R' v... L� F f, yv i i? S C. S �` �, S T 1 & .' E TRUt TO L W5r PkCLO A 60 4t, 1'Y tTFON9 4 OTHER F CATi3O S FO its ≥3't ,tm • DER TS COVZRA7. A6.0 Fk r. 'F.. 4?ti AL - °'0 `?¢�a t StOti .Ns7M,r. sR n 7 .O`3'.-.`,'_ ,7' • 5 7 5 !4 1 7 a G7lO tO Y S° Y ... IC'V Eqr 44 l4 0 flr... k k 4ORK NOT SH028N EA6 1m PC,4Z Ps@Ts st Sr c . 3ONS o Tr C,3'ti_.c $F ICAT ONS 6 NeLf N6a MOP! I70 COM sG'n O PAT ONS 077053, i°n R$ l'CAD7LS OIR 70... c By 755:. a... ,; c.' COP az o, >aw,wwa w w wMXGE:0 1. MC w« ow\ C7' «or« ?. « w x as:c«waa><* rOF oc e=ves = a a OF hl n2.i'RC S H SEE' 9 ;:Y;'.'S REp CV: '1m 7 ,uASok or M Nis S `d"o• t D WORR^S:A S9 L:3=� R4nMASNVGS AND S R" ., k x",- Ok e ,.OR O= THE 12CS"t72R+:i'.B 1'3 "u;.' PPD7M CONSVRCTION U? :'r;, at't¢R6i "kd^ V0?, .0 Qs {A: 'i`Sw Jzk. 4, ^K .. R .. :i' P'i.. ti:r 7K ar.� �a"' r' r �, ' Y `rt 4a: ✓: le A, i?' � Ry. M tr,' it.... w , MI a' .$ 4 S3RR C'r'R7 R SPaC;f" ea t.'xix+.S PAINT SHALL lit p ., THOROUGH 6mn se SURFS DADM COLI;TOH” TO 7V7 SIAMDARD v7 ✓!. rAFID w:U a BOLTS AND m w - w: s • : &S0M +v w «, . �� w>� ease o a me «ww:aeo<>w,a »w« NSTRuI w: w, AND AL OT ZR PAM rw; »w: O„« HI w: V ZC TS OF" W477 FROM >WY. PraGco«: aw aaw,< <o>« wP& P0D OR ,w: m=a ,a RA - O ar . :w z >. : � « , « >S ©° w »> TO =cwlawmwwz�«. a,aw:ww:awa» e=aw, . e cr!l = mz a c 7W . : S z ®a ® w<v , , « r« »u w = : w WORK am « » a ., » . C c w e<z =0 w «c :z e :: rr w::c » a»< S RC w,: a. . . WORK ,>w:aaw;, e„ move aTo :wra ,e )cam as 9aoGC;A,: «a a as 6w, kg`a<:... w»w <: m fl xTRF., / w:\ a SPCCFKU m a,r: fC « ! cr ««v .7gCc z dap e:<.F,RR w AO TEE 50ILDIS&S APART ARO W, . ..' i v'. Pa COOTS C0At 7F r+<` 20 OR 2O2A. cATIPARCS P G B RC 7c•CO:_.7. Pr a ¢ [7/k. s AN 0.7 N € 5 '," t" A ACEITAATASTC OT "TEA SRAITA SE .,..F,67.". T AAA DRA, STANS( AMP POP( GR MAT 79 UPON COPPATA WORK $SACC BC CEA ROOFING Y+ e"h;. S44(' PROTESTED DAMAGE BY OOPa, SC Acc TFAREE 77O 775 C0k77At T.9 r RIS PROTECTION AS m/"' R C Rc D,. C yF:��L `r �_, c•ss C=$ �P � r 8., Q AR.&MNT WARR,AN, /777; i 1 .a .. O1 sr.;: a.„ AND % RSD,, 0OCS GO. F,7 TEE THAT A. !'L= MORN I- .SC1 s70 F NO7R S IS PART PULL BE ' e I€ CTS OF MATEP w.... suo 'N FOR$ A 1SH7 FOR A. PER 100 or OW7 SP.t CCPTIFCATC, /4 OS 317717 AND THE A OT9. WADTJIES €ORTSCR AGREE TRAI'. PEW ROOFN6.z SV Lic IF" 07/,7.47^ TEED (SOY SONDES) FOR /7 TOTAL PE49a0 OF TWENTY (20 rterten 1R.Fi OWNER SMALL. RE PROVIDED 'lf , 7 ROCS WI 'I TTCM aSA9AN T EE SEFIOC FPAL PAYMENT 1H7IL PC DARED S VOPS_, Fz` F}:[,rveq 2„ R U `Fits rttD t !O `.c1 .y D Co i�.. C. RY iO .. NV 55C7 OPNF S . @v,.. _. SAA Y _.. .::_D 0' r. o-7ERv s , NO AT ! `n! t� y ' .... ,rt r.."4' ALi.R'i fi 6I,, Ft 7Nfi54 :-. ..E.. r. OY,` .. PEA NFOPf 4NG °. ' £.A5P0 ':Lt Ft .0 hF,5F,R Sri AC 0€ AS; 4AkVS. . F G RFORCEWZN75 5 A.. P_Y ix S; N T L¢,50 FA;N r} PK>AR F -k Kra. _•`C. ,':"r.. AA NOT h C S5 1r7 CAN I,2 S70 S F.EL, Kfl;;1.5 zOF F At_C 1R,,, Or MkRD9JI,RZ S;A B n, .nom ,a,P: . $ [%UR4hS FC TO eE FRAME cw`≤.eG ORJ�i2.�CT 2�. ti. C9 rIgOF. . S<1tCTVR R eR 4" I . &h_ "r ..... ;7 ..'E<°k P ROV F RN. SU fi VO! R9 MEN4S FOR ei Rr `r 'L ?r_ er !40`:,. i ,SUI !'£0 '5S k II FG AN S TO C+. DONAT . 6re i0T.-,y r3c* =Y-,rA3C,.1 ON OF SURa`wC'S k' ,A ROixikR e DOOR ,.`44'. A''*r TO FC PUKCMD `"O REEYE A B f'R Sit -'-.P=' Fc SEA. 7•I&P WAP r . FRAMES S7iA_k. AS RytPik tiRED Y vwflL COND1TONSp fJ l-4 S7,`FiP'L i f0 t I T7 ANCNOS ALL b R#MCS gt''_+ a ;L 7.; ie 9,7 $ 5d�ALL s!IC Ch,..EAIIy0 FR pF FP06A SC°1r", RUST: OR ROUGH SPOTS, Sys SfA&LL SrrC€:. x. ORE X0P COAT OF RUST S;1H"6e!7 VA PRIMER f5iE,7v R9i 4,3 ':"34 '717I .'`l^_.+„ 'i00 LII' OR iS ti143S10 5 lrAO PA R kG 5 AL 93I ^0FI'£ E COViRAC7OR, r lECTOR • S .0,:;!'., OY r Bu ;_.t r r w ScRrN AS CS / sits.. O. 20 7tCRAiNCF7 AR:. k4NrkC3GRC.,i BY of AN is Sr'4 + r'.. " ,i E ii d' K . ._ . ii :,2 S, __ APAO . FA E. .- W 5:. c - 6 is I f. CrCPEC7VA FCCONIN 7 Uri.;t WARRANT AND AA NA B, M ., 0. .. i'4 _..,. 9r5 F: IAC 4010 TEE SAVE WANT — 'tom' O" ,. F i W EN „„Tr RAC OR CAFEA &AO F!FRCrr'Y DCVO ri:rR R1' TAD fWOCO SE FA DK— r lids OF MATERIALS FNK i:'OOAK,;NSA0H' OP. !f'ROM „6SF DAIK OF THE FINAL AOR70FICATCq B S E A BO "4' !C P 5A, Fk r ! rC 'i COMER FGR7K AKAN 7HE �,.,� •... 4. & 'N `` B: '£ B. M, O w x k — PCNSICo REPAIR FBA) REPLACE ALL OWEN DWKOCTIAt ^t45RK `*RP ,,.,t OTAKR WORM R.M1k G.t `I HWl..'C ..k `.?�..1 0 "f dIA AffECNIff- A Na eft �n Hx. Of TMr GUAR'ANY? w&RR5:a.e A,. ". S ,;;q._':AR.NlI "A—l;'aRRANTI 00ES OT.. LErrcTS CAVEFS SC ,SK F.m B_US:=:. OF TH WORK O5= O EE S, If SUCK DE— FECTS N!-&: POS„ .. . 70 DETECT A7 Tikt.F or TB! EXs,.S`",[N€.T !'.ON OF 7ME WORE OF' TIAF O`aF!' :Sz* ., AWE R FDA D PROD 9 AF A. F OD TWA. ORAN qA4 µ ryry A ADD :`a2RRS„.O S ifUP , hADADWA ARE, *DE EP IU 7AAD Pi.R. F_ ,.i ti ' OF F '.N t � g s ,a° oCta n rs F 4b Cs 'r, .2�C+ , 9 i. .,. WOOD a9Q'� UtdGa. �. �' a ke i,v CP34TRM..C, TOR 1:,'WE i ° S 'cti a 0D (:If PReV1 DA 0' A c hAA Gyps ! o0ARq WALLS A A ` F ° . ti WORA CTEMS S ANN PR QA IPA. AAA, EC fi'tl ' PRO F:[ t `� 1 a�9 :.. C,. CADA �R wfl A CS!+P. a W RA NG 5F CL41NI -R r taAR`il$.Gt4Si« r'RAOES, ° s.9'x 'ch ':?Gp PATCH MG OF r'D RA00R— nRCn FOP P SDDT 'F'aAE WORD ETC A5 ne7A D OR 0RV l0Aw r RCDU [RDD, PROA fCli 4R na AAL WOOD GG1NrJoa°➢ vppS Dr'iA1TA Ra�: P[°p1%fC?F /rI�AfB '� N,r LV iii �� tl � 1_ � a=.� a.5fi '�arrEfiS�6aC �a.WORK.. sR{�.rd i-� r RYG9- i e s t.. t ° FFs OR 03D ,OU,A if RADIIRED if `y PROe I J4_. .AD +S .a,!5D CARPR(RV PAT Na AS sQV Pj,A ORKR OR FOR 76.t: 1R vs,G :VCT « ESE .d, rse Rr!v gazoR i TE. or ASIKE KCK SOLE LT N SANER SECTOSS OSS OFT UN Falk RSES OF T; e` P ROTiC rFp AND OSPI MATCRB, L SKATE NOE Sa Dr.v. FOR TE. FR -Pr:' , :tFgI OA THE „ars:&. END S EtEKIVES., S k .O :,. # AS .. .., ;'Sea _A, RESZRESS 70 SKATE CONEE COAKSK TO TSE raR .p 0r,} v:43 screR Rao 5 S,EASCI €4g r,w --CtiSSE TUPDS .s uu?:.M. e KE N SSASOMED NS K bo GLUE AND PASTNqNGSsA4tL GLUE 134 CAO NCY WORK SKA L BE or BEST QLAL4JS NOT AKAA GtU'F, -r EEHS APS,'. PERMiSSABLE " PRt,.cE E2 CONCEALED dt Bk P� �: €8 O-�"+•. �. �; oti ne, Nto �. ; a LUMBER BER. MATER B?'!C +�c w.zUr^,AL FrN'aSe^.$ Sot STOCK ,g�y-91WASSS .;4,tt .'itKG a/8, WALT Pft tF � UG CASEWORK r4ASAKIOSK DOORS AND GOATEE ." `H Ue`£'LEr4( OR -:' FA TCN g:HiO EDGES Re (Teti KATCAUNG mnED EDGES RHA C =`. ,. r A t .. C 8c WOOD C U OANC E WA ,F `£ . SHALL : c• • 0r.. a aF'FA. Woo FHA -y1C SANDED BE MADE , E (FUEL E HTEC R WEDS '000 s SHELL 0 :�„ t`AOPt EPENRVQ SPADE,K7KPt; 0 nRCf An 5SCHEUALCQ.!a, p.:. ACEURED a _x rou4,� n Ea P.es":,5 A FDGCS v ,�. , F '� �F � . N r Ec e r , -- Cs R' sf HARD— WOOD. SE"Cr F!rE 0aS FOR VFCCHAF ..a ^" r,,;, .. CONSdDER FD A S S r ,t: reR EDEN.OFEETON OF itaE. F itN I;Se3 FAFES OF »OC'nE SHALL RE LAREEEFFN 0 rRagES S .AND FL RE QADE . AHD KS',%:, ! r IN n..CCOR DANKE e s'31A's k4t 5g a.Rs -J.c LS- CO"m' "-a -T.O rVA. R°5TALK. EOMPZTELT ALF WARE AS SChrEeU'LE6., D0 ALL CUTo;NG .FOR F1N]EN r;AtRDWARE F4Z ORC cWISRgWG 9S `�C�"�'„ 4D_ JUST ALL 4fARD43ARE }0 0 u R4 TE $WOOTHL `tTHOOT RA'„LTI GRG. PporEE i ALL HARDWARE AF'T P NSLLii. TiONo Drr UVER KEYS FOR ALL LOCKS TAGGED ANO PROPE=RLY wDENTED. ALL F'F.CESF,u..RY Ci,PiKET N RDWARF S$A9:e SC PROVIDE© BY Tails COMPACTOR, SEE OP&WJPGS., Oro MtlALWORh--ALL WI'FGWORK 6NCLers@NG RnA€ r'o&R:D D E;TCo x�rte+ 9 O ALL OTHER WORK RE.C.SOPA? Y fONSar-WEr AS A•rct WO,PK $ ALi RA S NOT MORE TNAN 6% MO S7KRE COc TKN, A L HJLLWORK Si Al nC BACK PRIMED R1; "flHC. i�w C. JFl fitAY h O R C E≥u Fs !':_ tl NSTALLATJON0 ALF 1NYAROR ERFN ASH H ;ACRE SNd!' .BE DAFT AND FRECTE€) "sN A 7ROROOSUFT NORLM ,o MD AND S ,_LLE;D M,NNE=RR.. `QUA'. CABINET WORK° « Tv57V a:«. 'AMR D /e w<t :: !<c a,a a team« a awa>z: e a:r AIR aw c c«! «< zz «r% ar:s:aa *«,wawzat rr a o ar P. w m:9 BOARD <o a AL LS °DT t .55 VZ rm uwcm$wTr:; /\ ;m:v wr ww mwz wmw, Gw G w isR D AS P'df x. ,-AC ; U^ n FY FE ' AY` —pH PANELS SMM,'i-,L F' , FOR EXPOSED GE D„ Z STWM.,APE ,. "' ? t D 'p "r' R ' Ni: "✓' D w , Ce T ..`:, ett Gwrr. W° i• C S, Y N L A S CR rr E S„ b ;RJLLES AND DIFFERS EP.AL 4_ &E PROMEO Al;n ENSTA:LLE !Y - MECHhN EAL,, COciaRAC1 -OF!? L9fis'T A XTtH LS V'6 -.,L BE PRO1 Crf STALLED BY TWE r,::lC".ETE tiC,; t ONTP.ACTOR, 3. Acousr c I L'_'—Pili3Y[4_ ,AND INSTALL "ARMSTRONG" [2"NI2"Y.j" CLASSuC OU.st£'„'ONTOF O'2 APPROVED EQUAL APPLIED SY APPROVED M CMAN- ICAL OR ADDESITV DLETEDO FCR SPECIFIC {'ONDITti£rA'to ALL TI L.E. JOINT 7.J4F:3 HALa. $ Sot;AIS T AND TRUE, WORT SHALL t STARTED AT TEE CER7ED Or F:FCF! ROOM OR ?ABEL& BORDER TILL, SBC,;.fLL BE NOT LESS THAN0 W.DE'. AND SALL BE NEATLY SCRIBED dO A3 t:,Cl;';l VERTICAL SUR€'ACES, 0+o TiRANS.TOP--WNEPE SHOWN OH THt DRAWINGS SK€rALA BE I" TMICK `%ETk1 CEMENT ASBESTOS FACING AS MANUFACTURED SY JOHNS—MANFILLE COPP OR APRROVED EQUAL. F RNIS SO TIE GLASS AND GLAZING CONTRACTOR FOR INSTALLATION, i5s CALK NG'" EXEERaOkR CAIK!1NG SHALL CONSf,ST OF CLEANNG ULY 4WD CALK 9NG ALL. JO t4T<Sc BETWEEN MASONRY AND DOOR, t4WDOW,, AND (WET FRAMES AND f ASONRE CP CON,^e'._.7E OR S?FFL, CAL `,k JONAS BETsSL N SUB —FRAMES AND O0wk NO WINDOW FRAWE5, A C'OM LETELy VEATWER ms U4STALLATU}N OF AAWG '.'S NE7EMDED AND .ax K NG>, NECESSAR? TO INSURE SUmh 0 Fr,. 'i.Mll•N sraLI, r' 3r DONE, ;i^4CD t^t FG4 FHG APsPL S ?0 WORK DONE L1 C R TS cO 'TRACT OWL, { SAlqS .R 007 R tiTA D UTVflN A 6,ND MAS MR. ON 'CORK DOR.'. s O R Y4 'i CONS C . .cRR. WYH.CA, N.L. MeT c RDEN CR sC% OR ricw wig rui <rir "^'F _URCS_.n ', F', tom; 4,.dE ZERO ANN w5.v'- €,sO{"F ZE'R'O 7 _N1 L e. FPF t 3 ^..e :_g 7 0 7:4'^ " 7SR v I` 75 3 f WOULD STnC rM `' 7. G,eSOE!R .. L. LIL „ COLOR .x Z✓' UC AD x,J!IC.t r A. - 57 4C GUM N.'" 5NA,.._, 8YT .. E. .A3 "f. C TPe', �' m i>n y, G' v. _'J Pa - _.. e3 pa Us �'. ;sa ! 6, x : Sr FOR 'U 4 UNDR F6 sc` N t i r WANWAAF OF MPMVACTURCR OF C0M F0D4`,. - JOfiNTS HATER 5;--,r RaMO E.D<., DE cI ..,PASS rW4E1Pd77_. 0 7 "?A S>?O„ __ _ .4 4k; g ,A" EAN O Q :. r F?. S.y.� T , �_...___.. �'� �.._.. 4Aµ. ,..mm ° _ .- 5 OR . `2 u'; , L °L BC _, R f :, I R TRUE, ON A00 FDAC:4'v cwimfif 7H7: DSF,A {NGS RHS e. GN SHALL BE B kAD NAHLED 0WSOFAR AS a;€erce'BLEz AND SURFACE NN';r,.S. SHALL BE SET, WORK SHALL Fie .a( L,C t. MAILED TO STUDS, NA, L. !'.?,";p Bi4.OOKS, GROUNDS, CsNI'7,, 7C.RRiNC, AAA4L"l 'N.N STRFPSD ETC, Wcurtr x°30 -RS- SMALL SE TRAMMED- -i 7o "-D- TO- 41.- SENVO4LT. WATT v B@ND9NG4 HARDWARE FOR ALL DOORS SKATE BA E TTEB SO DOORS '!,a€-, CLOSE V OTHOUTi roR flRG OR RATIL:i NGu HARDWARE CUTS SRAL, DA. CFUA AND NEAT, G G1° GUARAUTIY'WAPe .'WI CP,!S CONTRACTOR SMALL AMP SEREST '?Ors WARRANT AUD THE GENERAL CONTRACTOR SHALL AND HEREBY DOES GUARAN- TEE THAT ALL WORK ENCC�=TED UNDER TS.rS PART wljt,L BE 7 DE- FECTS OF M - ERI-AEA A-cfl WORKMANSITY-.h-R. FOR A. nR-“<JO- OF ON -E k h F x'-EA11- FROM THE DATE OF 7UU4 CLRTi!F c.A,TU. THE ABOVE PART -rCAT THEY 'LLy AT °u&'SR OWN EX- PENSE, REFA2F' ABU REPLACE ALA SUCH DEFFCTOVE WORK,, AND A@_. OTHER. WORK DAMAGED sF'.ERLBT WHiCHi BECOMES CEAE TBNE DURBRO THE TERM OF THE GUARANTt—WARRAN1Tc mH"S WUAF:=i.NTY+r.AREANTT MOLL 3O° APFY TG DEFECTS CAUSED O' P?..17731 v. WO!07 OTHERS AF SUCH (DEFECTS WERE EIWEOSS',;-G-LC O- DC` -C7•• ; "'F+'-. .s.r O' .F P= *^!sE. :.PE.a LEAK- OF THE AO -RA- RAF 0THER5<.. SEC t cGee — PART i0 LATiNG AND PLASTERO4G WORs M• LItKD;: D_W.'i E WORK:.€)I u [ Fili EP a: ma : THIS ., R SHALL tiCLUDC IN FURi JS%4NO O• Jcj a Y,. F a.�;.Se EOt,1LPYde.N , TF3AEvS'PC7A— EON. AED LABOR rOP PrRrORM: NG ALL :OF3 !N CONNECTION W!TH IFC COMPLE 7 E NSTAL.L y JON OF a,t.T,H H.r, AND PLASTER Stu AND FOP LL N ;CESSAR'° a,,`'eT RdtoO or EK S7iNO WORN 2. Ge 3ERA4. -_Wfr R.z tx?-f- "FiE tai'..... ; b NA TO i' e.fi.. ! MY, is ; ?7u 5r c t IEAT dO*!S AND THE VT.A R OF AOOPTOK S S ROT S€ OV ,, THE C RF'E#iT S7$IDARD SHALL AtPPLe LL SCAFFOLDING R :C ESr=Aft" iN TOE x ::c rI ON OF T' P..F: r O4 ':E:r WORK SALL BE PROVOED Dl TF; IS. C13r,,."_: rOR;. �] ks � ^wO MA F (irR Dr t.S— 5"'7E'4A�. :-.AA Uf eSG t:b A4Oft3V MESH 304 PONDS PR SCPAPE \t¢rSii:"k "' ¢r ReO4}tREC; TO E;SW;wAt USG 6"x48".1c3/8" PERFORATED ROCKLATH PLASTER RA5C. A.CC ESSOAi ES - METAL ACC E5SOR i S SV•C:? AS "GOPHER I TE't, C E > : EAR'S, CIC., SFAL.L BE FORMED OLVAM i ZED S' E .I . NO7 t_ i'SS 'FOAN a6 GAUGE AS NANuF. CTtoRED LWY USG OR INLAID StE'.:.rt_. PRODUCTS Co.. Cit.xNIE;..Ss aSEDtED, SHALL BE 3ik" COL_O RO(..[.ED W Tr REST iiS; #4 . F pAl G PSiim PASTCT — USG "RED —TOP GYPSUM CEKEIT PLASTER' OR ArPRO ED EQUtk . ti Ot+?PL't 4 NG W 8 TV A.S, ! ,:M. STIDARD SEA' EC S F i(AT 4ONS D' S 38ii`vA t :OM KE.ENE'tS e: l+R£hf (ron EgTEPOR rt?x'.°S rt,N USG, "QuIcK TRGWLAf(3". BASE COAT PLASTER — S'S:A;. L BE USG "RED —TOP CEMEP 1 PLASTER". WA1ER• — SHALL SE CLEAN, FRESH AND SLR v'TABLt FOR Pc7ESTIC", wOSVS MP FOR 4. G£.!ke ?gTa.L--JS CAS I SG READS AT ALL 1& TERSCC T iO 1S OF F~E.. S` WITF6 DISS;Mft.AR ww`RFAC£,S AND 1°;.ONNERsYE". EXPANDED CORNZR nExp, SASE SCRs% OS, ET., AT CORNERS, SASE, ETC. fk TAL SCRvEDS RE+'D CVii,S IG 9N O. P ECE WHERE STOCK LENGTHS W ! rL F ,RW T. MITER CO^Ft+oR JO K7S, r 4 CtOSS.LY AND ERECT TAU i0 LINE 1D PL°=CMS. 5. PflASl'ERI7G--k CO4.D {9G_mRC* ?Hk_ 5ENPh RA1'Y'RE OF TeE 3£'YtLOns GS n4a:toL DC MA?NTA;;t'rD iN A trW9cOk?s RP:.NC . ABOVE 55F. rO3t .*Et' ftoEOLBAY£. AHLA AND l U ' �i fiSTE ,. ilf €�R . ,. s .. AYE f U ,QU J E;CA TO MAYCS S $ � v ?ACATrR,i .S�, Z' S,. p; > .. S?: :'', %^a TL` td"£ 6'Ufi .`a`, E0 ! r'H r0.t" ,` NS PATCH AU. AR.AS 10 SHfCd TS% ORLGNHL t'AASTFR HAS DEH REMOACD ORDER TO CARRY 0;'i R3;MOOrE ^rG WORP..,, EVERY EFFORT SHILL Sx MA.f:= TO MATCH • "'I ANT FI:ST3NS WORK r,N EvKRY RSFF:C7 AT T E CO1PLk 7 s0% O THE JOi3 V4iS CONTRACTOR SFF'ALp 1Es THE 'op,rA%'T Or Tt1' APCY81"SC.T, SURVEY' THE V,`.N e'1RH RF_€ZDrLED AREA AND SGKALA DO SUCH P0'NT;NG Mn) PATC iMG TO ,. AAS rri c1 D IS . BY INC ARCNSTCC" FOR A COMPAFTz ..aOr2, .70 BASH COAT --THE u .'t&ttsCAL NI NFR SHALL DE CAF N400 OF AA SCT OR HARDENED MATERAL K. FORC MATRISAS FOR .A NEW Oh CN A l .G`�%C3 :q EACH BATCH SXA."tx SE r3 X..O S€AA.5 TtAYe TERAL THAT HAS FM -AAA 5FT Se4A.L'_ HOT HE R T-. G- ARE0 OR USD. amt !P,t MO Y£# RE MA7CAUA THAN CAN aF USED N ONE HOVR, POT ZKC rAROX?^./.ATr .AMOUNT or k€ RC— QU sR4rUD 6.49 NH ea S Ito SN, WS1AE TSK MAHR R �s t4a c,o4�r c. �4vct � i. Cr) A?PRO A ; M - 4 3 HNAH T HC AMOUNT O AGGREGAIE t$:EQL R.AD, ADD N.AL 0E TH r >c`.,.R Gva C!£Y R. A: jr,F* or TF`.E A.GGRFG T,. WA TO PROPER ,AP AY E:.t NS 5 .- . ..0O NG ATER !r t ACF`.S„a.P,. AND APPLY sSr, s, :. GOOD BOND ON 71.t.'.: 4!' R: TO FORM CONS 'qr.'-.f '....AMING AND D P L A. 5 T U? NG kCY TO BF!MG Tit'P:. R7ER. OL T TO uPO OD : STRAIGHTENED 10 j TRUE SL'RFAC . WITH ROD AHD 90`+ Y'a t x c A crI i 'i. fi. S'3 0 d.. . K � �) L u Hip ; READ � D 1 � 0 �. W� h •, a Li F,The iNESR iS£:COF?ty, COT, 8. CORG ORA`d iOR OF SPEC a F 4 Cs. T SONS BY RE ERE,: CE --ALL PREF'.4.R.AT ONr 4ATER € i S ANO 3NS TALL oT ION or ALL STUCCO AND N R tOR RLASTCR SHALL BE IN ?.i.L.Ct;H,??P„£;E W:TH TOR APPLICABLE e'OR'GO iS (AS THEY PERTAIN TO THE CDt+ D P T i0N) OF TTNE PRINTED SFts:C J F t Ci T IONS OF TWE U H TED STATES GYPSUM COMPANY AND THE P AST'ERFf.?GS MANU L FOR A<P°iYi 4G PORTLAND CEMENT STtccO wND PLASER i.S PUBgSHtD S'T THE PORT's.P;NSsCEMENT ASSM. 9. € NIS4i GOAT --F NiSP E$ x,.COAT �' f t p �� ., . ?� '� A, g F Y E' .+.`..� �OVER Av A�. HE T 4 ei< t �•> 1� ORfa LEVEL MROUGNED GYR5SVm SAC COT. rE.NPSH COAT SHALL 3E SER, T€h'w:D EN THOROUGHLY AND aMMEPIA E,"r DOUBLED BI CfK TO FLL OUT TO % TRUE, F_Vf N SURFACE. TH EP'KMis:SS !>4kLLL BE 06"1 TO 4,810. ROWEL FN I HEWzSH L'., RE 5Si.#'h E? TROWELED DURING SET TO F.=RO'! H DC A SMOOTH, ONSE SORF4i .E OR DCORw.';• rONE FREE OF IRREGU's..C-RiTES AND D.'_-Et4d3Si? S. IO. CoePP'THON--A7 ``fur, t:O4PLET4O. OF 'fl -.!E F4N<St PLASTER WORK, CLEAN .ALL PLASTER FROM BEADS, SCR DSo METAL BASE' AND METAL TRtir, LEN S NG ALL §rORIC READY FOR CORA u !std BY OTHERS. REMOVE &L . VLAS T ER RUBB SH FROM THE SUL D NG.S,, EA I NG FLOORS BROOM CLEAN. REMOVE EXCESS MATERkAL FROM THE JOB STES. REMOVE ALL SCAFFOLDING, TOOLS AND O H'ER EO0 I PMENT FROM THE BU LD I NGS AND JOB SITES° i e GL?AR,a,NT' —WARRANTY--'T H o S CC:N T RCsC TOR SMALL &ND HEREBY DOES WARRANT AND TiP°' Ga N RAL CONTRACTOR DOES GUARANTEE THAT ALL WORK XECUTER U DER YPx,S PART WILL BE FREE FROM DEFECTS OF MATER.ALS " MO 'iOR4:P4#NS R FOR A PER;OD OF ONE (4 ) YEAR FROM THE DATE OF FPNAL CRTPF&CATS. THE ABOVE PART 4 E.S UR 4ER AGREE THAT THEY %.FILL, AT THEIR OWN EX— FeNS , • PAdR AND REPLACE ALL SUCH TEFECTEVE WORN, AND ALL OTHER WORK DAMAGED THEREBY, WHICH BECOMES DE7'CTlVE DURttt94a THE TERM OF THE GUARANTY —WARRANTY. THUS GUARANTY —WARRANTY WILL NO7 PAL .Y TO DEFECTS CAUSED BY THE F4eLURE or WORK OF OTHERS, tF Such DEFECTS WERE IMPOSE9BLC TO € E TECT AT THE 3 .g,E OF TMC FxAM N AT SON or 7E OTHER.WORKS. a. a , C I r'0 i_ ti DRE SHUNS 05 I :'. 9 I Au. GEAR PASPONSISqc °THUS WORE RECCE 5 E'S WIRE fa,. BE TOE BLUE R RGS: _ HA EARLE N,E , OF° 'SQUAT,. ESL -IRISH AEA LAeOF AND ".� GLASS AND a5., I.. $Ci ISSFR PLATE ER “AUAL, OBSCURE GLASS RSC ' ASH REALE €?L AS rHvrJ"i +'^v TEE DRAWINGS. MgRRORS SHALL . s o's se a "' LAS eaf `o il'E MrS—.GOpg2 ,f3 P4 ,4° KNOWN AS L.A m POL SUED .S so'. {�xk C5 h "'a m4 �i s MIRRORS �I SAKE SHALE BE 16"X20". MIRRORS SMALL SE EQUIPPED MIEN CHROME FLEECE wur:uFtlFRG EDGES AND METAL n4 DACES. Ti Ga AOcp SHALT Dm BY APPROVER a P e~ A 4,. [. 'J MEANS AND MORT AE s Luiac PROVIDE AND INSTALL MitIROR OVER SACS .E WHERE CggRE<_ g,�_4s ONE ob (;m LAVATORY. AYOR'Y. GLAZING COMPDNr sH ai FOR GEARS — SHALL 'r ` py x "�hu`M9Gfs � RASTER ur.' hNG COMPOUND FOR PAFT&,. OR WOOD. OZPFROgNI ON LOCAT iOF5S, 5S MAN°4e 5aC FRrD Be THE !RF:MCO {�'a.'[ANUPAS U VPG ':OMPAVE. DEEPfEeiT (WIRED FOR USE ED 9N A SAFE LOCATION AS O0RKC ED, MATCRY L SHALL MOT DE UNPACKED UNT A 4 APP,. :° STOP , m9 H - DINER '.'ski„ FRAMES AS PSIAIEED, S: ACTURE° BS KEHHELF S}A L BF D`.L,0'CERER WM; NS Re — KU THE A .`. T R M W D E f. B E 4i 1. i .� x1'.,': ir> ACESSORES SHALL SE &S t;¢ A N I) PRINTER era U O F0,4 _. IR- `ND rP- rROe. SCc R'VETS> AND C "H!,ER 41- U M H M € c „ `iii:, 3 , C S SflL OR CT ?f.° HE; I1y.. ti r' DOORS , k. S: „_on S ;NOAR1 FLOOR CL0S ,..,u SKkt £':: ., 1'a3E. °H.?'aRDd''At 4 fr t' Sfi C tr ar,-.Yq,; NEz ti:l iC.ES SHA P: HV MATERA C:(1, fsc c SC r WRrRE 0 BE r:LC Ix.T' CaNT MASONRY 4DN'S"ERCC dCa.Y �. F �^'. r.Fra v;I ,,, F E C T d O% ? e t f. *K S. NR :INN ,4A TV P 75S SmAY,v_. 'AIs..L r.o !! N PRr N, s Oo?,S_. HNGS, GO SE Sr, N•..€''mFx SQU'Rr..., •iL }I.-.'l,y ,"..ND ,:i` TNS,.R PROPER I E,4.A._. TON AND PLANN SAND' f7E':SrD PRO7R AL;1 ''W TM AL WORN, THEY SM P_ F3Y SkC'[YP' L.t Pi( :PEP AD R DY FOR OP'<RAT dO% R' 5PFCi' AL. H. JO H N`i'S its LHN P M TAL ANO 0 CALKED H N OR'LDF R "Q SECURE eA MA,'BPT NEATLY NO IRIflE0 AD'D EXCESS.-- P eTF`°?-9i ED a BI AFTER FRECT:Jr,Ms t9tS C'OP4'',?R CtOr 5551-'1. ADEQUATELY PROTECT Ac. CA POSED PORT VONS 07 TwtC DOORS,, FRAMES, AND OTHER ANDOg ZED KARTS FROM DAMAGE BHI GRIPDING AND POt, S5f'G MACF!i K'ES, iL „MEk „&°C !irt. CC.NEF°i OR OTHER fHARMFt?E. CDMPUIP?{DS,, AFTER kREC" EON A6tz':) GCAZr 9G SP:i;it'S ,CONkRtiA.CSOR PhALL C.HCE'Ct',:. AND RE— ADJUST AS REQUIRED All H EMS OF OPFRATHSC. K RDWA.RE OK.DOORS ,,.N-- S '.£kEFPf Ei HDER CF!S PART, TNS CONTRACTOR SAL.I PD r,F5P4,7eL roR REMOVAL Of PPO E"'; Z.. MA TER94' S ANt CLANNO OF Li.iHN6M, • AALUKhEALOM Sr R. "_ `4i F,,..,, ,. c? .,.lit' '.-! pN s. a.'C. F=• c, `4 N5 eROis. ELIe) H""PC "U__ St 4HI 0 CNHI OR fl'..,, i `''E., !'4o ARRAS1-a_. C EAN 1r S "„53F TS UEDfl TH S tqtkR5C7OR S5, .41 SR MCID IDSPO .S FOP Ds af.5 :S `iw PROS≤: ^t:. LhSI- OF 07R ,,2 EP_ft'C&yt1 Pck..ti€ttlrtL , AED >a c. EA y^, r i- C _ s r_ia S f AC GLASS HS OWN E A1e. CLnS IN — PERFECT CONT € R CONRAT a riAAASE RESDOS8LE FOR h°,_. r... FAUis, .�;. �" r �P' t# r � �i°,_- PY AC - . a Ad €2`[!......._!-JI,? t,3s. Ee ."t1C! KERESY Dea Wea.RRAN7 a,, ,ST;4RA J'OA RA7C.IOP >MA ?_ AND DA ES GUAR .¢ AE TAT WORK X.1050 UNDG fli!!iS rART WALL SA sonG WA1 ERPROO? "rya PROM ras - �' ', R' _ - .."; tj' F" MA.@�ATGRAS r'a ESt TP 'ni , 43. !4 e a h: Px 5 KCD F: RS s^. Cr ;7 OF ONE ) A�,. ~•-`i°„ ,7 'k.:. A5 OF ':'f;1 F' r Naf... G'`S.F •'r( THE ASOVA PANG VS rURTER An i.t THA4 7AEY. T THR — , PENSE, RCPABR ,r.s4FS REr A,CE Ao- S,Ur?., P €'5; €:e stk 1#ORK A„N€3 AA,.. S1 'R WORK D.AMrCG'IZD OCRFCi',r 17Y!'CN S CDFCES DICFECT9a': Elr ONG 'dNE 'irr°tw; oK:. THE GUARANTYAWAR€RAnY., TetR. IIS GUARs,,Tsa —iir2RBAl'ri. t4{1,!'._ NOT &RPi DEFECTS CAUSED SY TrAB ^tR7 OF WORV OF OTHERS vt: such wee"„t.C:.1S WERE 1FePOSS SLE T:0 DE7ECT Al TIME Or 3E EKAKHs4iTON OF THE 0,!rf`=.$#T: WORK, X0 FOP P Or:..._ 40 OS A 1" CE . ,, 'OR ZTPOS F7000 NOOD CC' 07KN PR 2 A ES Nd7KOV7 is O4! F Pt -0•• C Per,5 i9.: :0L.,!K PANTLG i)'r ha \U`^ C, 0. 4 131 �^'O K" ; f; r' U x '. iti c +.. ^ i )a. € FPA41.; r,C (K) NU. +. .kl" 0A'ORa b. 6 x R O! n:.i AND CPLN.V RF'F' 5KZDUi C OVIOUSL f OI R'S=, 2. WO F' i4 - C t ou EY " R o ?I ;_?' I e;' a €.: • OP COAS ON sr. R U 7 r I(f' ` ti. S, EU,p HP SdCP FLSM 01 d (PnSC1.t At'1tQU °a hti't dst d05t gC3 ilA. S U L O 4 $, a S r. F f,,. R 1 6+'- ii x: G $ SHOWN MK S e,. W a£ C R E 8 s r . P E C. i. t 9. 7 n' C .1 V S K F.P. S F,v CS1 OS5 SKik 11 Sp vRCL>✓DEO OR SKOP PANT PPY w I E ,§ q' S t. R n SHOP 00Th, K .'A f cOM5_ O he...f'. c h F+.. J!r.; AND `'. `keS O4. N &K KKR AK 'octa +'.' RCQU RZ$ f 1 TXS FART 1-01t) i 3 i!''.1 11 0 040 l O Y `I I'e. R$ 1.0417 Ct0Ai5 77h . 'k 5 t ,1 @k !-O li 744.) tP -Cr 5C4 SSIC 6 so"sor p03K SZFORT. ADEQUATELY NES AND SAFE LEAD U° AND C) JOB t tSED o -'T BRAND PAREPPM WANATATTSFER'.. NAME. .c.. a . ...7;„ ;. °„ �� z, f.. C""ie 1 EC FOR nt*E STi N ,"1 arc_ Or PAINT M ,fi.„. P 'rt`L.S EC I -+..z. Ss l,6! k.R, (f �`t _s':f ., GuN, s'Pr.a TORAAZ SPACE SPELL RE sue.. ., _, ,, .._� r_t .. �_� SHALL EA COVERED. EP TS PRESENT rpo rn 5vAL Or I'PE A .'-`n PO&LD P J 4 t f LATEST T OE 'GUM OF TOPPEN7liET. TAM., PR945R — tA.L .TW THXTIERCOR AD n„T`.R^4E? WO 7 :" C l 10 F9i,.VL. A. NATURAL ,1de''SVs SPACE KATE ONE COAT OF PR@.M4HG 'WOOD `SR1.n SHALL ._ L R'ACT ffOH. PRaRfNC COAT TOR WOOD EPAIS 6. STEM. S%1.ALL BR NgXCD kN P. .= PRO — ORTNO S HDACATEy ABOVE NOR 1 D ArffD 0i'f, (LA8NT. ALL FXPOSEI. DEW „>,R.',L WORK TO H Pd iT'r1O, EXTi E.RhOR AND efr.1"i.ERi!0R:, WHERE TrLyE SHOP COAT i', S NOT rc4 R%M5.!HG:f,• SHALL I3t_ RR NED 'sA T"t METALAC PAgDI PREPARED PAINTS Mfl VuRt iS3`r� -RLi. £P,;.}k`6S 9. FY 11 VARWfSMES AS MANUFACTURED DI PRATT & D-tRt'm Ii NC,, BFu?.CANfNY MOORS. PP©—MATt .PRTTSIWRGR, OR EQUALS, AS APPROVO fiT THR ARCHr ZCT„ THE rO.L R_Cda9 NG L E 11Lc Is :.WTI ear rL r' U.S 3a :4 to '107 ONLY. ANY SUR TJO6S MUST 33E APPROVED ST MPS <Rc: 1T _C a RFOR SHt.RJ k^k^TT L W AND REWORKED( MEW OR R[TH'OR ' r.`, N?. TF.L ARj COAT (SOX0C RED LEAD =rya.EN ((L w) c:. HOUSE PAfST 1LL I iL ENAMEL "'i t. ilSli iLO (GS:t Nf RSc 5y_ NEIAL DOORS, n' r R? v t .r PA N T s 2 1 R Or k 'fi 1� r:.:. a r?.. r n Y..`, r i' fi ., 7 '.. '+tws.n:_ ° ; Y. FS D O E OR O :..� S "38" +,'. ., � �,, 4 .: +, 41.E uz OR ReoFro W°0(C . •r NTeR i .)r 7R1i4 WOOD TRM (0 R t, V :i, i4 i* i R s COT )E ENAH4L UNDtHCOAT l►k A Y (. 4f 5 +le' R OP R. SF' T t_ .Y S r -F s 4 iz & C OT V t T R !R L i T E N ,y its" E L' 3.x o 5 OR Y..RNiS'? WOOD: EhsGSrtF.°Li tkw INO WOO 10 $ TC4$ RR Sf.K"'...' $7A+4 •.vF NEV AND PATtNED NU G RSUM COARO WALLS ',ARO . ?E- p(„; SCHtOULisD n _NAHE n OR Wit! SCHEDULED OF SOWN flp INT OAT S r.s u. C'OyS "i8" PA.:. Teo o '`y+:RFt` i $K COAT tNTERiOR TRdM PP;pau.R F`.OT VfTRAL TE ENAPC' UREREOt,T C&.1 6-T-R+f4�i. a � EIW44-t C -k O g a-REssmcLL - 2 COATS VAPEK PLAT WAs iNISN EX i ST iNG PLASTLRC4 A iD C COAT V.ra►PCx EL47 Writ,.WriLL F 4 N i Std! HOARD WALLS SHOWN "PA!t“" t " OR WHEN Sf Oi.w "k.' 4 OAT V 1 TR6G4.. 4 '& ENAPCk CIC_�:4S OR f•i_.kT NEAli OR REWORKED 4isTERIOR PC7A( EXCEPT Rz'•`,ii ST:C.R ? La. GP 1 ..LtSy COPV C'TOR COVERS, FICI NEW OR Ri:USE4 RC. s i S Tf RS: 1:!AL OR i"L E'S, CON-Vt1. Tt?R ETCCn I COAT ik)•ERIoR TRIM PFii I“R C t POT SHOP PcR i M CIp1�e� p� p ( q COX? ,7 i 1 RAL 5 E `'::Y i..1�: EE •-,rf* !E RCOi 4 t COT V 1 TRra1.; •F'E 4tdr;FCr:i, i CSS OR ERG4KE.L t•')7 SKOP FR P: Or O;c,.: °v i .k RAu c rC, .NAC t. z:4i (t a OR . ' (F'�� "' v' F k yy �y�e� A I `'9�`• G Aft* E JA IVG y�YA k�:" V i;IC kK i ... .: L+I� ! i 0 ST k i h.C1-= SAL:'. DE'•iy' . f a ..... CO:IPLE0. fi.: GCS k. WIT %I;.?k :.:S Igiu:tROC'� 3or OF SAt O(<:. 4'f. r`, INC. `"OP TH : P O V S D£J 3'c • . HEis S•cA Y Sw';_ WG or SURFACES TO RECEWE STAIN. 5. COLORS --COLOR Yrtfi'ALtG OLT STA MS SHALL B : AS 5 LFC'EVD BY C .u::' tTEL t. 4V7S :P. N NUF .CTUP.ER or PRODOE.T rS SELECTED F'".'•'O'r D, TOE APCe≤l E . SHALL SUPPLY zR4S CONTRACTOR WITH A COOP Sc"V OLtiLE NCITING ‘r.YL COLORS AI'n THEIR LOCATION 6. G N Sti L ^ -, S.• PINT Srya;P,.t,. HE k, `e L 15:.C* IN STR CT ACCOR Asi I: t t "H MM NUF1,.:C•3URar R c PRAM r'.s•? INd RC:'i'TiOi S PAtNI ON EP;P :SC' 5'L Sh L!. MATCH .DACf"≥•?ON BLOC*a JN. SS :7;RECT(;1' SY THE ARCHITECT. WhERk:. !=s:,{ TER i L ' S T { OF 7M I NAE ?, TIf A€s 11G i S TO B DONE 4% A COR— OANCE 1"1!1'• PR.Iw:i::D Di PEC,TORS OF cWx�.t UFACTVR¢:R .Q MO G SOL LNit SHALL SE AROVORT Ulu FEE' ,OE OR 4Sw.fl FOR ANT FOR'0 C IN CGRttii;CTON WITH fH PAINTWO. 70 WOqMANS' P'YFIORNM :iS S`€ aF SHALL ;KE Off" THE }1ERT BEST TM ROOt{OL,I a WITH ALL MATERIALS EVENLY SPREAP AN SMOCTkrLPOWED ON WITHOUT RUNS OR SAGGING OF TE IF:":- • ALL SAP WOO r AWO KNOTS SHALc RCw IVY;; A THIN COAT or Stti"r;.!-AC SEFORE PRIMING. A. INsiDE. AND OUTSIDE WOODWORK SHALL HAVE fax_ NAIL ?TOLES AND i►IPCRr—CC. T F+:''IIS PUTT4E0 O UP AFTER TOE FIRST COA 1 OF A I W a ALL PUTTY FOR WOOD WHERE !. NATURAL FINISH ISF 45 C'ALE` D rOR SHALL MATCH THE COLOR OF THE IFti F4 15k4ED WO000ORK. tF ANT cI-FRP<ES ARE NOT U PROPER COND 4 T tON FOR PAINT1NSp TAM; CONTRACTOR SHALL NOTIFY THE APCµ"i TE! SfORC 'ROCEEDI G ilOYe THE WORK; OTHERWISE Hta CONTRACTOR as ;LL SE• FEED RESPONSIBLE FOR ,I4V POOP WORK CAUSED rT :tllr3'ROPCR SURFGE:t, ALL NIAER/AL SMALL BE APPLaED 3N ACCORDANCE WITH T47 PROSPE 7I^IE MANU— rA,C.T& RF,RIS R ;S Oii VF.NtDAe IOI4S. i SCGR AC S TO • 4ICF6 PA#N1 IS TO SE .h3°'PL EO SI{ .L ST DRY AND cEAN N4 OUTSIDE PANTING SHALL ALL BC DONE IN Eh' PEME COLn, ROST , FEaGG, cR 0Ai P WEATHER. N£ P. 3NT'NG SHALL BE DONE IN Dust' ROOMS. @F REQUIRED S7 THE ARCHITECT, INC PA:NTEI SHALL SPRINKLE roops TO LAY THE DUST. PINTyNG GONE IN VIN1CR Ws'".ATifCR SHALL S DONE ONLY WHEN NHL T£; ?P'RA`I'VP:. S 50°F. OR OuL=='o AND ALL SCbRrACFS ±t,f.ISOLUT'ELy ORf. BEFORE loAfWT ^'t3 OR 4ARNI iS4ING .ALL SURFACES SHALL BE HROCFG4LT CLEANED OF ALL t? R1 a 1 L R GREASE, RUST, SCALE I'.t D O7sif i. = EIREGM N T Pe ANO ..,N.* O P 7K7 it I' Y' 'iR►TSH S.AI,.r.. BEw. REMOVED AS NECESSARY =RT SC.AE OL iiiING) MIS MO +A . PROVIDE ALL PRCv ER EXECUTION :S AND DROP 1y A, FDR L IN A,fl.. — F E 0 0 =�'•£.E tFROMftC:- DURING ifxM c0I TO•PR+O, PROTECT rooks RAGS M d FEA R rPHIL G, REMOVED A: r N,?' E r. P G N) zel O F• oils R A° 0' A k �, i. CONw {-.+. _. Eaf Ck 1A9kK r �. , O CI r rc� 9e ei rii AND UNDER `n.>- F<, r`f"' r. �, .'ws` SMALL 4C ALLOWED TO h£C`""6.id1P.) 74i% Pk.I N P�w F3 ice' % ' �� h •i£ E RCSPENSIVAE FOR 6�0 f TO aE WORi O7 t F rn £,C' €e. AND &i F C fETC CAUSE ' Cy e :- ft R` � d HRALL r, ' e € ('. - sG .r k .. _ DAMMED AND S'A BAR At GONTD. v s, 4 see.. ise ERE COMPCOMPLEVdON Cs.. CLx w SHALL CL k C t 0 ...Iq , Nt q3 WOODWORM, GLAD5, 1 A R5FC? PERFECT CCN .fC. 74E EIRE €�O _D!,N S AS FAR AS 4'S 0ORk ;S CONCERNED ka GUARA T WARR 114 CONTRACTOR SNAIL AND HEREBY DOES WARRANT ARO THE GENERAL CONTRACTOR DOES GUARANTEE THAT ALL WORt€ EXECUTED NADER 7M14 PART WILL.€' PREZ FROM DEFECTS OF MATERIALS AND MORRCMANSP R FOR A PERIOD OH ONE (I) tE,AR FROM TOE DATE or FINAL CFCRT IF.c;,.T7"c TYPE ADOVE PARE PS FDR NEE AGREE TRAY TKEY wELL AT Inc9k 0IEN EX- PENSE, f9a;PA4R AND REPLACE ALL SUCH oCrcT"yw WORN, AND ALL f1fa+7"f1 *MIRK DAMAGED THE5C CF WHCH PECONES DEFECTIVE DURING TH:A TERM OF THE GliARAWTT-WAF6;Ca NH7 Tits GUARANTY -WARRANTY DEFE C S CANSHO OE TH F ftf 6.±.C sNuc A,vcre TO � A 4_IURz. OF 5a'D e•<K OF OFYNEkSy IF SG`-CEN YCRr feC T'S WERE NHPOSS=9r_£: '0 DEEECT ATITHE TIRE OF EXO,MuN.`•TzcN car THE WORN OF OTHERSv HAPDAIA U ,lam _ n PR Y t'"r f6T ii v�tiG i O `5 TRACTOR ScL DE e k,� ... EPA GOV RNE0 SY AL 1 taREF CSE 1°Y . !TF pmRr_ ur 4'L� r :raec RO' E pF"�'E 9.i G.' ANDUD DRTAI�.S Or KARDWARE wi Y0 NpNl6FA iL$R U D..SEBIeS1'!a0 S�INC C . i ` 3N.'''' R. WHERE Er"f;EO'0Of{&Rd3ND SA't�PLE5 S''.a%, 'If r'UPR I EU rO fL f, F O'o r.D C:?':+. TES or AL APPL 4CAB� FE f R9�NF5 YO P°.?'E 'r h<;R psd1 'o - R A,RD*ARC AT Z&at JEST FOSS 4SLC +SE. `0 au. L !JOUR AND FRAME UP LE.R. 4. NOT B R 0 11rmE S OR s.EGL"�,�, � E 0t LOAF NN SC 1' ULE 9S INSERTED AS A C Ff, KRT y NECCS$ Rla.'f COMPr_CTF.e lU 8 DE: TO "C t EIA?"��'1 aF: E,c�.� ; e*r 7} BUT �. IS CONTRACTOR k 5HkLL BE RESF1NS3BLC FOR u1PPL v.U+G e.,LL NCSLSS°,R"Y FIN°SH HARDWARE YCR A COMPLETE RSTALLAI th WHERE FY6. PD?5RC 'L$ PEtnflRED bUT NOT , I vTED, 'n7 SH �'L. '! Br or s_I.NK QUALli'Ye OPEI*TiOR. AND TYPE AS SP C iF D rCY 5'l� LA =-f`S rn :AT 8CW7 9fHL r 0Lo'itusd. F RDV.8.EE SC-BEOULE S BASEE ;PON N!7NB''RS OF !4ANU— FACTURE.R RE.PRF5n.BTEO BY JICNNSON HAR!MURi ;i 9NC. HARDWARE 0e S'OVAL QUAL8TY ,AND OES"i'si 'K`up,Y DC rCEPTABLC 1.'i4t AJ CORLIA4 d13" l'ow! g, ≥. Dr A A.RErrCT t gyp.0 E g)E =8a' FhE R - „'E. 1'.E 0 SHACACYCFE ±, DOORS A PR BUTY$ EA AnAKwt HOUSE )4544 USJO C is S HARDWARE [E A W. 0.:�. STOP EA DoO S!..NCERS 2? Door 4 ' B05y . US0 GJ 64 DOORS L, M, NA 0 AND P - F::ci.8y TO NO!,`•`r PR BUTTS EA LOLKSET EA dTA it L S u o o 3 EA 0O O R S 7 E: N C E {' S EA rU OR STOP FOR P DOORS K AkO Q - EAC PAIR 3 PR BUTTS 2 EA Pus P: :aEs 2 EA PULL P'.'b ; '" F._`, s 2 EAR CLOSERS 2 EA WALL STOPS Dsz 114-4-4 y: [ pw pcv USk0 G 0505X US0 0,R k G? Bf3X. US0 BB11.01 DIU 632K US0 632K x 32 uslo 0 A033 H90 usK) SPRAYED G4 W8O5X US0 ALL NEW COURT HOUSE LOCc:.d S444 LL DE MK - I SET WASTER KEYS. SERV CES BUtL„DNG DOORS A APO a EC TO 2 Et MORTSE ` "sr."•3 #€tiFP FURNISH FOUR (4) 900 i 4/ 26ox629 t X978 3,/6 26DMK sB^_ ANC E OF AF DWA'.R , BY bOCR SUPPL ER i i 1. SR HARDWARE DOORS C, M? N, PR BL: ••, t t EA t.. O C K S E T _E b• ` ` 'l. -�' ' C i� I E h r O O R S1OP DOORS Do Eo Lo .1 PR 4UT S: ; EA Lo K s E -E EAU LATCVSEV EAC€o ER. 41' DOORS Da Ea DOOR P — EACH 70 HAVE 4 PR BUTTS EA! PUSH PATE EA PULL PLATE EA CLOSER EA KICK PLATTE EA WALL STOP toD ,•�} i HIP p' ckc!'_i TO HA“7L E'• a L? .9 DOORS G4, — kkON TO RAVE PR B nr s I EA Ear FL one STOP Df0 i) PLY US rO (34r CG J '6k,3x. USGRO WA — CR TO NAVE 664o D70P0 ' L °C LJS I G 00S PYUSCG O-43 PLG US[G 59RAYZD e', 6' X -4- E7364R) CPR 1 . 632c USED 632 n32 US26 !4073 R G ALUM 8x 6 GA US s G 2" GJ WB5X US26 2=18 DB7 4i01.A. Ci5EPD P=' USED G J FTWO 05g0 v LESS DOLOR 6 11DTH AL : e,sa< a„ t4,8t rt.iFt m PL" '0X2 W oc:$3 L m Mct Et0 Saar a7 S E�: ` ra. C — PAR' 04 RESLENT>.Y K :f �,f �. a CC T y. n os > �`"IJ ,{ r L L.?R.BOR IJ4 .} � 4`t E� .� E...�.."r.��' .�i, k'2 � L. v r F° :': �. � Ia .r: c, �' k .. �' WORK SHOWN i/PCP TV C.Ok�'. p;�"�F:TE k/�L Ri S 111'L pi r:N �Z "L FOR I s.LC^ M.VD SSE WORK AS Si'O Fiii' 0kr •Q �'�L i�RA F/ k ':'*wG . ON 7;iE SC I�'�. :eOUcF OF .� NT's, R I ORS 1;• k N- SOES OR HEFE!N SPCC.F iED, OP EOTgf AS FOLLOWS: 1R A. R"S'L,..E.NT TILE SOWN ON §R.A6:ifiiGS L.WHERE SOOiN OR SCHEDULED :,wCL?sO HEI S. $E: AS SCI'E.OU!~.Dr AMF. MET EDGING FOR k:BOYE B) At NAILING Of EX i S br I$G WOOD >Ft.OOR ENG AND f 6 S T. a.L ! DN OF UNDER!,-R,YMENY WHEPE SCE•:r.OLED. (C REMO Af: OF [ X 6 ST NE. FLOOR TIE IN PREQA9ATION rO?? Ni5W (D) CLEARNG or AL ..II,,r r; SuBm a 'S O: .idP'"LL' OF TWO S S Oi` #:.. i, MATE R P, r TO BC USE'$:_ (F ) ' GU RNI-WA°:l P .N! r AND Ali -e:, OTIflR WORK MCCESSRY OR Ri_v,5OSNABg. `it MC DeNT3:. TO Th HIS PART. G LOOP a 6 . i„OOR T4LE SHALL E f X,J .. 8 ARASTRON: E_ CEL?N STANDARD l'ITif CCr„O S ,S sELEcTD ,Bu T 4: /ciCOiTE.CT.. TtLt SHt,st SET aN STRICT ACCORDANCE #i7H MA.NUF'A.;riURER°S WRITTEN INS7tRVC7iONa # ND if S -C -DM -m WIDW'n CY$ ED -R- S11 C ? C A:P Pt, COAT :*N- * pp -Fro itAti FOR EQt A..v.: BASE WHERE AND AS S' OW I OR RCHEDUp ED SHALL B 4" AND 6" T"Oµ CI LIFETIME Vu'cavc is c S A S r-- ES- M Al NU r A r"to R -!k. D- ►e- -- a B i Ply's_. Rao_ !NC. COLORS SMALL OE AS .SECTD D5' THE ARCCFt 9TECT. F UBSCR BASF MAY Y BC USED UPON APPROVAL. or Ttt`s; ARCHITECT. r FLOORING SHALL BE LAID OVER EXiSTiNG AND NEW 'sl00D, AtCONaCRETE. AL.r. INSTALLATIONS AND MATERIALS Sf-a tL BE IN COmPr=.ci.E. ACC0RDARCE W014 LATEST EDITION OF ARMSTRONG. 4STALLA d iON PEC F CATRONS FOR THE SPECIFIC APPLICATION ENCOUNTERED. 3. REMOVAL OF E, ST NG FLOOR T --WHERE SCHEDULED RZMO" a EXISTING r'LOOR Tr E; AND PREPARE SURFACES AS NECESSARY FOR NEW RESILIENT FLOOR TILE.. VOL.A7 LE SUBSTANCE. IF USED IN REMOVAL. SMALL BE CAREFULLY t:>j NDCFD Ott` u F RC EXTROUISHER SHALL BE A '(!A I L— ABLE IN THE IFlMEDIA.YE AREA OF TNs WORK. ^f., PRFPARATiON OF EX 3 S�: i3iG WOOD S B 6 L4ti"'11ae3'_"'3Y It'd G>g Ss.. E DUL ED, xiiST iNr, WOOD FLOORING SiiIi E..L ei NA: .tED T+CziiT WITH C'E'MEe¢7_C;). NAILS O? hPPROE`R#R.TE S!!.ZES AND ...'ACING FOR SPECIF C LCD DF"'(C)tiS TO SEEPERS OR JOISTS fO EL "M ( NA ; E: S OE,,K, NO WOOD FLOORS NOT RES L uENT P -_OC)t tG HOWV TO R. C lt''. KaH EsRs YMti,NT =•`LkAa L.• u .acf.? a . S. NDo.% ' l` THE €' ik , S4' AND R MOVED x_ ME:;:.EvSBAR. 5C PRCi•'aD. A• SMOOTH EASE FOIZ RCSIL'rC•I T F:.OOR WALL • E o ai d≥F k? ? ri Y A 2'�,: R SAiwa? NG 1 .7P . AR STRO11fS S-40 Ih :,00R AND WS' ZE WHERE SC.MEDL..•.LE D F'RO ' DE AND INSTALL " OF APPROVED HARDBOARD OR Pk WOOD L7►-DERimAi.'"u#Eit? SUCH AS .ARMSTRoe3G DE,t.*n E k :MSLFAR * BS•?AL L TI0N AND EsAg:±' IRG SF2FLL BE IN ACCORDANCE; WITH PRINTED SSPECIFICA ' s"L)NS OF ARMSTRONG CORK C_O tPAdhyT,, '1i, TILE ARO BASE L&.* I NG--TILE SHALL BE ACCURATELY CDT TO SIZE W' TN TRUE y STRA IGVT,, SQUARE EDGES; FLAT ND LuN3EORM IR THICKNESS HE COLORS SHALL MATCH Ts•LE SK,€.vxPLES AS APPROVED AND fag,; , UNIFORM THROUGHOUT. TILES S#s?ALL BE STRONG EAC;UGN TO S7AND THE ORD FeA,I2r WEAR AHD TEAR CLEAriNG AND ;ORJ'NG OF FURNITURE `wld;N*** OUT DAMAGE CR DENTes AND THEY SHAL ► BL 3 —'AL U G„ .TILE SHALL BE ODORLESS AND NON —SLIP, • EVEN WHEN WET. ALL TI StlEA,,. BE MiADE. WITH NOM -•:"AL}' titG MINERn_;. PIGMENTS, ASPHALT AND OTHER L CCESSe.:? FIBER F UL L E:S AHD BLENDING AGENTS,• ALL OF WHICH SHALL BC INERT, TILES SHALL SE LAID SO AS TO kNESURE GOOD CONTAC"TA WITH C OSEp EVEN JO II M TS AND WITH AL FINISHED SURFACES IN A TRUE FLAME AND SMOOTH* TILES SI ALL BE LAID SQUARE WITH AXES or ROOM, W8FH WIDTH OF BORDER VARYING SL GHTY TO MAINTAIN FULL SIZE TILES €N FIELD* BORDER TILE SE4ALL SE CARRIED TO FIT NEATLY INTO BREAKS AND RE<CESSESp AGAINST SASE'y AROUND PIPES, AND UNDER SADDLES. TILE SHALL Sts CUT TO AND :*.ROLU4D CONVECTORS, ETC* a OR I•XCESSiV T HEAVY F i YED OBJECTS 'OVE. SASE SE4ALL. BE LAID R AN AMPLE BED OF ADHESIVE AND r IRAA .Y ADHERED TO WALL su FACES IN ALL PLACES* NSSDE AND OUSDE CORNERS SHALL BE HEATED AND HEAVILY FILLED* ENDS OF RASE, WKERE'. EXPOSED, SHALL BE NEATLY MITERED WITH ALL VOEDS FLLEO WITH M.&Sa hC OF PROPER COLOR, ADHESIVE FOR ALL BASF WORK SHALL SE ARP S7RCNG S-1200 CoRLE X CEMENT, 6., SAMPLES— —No WORK SHALL START UNTIL SAMPLES WAVE BEEN sS,+Li- -TTED AND APROVED. SAMPLES 9H LL SE LABELED STATING COLOR OR SWA<OL, AND tr A NDrA CTUPER'S NAME ALL MATERIAL INSTALLED LED SMALL aATC: THE k.FPROV D SAMPLES* 7. APPROVAL OF wRF"Arr.,ES 'L) f E'C..CLVE WORsg. —! aS COi.':Ri.C.TOR SHL*Lc. INSPECT ALL .$ REAC4S TO PL'CT;'VE;' :LL,L WORK UNDER THIS PART BEFORE COMMENCING. Ew fAaE THIS CONTRACTOR FINDS CoRDI IONS SAr u IS-- WREdRE. WOE DLLj SORB DE TUS CONTORCEE SNELL DE E THE SURNACES AS.EATURLATTOEA„ 8. FIR V N°I S_ 4E TO OE A,VA Ro ui .e..� BE TEMPERATURE AOP 2NebW REBUKE APP LEEK, 9a MIc' w. --AT •,! 1. t NS MMERE S ARE EXPOSED, SCREWO SPACED env J. S£. BEMEEHEE, STAFT; Ntom SO ACE TAnCl: OF _ETOU SELALL ! aU!RCC.T AND MANE N aCI_.a SARY At "US I T o Lt' t IM t DAYS OE '?EE r'.Is: MAE NEAT is I CONTz"s yEi I!WO2�,SLT 7R E, c r dN LEVEL PLANE SHALL AREAS. ALL f4 „ P .,ANNE NOT ic E., `C"s:v EASE NEAT APPLIED LOCALLE AND S4A _ OE QU dCELT RatLED. T 'ONE. OURNOUNONG LEVEL. ALL flLE SfrOiflk IC 'UR BREAKS AND FRACTURES StiArrU !E REPA REO WIN IN HEAT ADD CID;CKLT ROLLED. .ALL VM}.ES `8Ok?iINi D€RORE;N CORNERS OR FSRAC`0uRc _ii?<F''a F.N TaRELY ACROSS TREAD `U'RE'ACE SHALL. BE WRIER, CAREFULLY REMOVED., AND NEW TILL OF SAME COLOR AND TRCKNESS ;,BARS"' B U D. 32,, QUAR.'eNTS 9'E.AFRANTY"TS CONTRL r SHALL AND fR EREDE DOES WARRANT AND `OE GENERAL C )e Y ACTOR SHALL MID BEREBY DOES GUARAN— TEE THAT ALL HO Y, EXECUTE/3 DREIER TNIS FARO SH?E,!B SE FRZE CRDM DE— FECTS OF KNATCR IAM_S AID ' ORK W3HI? OR A PERIOD OF ONE (fi) TER FROM THE DATE OF EKE EHKAA ,ERPli tCATE. THE ABOVE PARTiAS FUREBEE4 AGREE TEAT THEE ',NIA, AT ?N!IR Oe/ EX— PENSE, RE'PAdP ADD REPLACE ALL SUCH GzrESTJVE WORK. ADD ALL OTHER WORK DDAIAGCO TR REBT. WNIC• DECONFS DEFEKTVE DURiNG TEE TERM OF THC GUARANTY —WARRANTY. 'P is G@A!.tR4iiTY—eASRANTV DOES NOY APPLE: O DEFECTS CAESTD BY. Wi FAHLURE OF TN! WORK OF OTHERS, it SUCH DE— FECTSt PE IWIAOSO BLE ;,O BETON ,R Rt�'i': -� O THE EEXAMH4ATOE OF TOE WORK O, THE OTHERS, SWNON AAS ,.Z. A e. U CONSOTA OE F"ORR. S kE .. - ,.. u- vto: rL. r.' __ - - - SS""d, Ti -As 2`PC2N Or. NC AAVTEMATE P.~<.S, °�<<" VATOPA A.,IPLEAS WjTO PLANT lC UCENO eir?f5AE READA TOPOPCOATOR AS wN'u r.feC $l64'i r".. EI END 9Dv'�'u^a 8. L Ea; OTftG rTEVATOR v,o., 'Es A TIR ATC !NC_ `�' FOR ^TWEE MANUFACTURERS. P`, ALi- AASP E'PTE E-, A.. OEAOC OR PART 44 r. Ce 1 ., fl if z6. 6.9 n S F S :' i M1k REFERENCE SHALL ADDLE TO AS PANT'A FOR A COMPLETE ENDSPESASLE -3s"5r N PP Fs'$f^.:Te HEDU Ffc/_a` REGOLATTftONS OE SHED sU! a a. TH1 PF SFIAAA AA AOF A eOPR r O HA SHALT E A li , OOORAT ` D , RD SAFETY CR STATE INACEETftCUT ASH LAC FO Hy: T8..:!,.. iCA 4s .5 ;A'r;t: A, AaF ii C,S, COCODE ESE Ec CVA.TOR S9 Ap . I ""iA A M. d.. y..<�' no AAA A..a'P. c/,A AMCA VOCAL CODES. SHALT .. 0 OEH BY THE ,AyCHftTECA d GEME T 'e RAWS NGS FOR A!r P50 !AlL. ��`` Gc tr;gp5 MAN:A e CiiURC OR II FPSTA'LII..'ATii ON9 4, PiftN7ft 'iis—a2E,w_. EXPOSED SEPAP WORK FURNftEHED UNDER THESE SPECftFftCATION5SItAL!L Ac/A PROPERLY RAftR ED AFTER tNSTAL'LATN/O& (EXCEPT STA eI A S 5TEEL AHD FACTORY F9fs ftENES4 BY THE ELEVATOR CO NTRACTOP 5. GU ANTA —THE 3 „VA'O R COCOS@TRACTOR SHALL GUARANTEE THAN THE MATER8AAS AND WO MANS4Sf' OF THE '.PSe:;87AYVS Ri1:TA;ULED ST HftM UNDER THESE SPECicF/CATnOrt$ ARE r tPST^eCLA$S iN EVERY RESPECT ANV T'"}UAT -u 'ORAL MAKE GOOD ART DEFECTS NOT DOE TO ORO !'4ART WEAR. AND `EAR OR cMPROFER USE OR CARE, AFi:r Cr2 MAY OVELAAP PM!Tit qt ONE () YEAR EA04 DATE OF ACCEP7AREt.. 6. mA R. PLR !♦ o T A4 it, w C R COMPLC 0ON 4S c4 C5 AC— CEPTANCE ftNCLUOftHG EMERGENCY CALLBACKS AT ANY HOUR AT NO &DOMO4A i„ COST TO THE OWNER. U ICL€.B€.-. REGULAR EXAMft4ATftONS AND ADJCa:STMENT:1EEs MATER R,AC_S, PAWED, LARD BERMS AS HEEDED. To SE PERFORMED BE ELEVATOR CoN RAC'OR, NOT 70 RE SUB ON PRAC ED° CONTRACTOR W AL :NOT BE REODHESED r3 DOPER . ANY ,•.R, CftHUSEO 3 AlT KftEDSE GP NEG.AGEM-*E OWNER OR O ₹i E'ES, NOR AT ANY »a e r e F rORD THE CONTROL OF THE ET.F,VATTQA AOPTPACTOR, 7. .PP aF R L-RSSM SU F r.°' V,; DE a, iV_5's-FRONT—TO—SACK, OVERALL A 3cP H5FLOOR CO ER NG SHALL BE [7 MYL ALE Er " ANC 'JrM`. ti.. SERVED OLY ThAT `8' ATER7E SN3L(L(F t e F rN.w.L �'uE Sa:P V 1 `r:c g 2 v AND THE CARCAR•BUIVON 29 A. D A? ...... ...._ ._ ,� ... , �. ATiON PIo `','8DED er Or RS, AND• U4STALL p � f RJR PORE THE CONC " Tf c r OV yy R_ _ JY �m s. frtk M3'UI4I sON CI.aLJ ci �I[ t3 eY kn 4 xui % E S RELAYi`si Sb h Z8 J`P4 LUCE ALL OVERLOAD AI i�F a`e ND M r acEPSr PE Asr Ra=. i s 7 FRAM. o i 1;1 g'!R'i'b13x"#.{i 588 qv dpi 2d y :' ` +8"l:�a.P SY !'.s (�°d�v FOR EL VATO SE"a C�. GA•L?r? S AR f8uS .Per. AND N9Ey8� TOPQE. Rruflo SPEED `k0r SLOW 3PE O SHALL 6V EC' q iQ Gw A„r;4 G-5-0 FSAKSM4LL 8., C`d c°*v 11 ?°G. B.( t"+. `�`:_CIlfi_:n r�.,g ₹': iJ 43 MACME, ., R 4; is �'O�Il kr�tc e k t ma E..ryAPi N4a ek :� LE.r,: 4k.,g'F:?Eh: `zq Vin. 8't I AS µ:jED TO PA,oy.S? S.E;, as µL OflRF.tcT i,URRE✓'f7o G6. icn3 i°'OMP,., F t v comPL %2AN LOOP 3s ccpm a;A7_':Ltlg 5 - au , HALL p!411 t}na Gu o?s fGtr?LS. COL.i uD TO CONCRETE rouv.-- ONTRACTOR SNALL FUR jU FC'UNDATY du E, DOTS I .PgiP' ;E FR L 4T 7S 4N CAR OR H.P.E L TEES h CAR AD O1, a 6`F't8" Q1 TC a- Si . 5 w?A Y FRAAilG ROLL 9EG STtRED LIGRL FOR ZACDa 2 O flR ''i FLooe CyN OPERATING Pr"aNCL O UR TE.Y_L r%(L.-i1. f S`Il.... Eic71,7 iiDDICRTOR Ton:pr A€ vss y��" 4�kNe 'u'':?3a %` -:iRya . —Y=0e2 MAINTENANCE AND T GC YID 1 J'N� 'i [9I C NCRECUC T STOP ; T4' ON TOR C/ R AND d OPERATING S. --SVALL ZE LOCATED 22 E P E C u :, n_ P n 7 DR !4QCOURMENT IWI COMPLYING lEf ki PEQU..RE '.EW S iTyiATDNAL ELECTRC CODE , .EK SUPPLY OR 240 VOL ) ('p,F'.FiE, 60 CYCLES, TO COuTROL fED tv REUGA RVSCOF!WE:CT ,x2 106 +N 'a CH LC ROOX SO TARCE FOR 05 �`•± rmP0 MC702q AND C RCt 4?f FOR CAP L P' AT G !."EEP OF ri;O1SiTWAd' y a PROVIED `9T TFfE ELFCTRSCAn (ONTRACToR.. E °dCSR9E,f'E:O 23Q OvERHyG`_D S saki>kS 'PROVIDE AL 5 -ARV TO Pt1FNUS1 PROPER LEAD OF PROVIDE; g LL OR POL Eh BEARINGS IN ALL. SEEAVESa POPES TO CAR ARO i E�,WE Sac,ki+'- a iso&'$w 240 CAR .SAFE 4Yr •.•j t Px fo+.'[.C US DOLL SAFETY 0Rti CAR SHALL 7E OPIATED By CENTRCFuGXL SPE C GOVERMORo sAv sTy OPERATED SWITCH OM EAR SHALL AUTOMA,t4CALLYr STOP F9 'o.R M .Fk APPLE ; -C rile SRWICT W�1t:i'd sAr,, "y SETS. 250 CARrrua ¥'E SHALL "SE. OF STRUC T" RAL ST€ -"EL C00PL`y 439E W i N R t. Coot, `inPF; e�l,�..=.�, ..a.., TNRED StO^:LFR 0a,.J7"S0 2-Q 6urr€ss--p'F4≤?V' 0C 'S,rpr ' HG 270 COUKTE r ( T Si a.,LL IRON JW °r4CTSe ROCAfi, Ifi YASHIG 4 FRONT OF TE COORTFRYEATIDT 280 CAR AND COUPTEDDRf?� STRUCTURAL FEAME WITT4 CAST CAR, PLUS 40% or $ C I- E'EF BUYAR.D ;.N PT i;n,L,. 7 `0Prs or SIZE AND ,=... 70 INSURE REEO DE AT HEAST D AND y".3§A: i or A 4, -MP t t, ❑r_ CEDTERQ r . NT q coLos nS SRTEERS BY T C A C rsie F I S STEEL ASS Lr br `E ENTRANCE V N'2«Y�, x COLOANS, 41.E t' MEi..,, ,,} ON P ; a, M Fd"# a[7T E,ITERE ,`S BEE L_ d Fz' 300 COOCR SALT RE ED.DLE—STEV,7 nN rS � E(F D 4 1 4., S [ >j 4: N P 3 - 'n8 PROVIDE S a e [ C �. I c .. ., �, ..e ETT r"i Ll Af°! ,'`:.. AC d DOas , t ,.. V EN`r C t RMC h _k THE ELIVAToR .: tTN AF;_ DOOR O, — D, SHALL 6 ,,. t.,� e p. e OPEN AND cLes CAR PROVOE 9' DOOR ORE,OREN DUTTON re CAx O `RRAT.tc SANELe PROS E;L »i SAFETY SHOE DOOR REV RSAA a- ,'ICE OD EA(1 EDGE Cr CAR r)p� 6OoE NCLUDE N ,ERLOCt5 OR ALL [ GL)FSTWA1 DOORS, - ,32a d C?kf }`YFTf °. N Bans 7' DF ALL "j* A T OiA: o et:.rr TRANCES REQUIRED, 0,� tv �"" st -en � � '•�) SPNar C'"SFEED HOLLOW •`wE'SE 4. Si IoPJ iRR ENTRANCES. F'taAMCS SMALL RE ,UCE WITH A PROFGLE A$ SE'[:.hf,.,.Ei RY TF;E ARCHITECT. DOORS &Hitt BE 16? GAi`is:E, MOUNTED ON S'rE_. HANGER Rooms. PPOV DF DOOR CLOSERS OK THE MECHANICAL Y ;'er To PRECLUDE ANY CHANCE or 0OOG? REMAINING OPEN WHEN CAR LEAVES n rg n SILLS SMALL 5E EXTRUDED s VMiNUM F r Ooo NTEROFORA E LANDINGS AND A TOE GUARD AT CAE BOTTOM LANDIO t W ITU BUST COVER AT TUE TOR LANDING, HANAER COVER PLATES `l:AI,. EC INN REMOVABLE TYRE, ACCESSIBLE FROM ii1; 3m a;4 TNE CAR. Flovol orAoins AND BANGER SUPPORT ANGLES AS NECESSARY TC, SUPPORT' HANGERS AD DOORS AND NON —VISION RUNGS ON E«V.CP DOOR, rRAH'E S AND DOORS SHAAL NAVE BAKED ENAMEL F3R0SH IF:' COLOR LAS rEL€CTE,D BY THE ARCCHI EATe 33. FIN SRES CAR ORF A0 t51+a PANEL, 4',,10 9 RuTrOF' FACE' [;,1(r� GSUDICATOR MCEFLA,Y-e tR LL teROWASw 3, _� 13ke. A. �>n S?�$N,N F NDar STAIN" LESS STEEL. A I F ;Cr7 !t }ers F'INISRES TO BE IN COLORS AS a !-{:TRD BY THE ARENJTECc. 34. WORK +NOY ROOK INCLUDING RIT LA' C.4 E6.r -uHE FIN SN WALLS A,U�n FLOORS e:,^ -eo .E Lt OR TO qrp ka E ROOM, T E fiRUeS L«n A,N F t R - DVER F ,mac' wF��t s a >_ x NC UPS ,D; ADAC:REQUIRED, _., =. �' >✓,� sr D A '� '`efiq it E,�s WAhr '�O 't. "'S RS f,E 3. d IDEDVSPEED g. VSEDMEPO7 SE ALL S S r EE, T S- N OPFs.!EG UPPP. C7FE 1 ARE SEC. NS OF 35 jraLs; 'uLt LOAF guaG TEST, 0t "a.. E O&D SA.6S`? S?P. CAs je3F„: DE'MON.STRc'T' D? OF' $CT i 3D OF 01"FaSR 15.FIY DEVICES, :N ErREOCr.SR DOOR § EV!LRSAE 05W C'S5 AMP „4.{3FR;M`. 'i. O.P R'.: t i ! - tfic?:.Z 5 UH TSE PRESENCE or AUTTHOR0a S Rk.u'eREs S;NTA ir' Os. OWNER OR , ;ii :"Fb 'ism 5kV EF C.7- RE MANNER BEFORE ACCEPTANCE,, 36, GLARANTY—WARRANTY--THAE�y cos^3•rr. C6Oo-. SHALL END H RG"s`„ 00U4 'WARRANT AND 7.HE GENERAL CONTRACTOR SAIL AND HERESY 00'7 N A:.RAN— TEE THAT ALL WORK EXECUTED UNDER T; 3 PART SMA!L,_ HE" FR`€C FROM DE- FECTS OF MAC R:_ ,'-.S AND WO!',;AHSH%P FOR A PER SOD U'"' Or S17 ( FEAR PROM 7a!"% DATE OF flLC .r tl^S A4, CERT1 FiETE S ;'E ABOVE PART!CS FORTNER AGREE ?HAI 'sHET .EE, Al ftC,R .;WN EX- PENSE, REPAIR AND REPEAE ALL,, SUES EDEFECTd VF WORK, AND AEE OTHER WORK DAMAGED TO RCB , WHICH BECOMES GEf'CTtvE DvRsNG THE VSRM OF THE GUARANTY-WARRM*TY. jH'S C4'AR:ANT''-"r.'"o.RRANTN DOES NOT APPLY 70 DEFECTS CAUSED 8Y THE FA'LURE OF TK,t; WORK OF OTHERS, iF SUCH DE- FECTS WERE nPaSSIDLF TO DETECT AT TIIKE OF THE EXAMNATEON OF THE WORE OF THE OTHERS. 7ONN UNO _. TV ASSGREF TO THE MECHANICAL MENTs.,RT GENERAL I:ONDITOr ! HC SOFA OF TUC MECNFUEAI SECMON D SOVVENCRIAVI L C is TO SE WORE NVECStEvALE Y`t .4 Ut BS\ x S N'L SUPP'' .. !rg-1 J'C.. nN 2. Scot o WORK- VRPE° TEC mvANIcAF oIC'ri' CONSIST OF:LANES—HAWS ALL _. ALL PEHMS G, SEATING MHO NPE 0 DT B,A DRAHIFAS ARO _ ._„ HE ELEHDNDn t-IE FILFEEy i?`W ='ACA F-ICEEPCAA WASTE t. NSS„ F .3 rc .N "_? ..N" u0u C':FHATER SYSTEM ;HAUL I N t URE ca LE; RAP ,. `f ION HHEN FATENStiON or *FEEL . RETURN INESs MCDFICATON ,. DAQ a LO.b, IPA.". OE lx s7 NLa DADrATON AN1) G of ES; ,.OA NODiECLiON ENO N I WI S. I.0AU AS Nry CESA&R: V I .r tRATUR_ s.OHTR0I4;C AIR DNF I`t;tkFHL AND cFNB a 11 ION WDRN SNEJA NCEh1 P5 HOH9r C,,! CI3 AND E7.^NS 'a.N: OF ;It ST;NI DUCTS, NES ANT RE— LOCATED RIBS IS7r_?S AND fi>F ;24EH9 ANO RE"'°-8:,`I'tMC PNCi OF CRISY IgiNG TFSF'MS AS RN IEC CSS&RB ',15 DRAV- ADDfiTICKAL WORK A'I IRSu rA DESCIPEFFIRTI (,0BC I5 !,, id q_1.0 WORK ,,.. F a FAO AS R. C i -. t3L v rift DI vc P..usflUlI'O AND nB-CTINed• FEW. A/C WORK 1 ti«I_ VE XECUTHO UNDER C'NC NBIHA IV,0,f CONTRACT, AND EACH IS DESCFUBq of A S&},a5P.ATE PART 0:7 :Hi:S SECION, SPECR APPLIES TO BOTH tp,w&i-'. o ,PAR&' ,c "{S 1N ANY P:CRI k'. r" THIS S5!CT IO i 1CK€CF DESCRIBE SSMU AR F,?ORHr S`II: r,G.. &HEILY TO ALL PARTS OF `€HE SPEt3.FICB1IIONS, • I!RSUFF iC E'ENs' 9 t';'P' OnmATioN OR DESCR'IVIlIOtI OF MATERIALS OR LABOR 9dHCH PREVENTS THE ACCEPTANCE OF THESE PLANS AND SPECIFICATIONS AS SUFFICIENT 70 COMPLETE THAI WORN MUST BE REPORTED TO TFE ARCHI— TECT 72 FOURS PROS TO SUIBMrr hTIN» .. B Y4 HE MECHANICAL Ct2-IV'. RACTOR"S BEIt WI4LL. SE CONSTRUED ID AN OFFER YO COMPLETE THE WORK WITHOUT ADDITIONAL C057 70 5? 0hfa`1 ICo EQUIPMENT ON THE PLANS, BUT NOT rNELFDEN ZIPS THE SPI'C F C,vr_. lO SE 0R 0fl1SCR SL_D PN THE OVECCYCHIONS AND NOT SHOWN 0R 'F,".C TLANS,. SIT NECESSARY FOR THE COM.FLIt V'ION OP ENE PIUMBNG ANS HEATING ND AIR C0NI.C. :ta'cN N''.S STETCMS, EF,"'E S: i>UOR A O yN9? gnt5Ri."_=.C ST THE MECHANICAL FONTS♦:CT R AS . CA'N15,CT° ! ON `9t 1C rf.O.r3 r, P RFOR:r UNV,:+7R ii48e. FAHN7fliNG CON ? itV 40 TON HI: PR .tlr' @ $ S VO ik E d i4G A BD '.$ Vfl u. TRA:. P . c; eECTS rOR A P`-'u<'PObq. $HAtL 6r Pt,P`..t.LC lF_; c, °c, THE 39ECw.ANIC A.L COK.'i.'.f... O';= "Hi_L Pi. Frf:.. ,..a @'R POCKS. Skiq TA%i4 iR4. a. <a'{<'<Fs - Sr F Et . us IZ µ'o hz S'l.!e.n F tRisF ';0 COR., t M :0.V' 1WARre 4r Pu?r' FA(S ^.C WORKMANSFiP OR ;“TRLA TO ORTA�K ' Ik RST CLASS PERFORMANC< ,r,'.� OO r Pkbf4T o tH i..L VT AD -.Fe`. S"FNOP'f .UP— C l'``" r.NOW is 7 .O fi: AD .,, l : C, F t o R E 'FAT LUUetE:R THE PRFSVRL THE MECMAN.ICA'L COP;�iRE'c i0R. '_:M l.L RA:UTfl TRA7 nh, .^ft a•"; NSTALL!FD SY HM tsfl,L NV R `.xi;.:: IN K(ANSS^BSS mON OF OSJi: NOS OR ',°RfsE'A ONa aO ANV PART or .;'..t SQit..EuPGS. HE 5NAL.C 'A, E FULL RESPoNs a.� rTI FOR ANY F4O ISCF CA..T.IOt OF i s cC~=Si PREW70 OR F OUNO'AT I!Ot^::S AND SUPPORTS FOR 114E S ME? 70 SECURE ThUS RESULT GUARANTEE SNAIL SE R€�!WFORCED v..407H C<;F7 ''!F`ICAIw`.S OF WARRANTY ISSUED BY THE MANUFACTURERS OF THE FOSA r.FMtNT US3:E7 6. 0ROINAWC.CSi tnI: P_ ra-u7S TI1 iE KEeh: N .:d:l, COHTRACTOR SHALL COPPLY W!TH THE Lf9S £RD ORI) NAKC EE fib4 f=EFeCT Al 7HE S l:mSe A€0 bf IN 7147 RULES OF THE LOAL AM S777C PkSY;7C ORS<, SUCK CODES, DRr',ii1' S a 5 AND RULES, ka Cf RF t Ar?Li, .t'..2 + K PECEOENCCE ov e s: tEsr PLANS AND SPACUPCATl N THE FA7,d.RAN CAL ONIRA_ T R SKLC7 i7,7 .. SPLCA7ON AND PA. OR ALPERMTS '_ HO CRITCk7ES OF NSPE4 :OFI' R 0U; 9C0 I'OR Y„. OF" kt'g3 AT COMPS 7J ON O 7KALL RtENrq -. Os,lkR W37, 77;1 S FkLD e FFFRT 1 F G CATE.S 0 `.C7 E,.SPE?'T oOE. I47, ft. BOARD t1F .: nSoI.RW T''RS9 RULES SHALL P OFsS:^` s.v '.:-1 ',HO t "'U;?i!= 'tn'ut?q THIS CONTACT. G'hA— x i „ f e < h' A. e B C USED is C' YJ E i A. 7} g 'z R g A, F_ e 68 ,/.. 4a a <, rs .. � F FI i , Ft ,s. -.. ..- _ _ u SRSC S N A L D5TRtA!,.NS S5oR .._ • kU5k5cRa5T7s C94 a_H_ ti_ S55r413- 1CRL rx s 5 5 C0I ,t IT N I t r 5Lc500 %0.;`., T'C ✓ C 7 s OjORTR5 O?` LRC u 1Rf“ U -Lt�5 re CP J.:. ' N D: 5SiO LOAL SO S' SCC 0 :1Fr R m. l 1 %'i h t ay )SS, SRAk N O R `' t Mi54, 171 °; II• fl s' ft TSE TCxfa,?.ZA iCCl 55 tt D l '" z o F2: It e c - TOS N r5_K: FOR 'CVF ',. Ft y &LACS Nd R LE>,r,I'=i. RON S. 5 $1.k5F Ok5T F sN F5CkD;ICU f a dilS5. OR WkL (R9MG TIf'uNa5 k5 ! FI;WV [3 U4uwEr4 — A4k. 5:rk1 ASfs ikSTu tGNeS SR A;U+ Nfs TP' Nl«.- H(.O:^ ' 'i:; TH EXTRA f,1aAY'C CAST ?NON Fr'.'3f,@F,S51. WADER L UCS — ALL +Wi CI t ;CI.,Y AH5 ND ; ENSLOeC NO 3IAEC'R Li.,WS SKA..I'•,-,f.. OF. MXOE W' H THE S *C G PC OE P ,TL A NI LN0 MODEEO EO 4Ft, E . d E9i:tC°3, U.L) PLANS-- Tftc F 4')R;:. @36NCS ARE UR a1H AAC f;N Hr2.RACTnO FHf!A.TI' LOC,A, e 2ONS OF NH . ELEMENTS OF NSF SU ;'Cv$, MEASUREMENTS FOR C4f T 1MG AND MSTA LANG NPFp AND Ct'U IFI1Z IONS OF ECUPMENT SHALL SC ry ER N N",C3 FROM ?gay? STRU': .NE NC? SNOT'. Ti! CCIt o AYg FROM F DRAWVAs'GS SPACE R C:'2ifC:INUNTS OA 75 t415'e5ftILLS THC s.ULL.f,NItsr- CONTRACTOR PROPOSZY TO UURM2 v5. SHALL BC NktiSJ LGGITCD 5Y 4n4 ' "R i;OR TO RQFOiEF3N8 3SL 2C, F_R S: O€x 5O2URNT, 5 R3Ie^. TUNS- C'.OA3Df?BOHS G'7 r 5 S> F: A,' :1SS MST RCcIUS5C NSS5Ss.TYN. m_`.S N !(5s 5575kA7tON L4> TNT MI... „*'... . -'C!rd`.y AC.h SOCR CMAS5S `SAIL'_ BE H,CU'°" H.x 5" 1.CLA.0 k$ r.5R0 OF r4..r AwA7r7, BEFORE tUGM?F" _ F. F3 Rp KILL D5AW!SG5 kk5 SCr CAM1:; 0v,. p,. Ti O'^+ SHALL ✓. " if iI S C )i m A. 4 C I ii S C C .: N I N -C, D rSeSS i w S ?H C NS ;C <". UNDER THC M wCHAxis cOMTPACTz 1 4 BM SHVFo l IF a k4 c. - C ., C s t,! � eC �"s! NOPC S.!(u rR (,e r �f4e-e .� ... - L ^CC' C a { c -.,v f .re.,` Y PA _ TSTS rc t tee >:. Cu r ° OW ALSTED AT WO AVM ?SR SQVASZPCP HADNOSTATiC P c LF 3C: SHALL re.2" ! IC . iL S C I Y e 5. K s ad's; AND %` VENT ! P 0 ANO 7!,t MSS1PS RSQ1HRE_ r. tCI a -NENE N E 00 NOT R i A C? S C CIS L N J I• ST Yi2 LI ° rya „C ¢ f; f iN 7u z a^ a 6 at v V F xS SMAL tl'. F FOR PLHMSNP SNP 1.19C.h,;z ? t F:♦ 5 J .e,4 6 Edo" PEP=SPEPES AND PUNTSC r LS S Mg. -;'l d ;CC OF a rvu ^RiL-P�h6'`v!'3 MOORS, ^CDQ' CND u e a t W c !k Cs rAR�-d e F.ciB N#4* u. v.�!'n v rr �x e r f"�!'4 I( S@, �€ w �" c-i� t TO CUT cgs a £?"`, POCFDSSS y MASS, PS(!NFORCE WALLS AS DRFCTSD, AFTER WORK „ PATSw HOTS i® MATCH H PP[ 0P C.:CAC. r, ,9 PSN]a 3. SLEEvzs &N g k ,951..4L CN!, r •_NICtr a, iuj9:Cd IRON SLZ V!=S ,4R FFES ? EMO WRCAUG54 LO0fl5, ROOFS, 9I*C) WALLS OaR JNP ,. L l RCz FrAT1!Ss % F8N °�4� F RVS OF CMC 0 — .LEO Pr CBROM I ICIN'PSK CO PLATES SFALL IL B U' AFTER 6��!4E df L�7 R, 15 F"Iae .I aEn � �aTAl.{. EO ON ALT V XSOSIP9 ° PIS DA -SING I ROU4H t.. S, FLOORS SEND CIC I!;. II e'k2aSn 'ul.ANGZRR:S.—Y 0 4G .KS FOP STr'CK F F 141 SKAAL BC # NSfiACL s!) t0' OR Lf_SS,, ,AND, S"9!,.1 DS SRL f!si RILPG OR C;!LLV 5 u1aEa WHEN AD— JUSTABLE on, ,A iJ; Et d4PRu' OR tiP xR5EL.C. WN': ZR'E E»'3Sc.auL"€_s 46aw.,S SMALL NE F509z,r AND SUPPORTON Sr CAST r. Ch . SMALL 4L f)r?Qpyfl) !N MAND P�%>d&aEKS HANGERS. �raSd € t3� . . EVERT 59 OR ONE MANGE h TO $C`FI CODMI HANGERS SKALA FF NSF(ALLLE ST ALL MANG S tN^SPH.C7#CeN OF 5K:C r'a v CCAMC TUE DNTSPISON R"w1 ZFS C "'Qt„} f₹'' GPG5S`o: ft . -R1 `: N PCRR C IwN e B"7! CCCC_.`? FAD-NN“MCHANSRP ,`S THE STRUcTHRF sALI: St 2'. NS VSTMOS OF APPROVED :F" r .c. A 6' 1..'!-_.C.°:''., LAT IOW° ADDS. -LDS SHOPS PIC?U P1FC CONTRACTOR FOR ,499, COMMECT ION tf'USB FSE rI',_'UPJI. t,CC ARS NTATNG 40 iCOF y g; r ! rvAL AA7N r G E " " l ASTA7EA77:0A N + .M4F ;y Pw fa ? .. N NATLS AND T'hPC C !7L NGS, DOORS SNAT7 v FL'IS OC i4 v Nr 5i ,,:9 4. PRF FOAT 7NISE0 V': '_L r LOOP _ , .... , _...._ .. - ... _ ... ... . .... _ ._ . SPACF AND SNSTATT PT.P Ci e_.AN A'tL NAW ./OSEe "'Sr0PO¢J ANO SE.S CON,P" :`_ TRJEP°rI 4T4 „-AE, v n r peg;.[, F - MANE A_ 0 .PaM roa Ai !;V SYSTEMS NEC CNN ' 70 'u-4 S CONTRACT, FTEEFS--1A0F AEATIING AND 0874UN ALL WECESSXRT u,'TTOA.7NCmSn COBa&C7 ON iN FS TAE 0SF OF ANY F7ENTED SHALL.HO D AND SA SN 'qTS ARS5. IG FROM SULK USE, AiL CLEAN /LA EcF C. ay LIES . OR c1 N - hid"; 2 A N Y M^ tl A f P l- s F O R CtR ACCtt$t c i OM c n90 .`.SEPER3 BSdON op Wo YrE 6 C t Ptn C; C TRACTOR SNALT NAVE N CHARGE OF THE WORK n'., AT rl}f a :'5 -4.:u t,`n-, rf RPJiCr SEPPRRI[ TENOENT 'eaf oN A N CAN EXPER F k a � PLUMONS l Ei O P A T . [NG ANN AIR ACINCTONftAG NONA TO BC w^, A:L5 C:. Uid3eFP 7Mj ANYONE. NOT 'xDc.:'ENED at:. i :dS «L•56.p—C�� s- Cs Fc.r � �' `: r� Z`rn'�fiJ i'�C'c �P'si. d., iii RFf F �z � PES" MEDBATELY UPON sR lT'-:_Fa RHOULST, ST A SAT{S"7ACTORY REFLAC ENIENT ,AF'S;TR A .SAT7$ aCTol2 S@Iiir'EN 1 8TC.N[N` N1 t S BEN ASSfGNED, HE HHALL NOT BE WkTHORAW UTHOOT THE CONSENT OF ISE AT=FEi7ECT, 200-_ GCIARANTY—WARRAN7.Y— TR.35_ CONTR.FC r,_R SHALL A.D EV Ri:DLF OD -ES - WARRANT AND TEE GENERAL CONTRACTOR ;S!i&lLL .AND HEREBY DOES GNARAN- TEE THAT ALL WORK EXECUTED JNiDER TMcs PART SHALL Bt FRiEZ CROM OE-• FECTS Or MATT.R„A'SS AHD VORKMAMSH FOR A Pee 0D Cr ONE a 'YEAR FROM THE DATE OF THE F`HFE,L CERTFCATE0 THE ABOVE PART'' S FURTHER AGREE THAT ? z'sP rAT 5 F iiP OWN EX- PENSE, REPASR AND F:T-PL.AC'. ALL SUCH O"r CI[VS +.$OP2( °.Fi6� ALL OTHER WORK DAMAGED TNrRISY, WNPCH RECOWES• 05F:CT.'V if. DURtRG THE 25£;-:54' DF THE GU6 RANT -sWARo ARTY” m l,j CA A P. `rr 'r 3Yn4t n;, v DOES '501; APPLY TO DEFECTS CAUSED BY TE rye UP5. OF THE WORK OF OTHERS, rF S4:CF DE— FECTS WERE $@fiP'O.SS O"LF; 70 rCr..__CT Al 77,Z Or T:•mE EXAM; gs', : P:4N OF THE WORY.. or THE OTHERS. DEAYJNG A L_ •_ O STAR „RD c5.._,AFN c .t A 'S oN tY E A f' F SNOS CSAA. e p: OA O F3T T.. BE i NSUt. A 7 3' 'A. ?N A P:•DC ERA ASV ' Ri. '.A ;0SE ¢' BE tT .-S. EACD fit„ CONVECTORS�rA �a FJO-..%URRSN :AAR iNSTL+.^. Moan m , vit ,,xN OR rQkL Cu P$;6rC OR$ AND 5AS&:8uADD R.AL .!1,'P,Ohi R..iS'. BAs ON C:G AcR sec AHLERENTS AND R '4'Fe S7EEL ':'.AB: NETS AND. F,.SETCLA Or Tfff¢' ,p CaR`t.hp R t t3 Na .: GnT sHoRN o3 P, ANS. FRoP dS ,.N.iAA BE U GA. +fii.. BARTSOESB RA"+ „L OR.s, SN'.LE WAVE. FU;i.A RACK rL `` CS. PROR DE r_Sd EZ EAEs, ADC.CO ACCESS SODAS ECE N7 STRhAS, Si Pr Cii.duDAS HANGERS AND ALA NECESSARY .ACC .SORyrRe USE @F,, Et „it& tOMBECTOAS BETWEEN A. • COPPER P;E NG ARO SIRED TYPES O6 tPBcNG., 5e WE.DE ?P Mt�._._CS !.;?a 5 • ER AT THE MfCl1M c A coNsR,*,croR s c. FOR "s4"ne D{NCA, AvEE END S$4t9. BC r'OECO 7O TDS TO WARE 3A;! WA.AL . BOWS ^µ^'TUC SS ".TTANSO WELDERS. SPATE BE CERT— SAAR. e BCHTEATD, ADO UE WEEDBB G THE: x2VA 3OTYos3 OR THE AONY. AN.r. THE BEAD e , UP + ` :o 7AT APE WALL TNERNESS. '3TS TOR UNIONS '-AA9 f BE b' C.! -%G. BAAiL Si! MADE,MB AND _ it fi, ° 7 C%11S DV eiS n« nW %."4'AND .— �c s e CDp CONSIPAtVrfl of ° OUGt90UT 7H7 r.. WGTO or x:$'., ,.t Z 7! kErE r -. d:PT't£9 grw [PEAR WCt' ADZOUATTRUC7VRALL r 5At r„s.'�.i P a: GOOP ..C. 4 G 4e .,Fe V ... t di oP C➢ UO M M.5E q; 7 9QDCS , 2. "r` FEL CT. B S AN13 V p3F' - C0H UN i 7 AL,E. -„isv:0.FIO�NS O O7_Rt7uto `R0 -z,._,_ F,L.. a•Ll. SeREACR'a ° Td ?R A Ge6AT4R; TNAFt 400 SOPrk! E .MCES. Duc ¢ 'i Q '.C'kF. h MC;yy ORC.I OF gA IC I th `C 6i C, f q. 6F MAJ' C:: 7. Tor FOUR. 7: f1 “t 8₹C rp _7 9 t5P CC.kCHB'. bM die 70 WHERE 7Rk9s$lf'PS 117.S ARE Est ,. €.eD FARTHER THAN 41 F, fF PR*CHIG NEACS SHALL SIRS AL'= T? AS LSG6.D IR INF A$HJRAt, GuHut. 0u Ti Ettii:o JO N7S 9v «a. Et. i•lA0 WI7A POEFET .10 iu iS OR S CL Irs ,5:rw DR VE C.'L6PS, WTeI •C 4VA MC NFOREED AS CLOUIRED FOR LARGER DPJ:CTS. PROV DE ANGLE iRON 77:NFI)1CSUG FOR ALL NRAUSVERSE .lOIH S, FOR DUCT OVER 48" u OCo DHCTS „UCLF SE ?!ADE'FiR TCGWT WHERE ANY 0P7F§ 04SS OCCLR. OR emu.R'CRC='__ Sr.AF#t NAVE:HOT BEEN MADE. 'E 'dGHT, EN USIC OF TAP AHD MM-nEC-800o WHERE SHEET HIETr'°L DUCTS ART CONNECTED TO 1 E iPTktE ARO C ` :d 3s RC OF AIR SUPFR.S UN?FS,, THE. CGNECT 1O`E BEALL E3C MADE 14CV6E , is RE — f Sg L APPROVED FLUE DkOERS S ^STh1k7 FiE N87r D �LEXF9d �. c7v. CE< ;tN fx C4 A7 Plfl HTS AS itED4 LREV DT TKE" :'+Ur ES AND OROINAHCES OF 7KE s-OV RMIJIIG ZOD7E£o PROVCOE DUCT TURNS, t, ACC RS ,a, s:; l? q, R XrRA TORS AS WOTCD ON 1717 PLAHSo fLA5E4 `PE[' E%.,,,-SRT 71307 PCE CH.G THE PO05_ 8, DkFFUS SHALL BE AS 9E A RAPT 0:= O.�4A FU'oSSRS c..RE3 RESSt SEAR5 OH cIUSTC€NT OF AR FLOW SMALL. , b. „.7 a,7 i, ^. 5: , s�P "E2. e TO v'!.* WOCCCAND NE SHALL ff:- ? E'er `'.::,P +'E„ t T , ^t' a OE E< trr;�. kC>: to.a :O� TR,AC'O ^ r';sZ 3f 9s N i1 O •#c ! . a f�3 � � �. 5f �:; t3 F L? ? I� e: E�r NG CF Tf;'_ PORTfON OF $YSF�'€S Mf„ EC' D Oi �'.ci. s 4� i� t. t R . 3 : S C O H T R i� i; l �. !ia .� }• d: 9. C Sr E d,M E M G A s� 'T : e? 'N 3 �d '" .d:. ; , t! �'t !. c. �' !v , E Q Sr 7 � M Sb T � � � F' REPO i<≤r a? R S 4' �', m E !- N s3 F+A 5 c :�, i, LEAV E° `= f+`SS` CAS coFSr1, i .''tf$.,v LAte T it Sties 3 S tN NORMAL Of! !-AT T 9fi: COHD! T. O M` EM E F i4 � �!. b� 1 i� gib• ��.s. �n.�USTW!EaPTS Rr,QV ; RC�u, 6 S•'� JjST I NG AND RS 'VET “iij —'f N : S f.ORTRAv k'i.'R SAC.". s EST AL% NEW AND REWORKED FFORTiONS OF THE S� I MS ORDER NORMA CON T ?CAA S DURNG BOT€+.. ftTee AND Sp.1Pc• R NAttNis si F" t A '©F gT' �- L fi�Qt••FF~t O 6!DyOSTMaIk:E� c TO .. FANS, 7O ETC ; OWTFOL S, .A'• R AS`dPERS a fiR F L ES rsRaSSURE 4tCDUC . OG C. 4 ,SNT S S.. :L F. P RrORh= OC REr V REg#ENTS &RE MET. hF, iptPE:An4Ff2k...'.:.OPi•p'i;C3t--G:fOfe.'.t''' AND XyEN THE iO4Ls+rs> TVRE iON;R0 S ' S f' E !;3 AS .,< i l'? of 3RF AF/OR R >:t #f a S'+.C h't c O ft N t3 R Wi t. OPERATION ., MA T EF h ;A, : h EQia t, PMEN7 AND METHODS C)DSi FOR HEW r . EASTfRO SYSTZWS SHALL MATCH EXISTING INSOFAR AS. POSISL, AND Mt�00fF�CADQNS 70 THE 612. GUARANTY.-1WARRANTHIS CONTRACTOR SHALL AND NEAEBT DOES WARRANT AND THE GENERAL COA3 ry R C TOF .4'!.Q S, : AND HEREBY DOES GU ;R N — TEE THAT LL WORK EXECUTED D-N"O_:.f2 TS PART SMALL SE FRtE FROM D FEC TS OF ASA,TER. Ff S 'AND WCRSiM!' NSH I F P'Qr2 a PERIOD OF ONE (i) YEAR FROM THE DATE OF THE FINAL C.RTFCATE. -NE ABOvE PAPTIES FVRT4ER AOREE THAT ThZ'7 WILL, AT THEnR €?9JCEX- PENSE, REPAIR AND REPLACE ALL SUCH DEFg4... �' e V E WORK, A dti D ALL. OTHER WORK OAMAGEO T5hF F'EFrs WM CH BECOMES DEFECTIVE DOR r t4G THE TERM O THE GUARANTY-WARF?AM -p THIS GUARANTY -WARRANTY DOES NOT APPLY TO DEFECTS CAUSE OY TnE F r, .4i ne OF THE; WOFH( OF OTHERS? r F SUCH DE- FECTS WERE VMPOSSPBt,.E TO DETEC'N AT TiNE OF THE EXAMINATION OF THE WORK OF THE O TNERS. SFellON s. ` PAR' _ "''', ivgeNO 2. TDRES, AND FOP EN S L F9 CHNUIC— HONG. .;t'a "-STE CONNECTIONS TO THE PIXIE I t`ebSc IHI FLANS IN GFt4ZVAie SHOP/ tHr, PL0N AND D S it E � ES .. 43 f 'i' t 5y' g..il' EACH FIXTURE SHALL az CONNECTEP TO THESE. LINCS.. THE MECHANICAL CONTRACTOR SHALL VERIFY INC , O.AT OH OE s IIIMO WASTE LIMES AND VENTS BEFORE STARTING INSTALLATION OF T r+. A NEW r.:' e UI i_S AND SHALL USE 7mesz AIRES IN ACCORDANCE HITE CITY C'D..O LEAD P/PF rtuRr aO LEdT .OH$ SHALL. RAVE PIPED JOINTS AMP Ftz,;4 CALKING FERRU t..ES° THE P Pr.e1..0 SYSTEM. . U.i'.ING GALVANIZED STEAL FIRING ING WITH ASPHALTUM PAIHOES CART '4 NINA( K F e_ c 9 ii `, j t Ex ^ DP USED - AT THE MECHANICAL F N .NcYCR NI ION. THE MINIMUM I'ITC"1,EOR _ 9:4,5 i:t' Mary 03t .IrlNc4 ,`SlitE1C ROT t4ss &: 94 p IN 8E. FULL SIZE BRASS ELETHOOT PLUGS SMALL. BE INSTALLED WHEREVER PIPES CHANGE atRECA ION O4( WHERE ORMTERL'nSE REQUIRED OOP THE PROPER CLEANING or ILL NEW PORTIONS or THE DRAINAGE SYSTEMS° LEd.N0Ib'E'S Its CONCEALED t ,.ayEe SOA..:. r ,TEkD THROUGH TNr WALL OR FLOOR ANO. SHALL NAVE CHROME PLAYED, , U3H !PE CAPS. CLEANOHTS IS FLOOR SHALL OE INSTALLED t3LAF A WALL,. 3. VENTS --C <A'CH TIUTUPE SHALL SE VENTED 9N COM?L II S@S tITN CITY CODE AND ORDINARCC LAND APPROVED BY THE lNSPIECTOR. VENTS HALLSE• RUN THROUGH THC ROOF,OF EELC CONNECTED TO A VENT STACK, OR CONNECT TO A SOI(. STACK .ABOVE THE HIGHEST FIXTURE. V,ENb"S SEfi A1L iL BE CAST IRON SOIL PeFF WIN OL.3.UM AND LEND CAL_EED JOINTS, OR GALVANIZED STEEL RIPE WITH GALVANIZED MALLEABLE FITa INGS. 4. Ft.ASHINGS--E.,CH PLa'M5ING VENT THROUGH THE ROOF SHALL HAVE A FLASHING 214" SQUARE? F19 TY A PLASHING COLLAR TUReED UP AROUND THE PIPE AND OVER AND I7TO PRE RIFE. PATCH ROOF. 5. WATER PIPING --FURNISH AND INSTALL THE COLD WATER AND NOV WATER- BRARCHES- ATM R1SF"i;S TO SUPPLY ALL HEW FIXTURES. CONNECT THE NOT AND COLD LINES TO SOURCE. 4 NSTALL A VALVE AND UN/ON IR EACH L INE° NNSTe t.,L A VALVE IN EACH BRANCH TO A FIXTURE, UNLESS LOOSE NY STOPS OR SCREWDRIVER .`TONE AR :N HOT&LL'ED AT THE FIXTURE° T SRRk- ti BE POSSIBLE To v SOLACEAN7 AX.7VE WHERE VALVES ARE rOHCOAi L'" IN j LI 'e i• ACC PSS DOORS. AE PLAT. ARTEG E TBE RUA LED . DT THE Cd?;('r.,o MART ADE.z S..E. CORMRCTOMB !TRT E9YTORPS. ,'. ,, PAR NG SHALL NE BEN AS OPREC T AS P0=E 'sB_.'r_. ND SN„ L.. B4 v ef3L ,,: F.f U4 F RASBEO ROOMS, 6, VAL. za- 4`At_WORuH OR ES FOR. OO rCS f . C WATER P t SRALL SE JRBK ES. P. ROC t.es. WOF` RS PRESSURE. pin..` feSU4:AT NSVEET I:Q di TH CAUVES COVER. NWA R P PEE�'w WITO t4 GLASS. & ; E xT:luR S--!i RL w!i AND FESTAEL THE , ''; 9 d'l RES SNOWB ON TZ e. '!FANS AND SF CiF k,D 4E TEE f MORE L3I. 45.T RG .P'A I.'R.M OM 4I;r !!'NEE AND EXPOSED PIP:Rr AL I4E , l' t..pP CHRONULN PLATED ESCOTNEENS. FEET g rvRomlumi PLATED, WITH A i.LrnxruArs S1,P I.C RR WF^;f o F'I:-.P:. F hXTUR'CS SMALL. MALLS ANN FLOORS CORD NCEE %HTM E LBANUFACTURERS E -:•i3 gin.. t`i1 EE Via., `s7' $vET rWG. RfZQU AFTER E XTDR•ES 4AVE EEEN SET TELL SRATA OC. cA EFSLLy P?OTSED.T UNTau_ TEIZ CIORR FAO BEEN ACCE_'TER, ANY DAMAGE OR DEFECT PRAETOR — HO BEFORE ACCEPTANCE SHALE BE MANE GOOD AT THE t lCMAN CAT CON— TRACTORS EXPENSE. AN AMERICAN -S At kRti i.;TURE I ,E;T is SHOWN, KOFEBR on CRANE. c;t1- TURES OF EQU.Ac T;?Sr SS"LL, CAPACTT AND FENISM ARE ACCCPTA.i$t I-:_, 9< FN&TURF LIST WC -4 WATER CLOSP T F— R.?..E MAD R.A S PROW „,A t ELONGATED SOWL WITH 21 TOP SPUD; F- 070 20" WALL. HUl✓HG TARN 4d 4 TANK COVER LOCK; N-3020 NON-SEFKOS EfG WATER CONTROL 2" OFFSE1 FLISM CONNCCTI[Or; #395 c uRcH WHITE Oink;; `RONT SEAT LESS „"OVER. L -I LAVATORY F-390-40 Igxf7 r lrrerLEID DoE*Reels cM,l,rA MALL HUNG LwVATORE ifl74 • ANTEGRkL CP.LBA— BRACKET—. N -2P07 P ER$TASE SWEET F lTTIUG WITH POP—UP WASTE —VANDAL PROOF AERATOR; R -2604—o 3/8" SPLV . .ES W4T4 STOPS TO WALL, R-7000 him CAST ASS P 'RAP €l7t CCLCANOU ; PROVIDE SINGLC BUP,S ER AS PAP7 OR COL"' WATER FAUCET. KIABING S3— Stt P-770 22"KI V CAST tRn $6'cta ,. i `^4@5n w% 1~<° RIM CIt tRD; ��7.� TRAPT. R -5O& FAUCET IVTR VACUUM BREAKER GUAnNT-WARRANTY—TRiS CONTRACTOR SERA L AND HEREBY DOES W ,RRRT AN1 7? , GZNC L CONTRACTOR SHALL AND HEREBY DOES GUARAN- TEE.TR T AL WORK v EcUT :D UNDER TE?'S PART SHALL BE FREE F' Om DE-. FECTS or :+.ATERIA15 AND WORT 63ANSNIP 1= OR is PERIOD OF ONE (t) YEAR FROM Tcn 4 QA 1 F: OF T- °. FINAL L ER i ;,1 E a VE ASOVa. PARTICS CS FEtR OER AGREE THAT 1Hl : WILL, AT Ti - R OWN ER_. p NS F REPAIR AND REPLACE ALL SUCH D" F .CT i VE WORK, AND AEA., C YHF:P 4XORii OAgx.,GE:D TH R`,.t , ki'!CH BECOMES OEFitC`F:VE DUR! G HE_ .1__RI O. *'U su R: N TY"icARR NTle. IRIS S GUARANTY-W;rWNTY DUES NOT APPLY 4 DEFECTS CAUSED BY 7RE FAILURE OF THE WORK OF OTRERS IF SUm DE FEETS WERE IMPOSa1GLE TO DETECT AT T MME OF TRE EXAMNATION •Y!ON OF THE aoRK OF THE OTHERS. 27 SE T fON E " PART E ZL E C; TR r CAL , Scop Or t OR#,— INE WORK C.{.s+ir-p. 'D BY TS "S SEC : gOE4 OF THS SPECI— FICATIONS CONSISTS Of URNS: �' 4tl -5 t: t`s AL L. A S O F .. E 0 di I P M E At 'a 0•S 4e P .P : J C S AND MATERIALS, IALS, S�NLCSS O>S ERWIS S IAND a PERFORM;NG ALL OPERAT€ltd, NECESSARS FOR THE S NST;i4,LL,T" ION OF Ti::: COMP ,ETE E .EC R y CAL CHANGES AS REQUIRED U£s33i~_.F{ THCSE SPEC I F I CAT lONS AND/oi>. SHOWN ON THE DRAof tttoS, SUBJECT TO THE TERMS AND COND t T EONS OF SV ' SONTRACT* 'FFE WORE: SHALL ALSO 2NCLUDE T'rtE COMPLETION OF SUCH MINOR D 4AjIS OF ELECTRICAL OR NOT MENTIONED OR SHOWN AS NECESSARY FOR SP E SUCCESSFUL OPERATION OF ALL ELE.CTRiCAL SYSTEMS DESCRDEO ON THE DRAWINGS OR REQUIRED BY THESE SSEC'FICAT'IONS, 2. WORK NOT $NCa.tki:JFD~"sF.'R7A If,': Li OR MATERIALS ANO/OR EQO r PMENT MAY BC FURN±m++EQ BY OTHERS., WHEN SUSH f5 Tt-Elr CASE, 3H^ EXgtwN:aa -SOftRCE AND QESCRIPTiOi'e OF. SiM+_: SHAt.k. Oi. AS INDICATED ON TOE DRAW— INGS OR AS OUTLINED IN T PI y:. SPEC P I CA T IOP:.S v GENERAL Run'A ERbi E,r:iS4—.`t-::r. GENERAL CONDITIONS AND SU '6}J..b'IsuE.N TARS GENERAL CONOI i POW$ OF THE CO€iTR. CT AND Ak..F-. OTHER REQUIRENw.E143S PRr'~ f bED SERETO FORM A PART OF TiJC.SE Sd=C.i:"fF(=A'TrOtdS �`..Ckd3 ASPST 70 ALL CONTRAc7S OR Siu'FiCONTR'CTS RELATING TO ELECTRICAL SSSTENSc DRAWINGS ` IKE V R AWJ.N'GS WHICH CONSTITVTE A PA O^F CONTRACT '� M V F' THIS INDICATE THE GENERAL ARRANGEMENT OF IRCU T4 AND OUTLETS, LOC-. AT IONSOP SWITCHES,, PANELBO&RDS AND OTSER WORK. THE DRAWINGS ARO SPECIFICATIONS b.R COMPLEMENTARY EACH TO HE OTHER, AND WHAT IS CALLED FOR 87 ONE SHAL . BE AS BINDING AS 4F GALLED FOR BY F3Os'H DATA PRESENTED ON THESE DRAWINGS A,RE AS A CUR TE AS PLANNING Cr N DETERMINE, BUT ACCURACY IS NOT GUARANTEED AND FIELD VER IF CS 1ON OF ALL DIMENSIONS IS DIRECTED, EXACT LOCATIONS, DSTANC ,S AND EVELS WELL BE GOVERNED E3i ACTUAL FIELD CONDITIONS.: THE CONTRACT- OR SHALL ALSO REVIEW_ ALL. PLANS -A-. Sa-A%Oki-U$ i k I S HORS TO CONFORM TO ALL CONDITIONS SHWON THEREIN. DE SSCBEpij1C I ES ShowN ON IP ≤F FERENT PLANS, OR BETWEEN PLANS AND SPECIFICATIONS, OR REG(LAT 1O +�;.� AND CODES GOVERNING G THE INSTALLATION SMALL BE BROUGHT TO THE ATTENTION OF THE ARC CT IN WRITING BESORE HE DATE OF SID OPENIMS STANDARDS FOR STERIAL AND }b r'-ORK k..NeSH4p — ALL .'4ATCR l4 S Cb A< BC NEW AND SHALL CONFORM WiTit THE asPFL C.ABELE. STANDARDS OF TI' Ff w UNDER— WRITERS LABORATORIES, Uf-e7 ?t3L(.°SS OTHERWISE If'tI'3iC.ATa"O'a AND NEA: APP'tirt's iANC E OF HE INSTALLATION St;.k.LL ?G; O EQUALWORKMAN— SHIP IMPORTANCE WITH ITS ELECTRICAL AND MECHANICAL EFFIC'I'CNCY. WHICH ARE DEFECTIVE T SHALL MA— TERIALS bEF VE GE REPLACED OR REPARED IN A- NAN{NER MEETING THE . •"PROVdsL OF THE ARCHITECT AND A7 NO ADDITIONAL COST TO THE OWNER* ANA/. BE USER ;I Pti 7:fE HAS BEEN 0074 R'EU 70!:fl, „ TO to 5NOD 07 OSIAP 'LLELFCLI tFTKUT ii r"U . . A O NU9AC;7UR L ° ., SURE OFEC?FS TEOF KA7 ?ROYAL C? O e ER €9 .TCR l AL 70 F JD OPENCDC ,F 'ATN,, SOERIFCA7ORF H E L A T -' V E 'I = .._ 'p.C. - COOTRACTOR - SR SHALL 057A6F AND PA`. FOR ALL P '5S A.N L IC<,:'.F9 w q. 1RA MW SHALE FUC.+t°: Sf, Pf TVIE ARC �.C P FOR =Py h c_=F CAT OF riN/=. 4,' _nC.°TT ou n F'PRCL'A FROM FP Loch O AUFRI .„D, F79104F OVAL E `L LICAL INSITTATOK. or ifi4 „WORN. TEE NCTPLIC.AI.. CONdFk_o R S ^LL .: a1C N.0 - A... wP iEP,,.. N' 't'FS7 07 NEW Ns . ON For Cr.Y.G;4+§45 S,T O -c OF rr--_ _ "€; T S5M7T6MG A SIIC, INS 'O€IUL C.+:`OR SHALL YIST THE F TES OF THN .dB AND SWAN IL FAMi..LLYmIZE XFOSFLF idITN ALL COMOu`Ii7F2., AL7FECTOG IRS ?m..OrO.i:NO ELECTRICAL 4NS AAT OI AMU SHALL MAKZ nROI 5ION. AS n 't•.('. C" "r. 33G'<REDF, GUARANTEE — IRE ER.!- .'6OF' 5'..r. C. ALAVA THE ENTIRE 4 LFCrt [:i'. SYSTEMS INSTALLED UNDER °t't'iS CO€3TRACT IN PROPER WORtfINO OPEUR ADD SMALL, WITHOUT AOrwITiO€„I. r, AoRCEr REPLACE ANY. WORK OP KA.7 AIL UL sEACNPT F,ETCP 9,° FUPN83°U .o 67 O MERSa WNEICNI DEVELOPS C1F,F'SCTS, EXCEPT FROM ORDINARY FYY:Ar. AND ''LaFE OR ABUSE, Vfl7H M on () „V VAR FROM THE DENTE OF A.cCCP E T(KP:RCEOFc NSURANCit — T '.` COKTR .7OR SHALL PROCURE AND MA€2TAINp A7 MI5 OWN EXPENSE, SCM LPAEIN!TY II HSURANCIC AND ANY OTHER INSURANCE REQOIRED 9Y LAW AND/GSP'I`ZCIF64.D fN THE GENERAL COND TIOtNS AS WAv p... PRATEC-7. HIM. AND. TME. OEWIHR AS REQUIRED. ABOVE, DELIVERY AND STORAGE 05 MfTERIA!'L — Ti CONTFCTOR SMALL MAt4E 6015 OWN PROVISIONS FOR INS DEL VARY AND SAFE STORAGE. OF '<!dS MATER EALS0 PROGRESS OF WONIc "" NNS CS "a?C TON :':HALL ORDER THE PROGRESS OF €iIS WORK SO A5 TO TONFO .N 70 LME, PROGRESS OF TOE WORK OF THE DINER TRADES,; nMD SNALAL ^..c OLZ? 'PF FN7BRE ENSTALLATIOto AS SOON AS THE COKDLTIOM OF 7M FULOIS SWILL P!LRMITo AHY COST P!ESUL7U40 FROM O F-c`'a,vN CR JL—Tzn:UP F'IERFOR&1IZD UKD'SR THIS SsCi'I€tN SHALL 5E HO'RN,E 57 TH FiTKCTRCAT (057RACTOR0 C UUTTTfi? It.... ADVANCE, `ff'IT.i'I, DE CAREFUL Y FAIIP OU7 IN •:P€f _ y=°'..+it.DE LE%Gy CHASSDG OR TR?LL. LIL OF SARY R lr cAR O LRtr .t4k° ANY TO3ylr_ fw`,' u- N TY WORK SHALL BE PktP.`.� t'. Sa CiJ,.L F EL' I;..?. c_ OF Item. TRADES YED AT NO ACa£` TiOLA'. COT <ONTRaCiOR S.Lt DO NO CU7 a NG., #J - UYFeS Qm. W D ,t OF. `s'E, cT9J". ¢+. ro?Lti:ssRs OF 7HE W,V!O— NGS CN?.. ESS HL FRSFRST OF,tt., r x T:€^. S'S ON FROM OM r ,e ANN N p 3 tEisT:; CC AWMORAGZ Yi'. 51 } BY : D OOS ,3 r :i HG, zQLIF'._ C.s.C`CCR, woou440.,`},^ OR 'Y5 Ct AN "'9 - THE CONTS0 C . S“LCON ,u'7C fir. d t'fl' WOVE ALVATERS7 SC P ETC. R7V 70 HS FLE7pC e. C .LEE&.. C-.%U''t, !ON 6E"¢ r Y4'6 IC CCe# r.{.C 0C S4 h.l HEW _ IL.CCft SCAB ;1GU0 PApLCI.ONS, FOR OF AL .i_ r9E+SIV li - . AND DUCTS iNS7&L 'LED +`7 °-. .tO E' .'JC„S rs'FGPCe1 HE OT Cr AF A SOFF C CCNT T Ia4.^' AND OF 74':e Cot •".'FA.;.TT ir.Pu Pq SO AS 40T CO 8 _ AF.. THAT WOR, a OF IL7 FAS o.NED IN ;sOC'Y$C?PSv :4T 5ICE E SCU h`4mOv'xOR R.`'L.Ow,.TCoN- ar. ..T+P°. iyf.ri 7. :; SUCH EXtS`IING CONOU T 011 §<`.tic reUFD f AS IINOiCAT'=O AND AS REQUIRE O ADAPT I.Fer ._I.w NGe E✓rECTR9C L SYSTgM;' TO THE NEW e;.Efi 7IO1t_. ...LFS'?.SL O'&i?'R CIS, CCNE4HTSPVf.RCSF OZTIC s, C'!CvsNLtip.'d BE REUSD „•, BTi r00O LR COCi?5TI N "i 6R IING SHALL. 4E CONT NUOUS FROM O€,5'nL.S T TO COIL CT g;.;2C SHALL BE ACCESi K` t6 EX JST4NG CONDVETn Dt4V P P.S .XT£r r°"tCCRR ETC., HOT REUSED SHALL €` TURNED OVER 70 THE OWNER., ORS eNOuSTP.V STA DARO THE COMP€E7,r 6NSTACL6,AT5ON SHAL CO19PLY WSTSF TeIE ff: Y'u"4.NC.AO4,r LOCAL AND. STATE 'A R545 ORORkANC':•.s, w' THE REOUt TJONS OC THE 4.. A,TESe F^?. "^N5 OF• THE NATJCMRIL. EL!ZCTCs IICMk. CODE OF THE NAJBOHAL BOARD OF F''6R'E eh'3SCARWRITCRS (S4rP'.FMFN7S AND OFFS :A DiTERPFBETATt OrrS 54x4. C!O ? AHD t$JTit THE RTQt RR'0t S OF THE POWER AND lEE'st"+°34r. E, C'h ,R ,, `a a fTflN5Sr`1Fi;:> S RViEESTO 1H I.5 3 I.ESTAV,C AT JON. Tri _T DRA'iNND !7D `?F' `'If.AT8O!S S€RALL Td,Kc PRECR— G'tRSCT' beiEN Ti "_7 ARI1 MORE 'S`r:I {Gc rg., d ',AN CODES, OR?i.HANCES, OR STATUTES SS lF iICYo A.PPLCDE COT, C.ROEHAUCES, S'Ar JDARPS C« STATUTES SHALL TkNE PRECEDED -CZ M.. I 9 ' ARE }',IORF a`'JR 4Gr 7 cut CONF ICT +e F" TAP..• PRALft2(45 ffl.. 44 3—VNRE ,OR Go :'O ALi; VC POWR 7, [� s4 flOVE SEInH.CE O "rr',E . . .e i .'. e - r,s' v F TO PEr pa,. PAP 5: JP ?.,A I F- F, Y S' SI T. DO AE 7 TYPED D iREC TORY C6k rA k THN. D s.•',F . k= O €',;CFH BRANCH ANCE- OASO, EAC& SEPARATITY tO ;"SY D r ,_ Nd .a„ “:E7, ST:,IT:TE.a> ETC,,, FOR A MOTOR OF FAXED ., F! N(E .... NE Iq Off, . r_ P ':, ;1 .-. OR APP 1, d s" Rg C', lip x TOLTAGEt, AND PS5Sc DEStlG &.TIrtFSz AMA0S TO 7 FT5 €5E. S!.'RDA,C€, OF T1". C0V:R# USJMG tr c „Ss OR META OR LA`. flS, FARE HPP1NG PAJSE1 11^5T E MOTOR OF PPFLIANCE SSE T tiOUS SMATT EU? ; N ACC0R +AH0IC N 'II THE DC x lGU, . ;0NS G E 1.1 ON 110MU?44U e AL OP APII T C TUR,,,r_ P„AF?S„ 0UDU I . .%VSTEM CONNECTIONS LO II5 laa� `iY;3`,C 4. STNG OLSU..D AND R€P.I R TO coroRM 70 N0TEVALET EL5C:'f R. , is ODE., ALT ,$f SEE aNSTA+ L .D SO As I,.C,a NA iTA f: A COMPLETE GROUNDED S'r .STL -can.. JUMPER sE E'.R AS R„QVi!P D 0 ;ll THROUGH - 6. SAFDT LNO D sC § 'C Sf l itids "r oR? s AND U ESTALL , it .(,:" SAFETY 3' uc"CKCS ATNE Hr_ O CRLOAD S;u;.TCHFE WHERE tND C„IT€'DQ HEREON SPEC -1 L. OD RECOA SD SAFETY S'1#ITCHES SHALL BEAR THEUNDERU'R t TERP I 1.4BET WITH EACH ENCLOSURE SE : NG or nit NEMA TYPE SU iI TA;B1E FOR THE SHHROUND I Eao AREA AND CO D T'IO4€'S o 7. BRANCH .EERCO37 P Ifi OO .APO --PANEL SHALL BR DEAD. FRONT ! U?llTC TYPE 5RE:AIULRS SHALL BE THE 1gLFECh—L T: "• BOLT —ON TS,'PE, (:CIRCUIT BREAHERS SHALT BE `KF'R AL hGHrTlC TYPE FMPTOY hlG QU'ECIa:— #CAKE AND QU CRC—SREFv11G ra CHIN19P$ FOR MANUAL OPERAT9ON AS VDEE AS AUTOMATIC OPCRATIQc. aUTO?A C 1YR4F uG SHALL BE IND4s;.ATED n' THE BREAKER HANDLE ASSU!nr3G A D[STU4CTIHE POSITION FROM TOE MANUAL "ON" AND "Orr". ALL MULTI —POLE BREAKERS SHALL HAVE A COMMON TRIP,. 5irht HANDLES efILL NOT HE FERF4STTEDO MANUFAC UR:ER AND TYPE OF PANS., SHALL SE. EQUAL `0 I'; ISTI1MG PANELS* PR0NB0E ppTYPED DIRECTORY CARDS IN RSRFCTQRY ..FU"^WIE OF PANELBOAR , Um RACEWAY •-••.PR0V D , FUa l0 CONPU I T, EL EC.7R ICAL b°: iETALL'?C TUBING,a id1!REMist,`F, OR OTHER TYPES EE ? <TT`,D AO DESCRUaII.J ryK `11S SECTION, FOP RACEWAYS CALED F0eR N T + Sr SPEC `FICrAT IONS OF OII THE DRAWINGS OR O50)OOSTY ,.LO I IE5, CONCEAL P&C?Ss "rU 4 'PALES, a_ d4` -≥x. AND FLOOR H R w: P POSSI BLL l.o PATSF DMEACES THUS D!', 5'P'f5T': sT-, PS`IE ' EXPOS PONS P HHK : CA, 1444''aF _tiC AR S PC '4' PARALLEL € rS OF ELALS, S7 AT 1,`L$T i E a,. FLEAS, RACEWAYS ENFCCER 7O WCAVREN CR iNS „_LED EN CONCRETE, CAPER, OR GRAVEL. SLLS, SHALL O_ pre o GALVANZED S"FEA CONDtA,? SOAKED a2?_ta Z NC Be AMY OF YK FOLACARSO . MH74OO$a 1 rs. =�d'f n'"D5; ga G, k`> P L r3 � SHARAF ZkJO` , OR MR T`. 'LL IZ . N`r '` TARCADS E` -., OF 9 E C`e7 PAVE A k isC COA .kHA R TF,F SARr,`.. £a '1 r q SKALL HAKE A Tr ,; =Nt'§ OF LACQUER, VAANMSR, OR ENAMEL TO rpov DC A SMOOTH PRALNG ¢ :.,' s+_. 4.1,L CORS '7S EN4 EPpRO o4'T(_,FT ROTES, CAB , GUTTERS, CAL,5 SHALLPE sROift!3€.O }.a'L!H DOODLE k -O Lx�ft '3 .. `Cd rye SM R S RACEWAYS CONCCALCS N CRIS RISS SA ATTR Oa LS P 5 - °.Y 3g AND k 1^p`A-.F X41 LEAST 5A&O @: ,_; CLOOK, RAOADRD AMUR ARRAS ARP OR7r rC IF;. Cg-. METALAR x O PS SUCH RUES RG.G S'PALF., BE GAi'tf':.N z"_9 0cy THE Z'iti;"`a of AND COATED OR TRE N&OS Wa H sA dP9OOaS WARD RUHSH OR LACQUER, AA,FLPis Sx,, OR ENAMEL,. ALL w F''EGS FOR tdt'k3 ;ft Nis SMALL SE OF THE COPPRASS ON OLAND OR ' 'iTOM C .z TRE; "CREMP ON" TYPO ATI'LOS Ai,,.L r,0O'6 BE A•LLO LIP., AS RtRE,N SP['C E E`,"., s«�_,:a c. t' / -. :t C' OF SUPPORTED eq4 APPROVED TYPES of WALL BRACKETS, CFARD'TRAPEZE PARSERS, OR MALLEABLE THE _ SSE OF PLUMBERS RS ALRPORATEO STR4p AS 'a '. : A •s or • ACT ai_.RERMOTT0F BRACKETS OR HANGERS SRALL L'^` EOil'.t;.G, e' 3 ° O ER -STRUT", OP fl;R S RUTfl CU WAYS OR FOUUFMtAT —6.k1 ^a L L R OTHER PIP SF$G SA7 &SALL SE SRE OR NG METHODS SMALL ER &ECHOED BY IRON STRAPSS. SUPPORT WLIL1L. • 7O F;'a.0 Ra "5G Sys ea FLCX SLE t4ETAl'.. COROUST or GRCE6.'A ILLo MAY DE iSE3 .M ,R RA,CFs:R„ WHER&-. EXTEND 4G i' RLPAG OWN THROUGH 4,,OLLOW PORTIONS OT *4ASOfUftl 7O OLfTP_ETS IN THE t<O ILLOW MASONRY WAILS OR MN R€ MdRgNG tS TO BE +6S'rfEO 6N EX!.ST NG RCMOL?Et.€„D AREAS,; 6ORT EXTEMS6Og4S OF FACXRBLF CONOIJ9T MAY SE USED FOR R<!tKft?G UP MOTOR OR EQUIPMENT CONNPECYLONS AND FOR REk-.OCAAT ON OF L HT+NG FlXTURESe 9. W'tlRE--MNiMU1M SazE No0 E2 EYCEPT FOR CONTROL ClRCIJkTC "VI`CFR MAY BE Noo 041 OR StG?iLC CIRCUITS w'RICN SHALL BE: .AS BNDICAMY, CONDUCTOR «NSULAiTdON SHALL 8f', OF TYPE. kr- O-GNI-aEO- Fi-Y. TR NEC Ai. APPROVED FOR 6963 PART RCUL.,R AFPPL fCAT ION, WO, SUPPORTS AND 'iA u'GrR--GAL a6CC`"k,AYSp C,ABfNET5p, BOXES, e r..XSURG.S, FTC,, SHALL BE F,slaPORTPO =:PO 6E. 6GNED RN AN APPROVED MANNER 4NO T_es FROM STEAM,. WA,T t., OR AGENT„. , ;.,O•RT OLE BOTTS UP FLO rO'Aa- EL, ,,;T R a4(_ _Ag R7a :;}p r:xh s:0 F;t)! f`> .is ,,:.O2C F�t7K: &?%•, H•".NE "03. 'S,f S'�:.R,."W.li- OR ON M'C.T L 5VRFCS A6 WOOD Ck.,,:WS CM WOOD COiiiS1RUi, "rE:Iii. It LE OR CisNPC_pORS Sf3 :LL BS; c.'POR t N AC•COROAOCw.. WI7H me pRE'.C8YIREt,fEK;T$ or THE {EC o,UNCTION eiO£? PULL BOX.E —UNC 6 ''O1. ' t UL iiOAfS NO OYR °5O cLIB;C yNCH S IN SIZ . 5F'A' L D`P ONSTR CTE.D AS STANDARD OUTLET BOXES. 1Jt4 CTiON DR PULL BOXES OVER i50 C.f4BIC INC0t$ IN S Z': SHALL BE CONSTPLcCD SAME AS L`:r E!NE1S q# fH COVERS old FF SME GAOGC RETA‘ AND SECURED EY SCREWS OR BOLTS. REMOVABLE COMBS t4UST RE CCESSES .E AT fi: L Y:K:GC- .OES ON CONCE:c; t'D COf L3!b;.T S.t,k,P L. s SET kHHTR COVERS FLOC`'#.c 6a"< 3iF FNS .g;R�tii.C. '. i.?TaE.0 •?yXC`. :Or: AS PULL BOXES OF APPROPRt'dIE O6MENSONS FOR CONDUITS .tJ0 f,`•.S}N;V ORS NOTED SKALL Cs. tNS,TA LD WHER2.MCCESSART OR CONVF'NMf'AP :U— ST•AL.e,A T ION OP W ! FihS OR tim> e..e SHOWN ON T E !,RAVING=. i2o OUTL S_^-0UTh�e..sS SAL a s ► ELF OR OCT GONAL SHEE S 'E&L BOXES AS REQUIRED' W'. Let UT LI'{"o` OR S .C'r aONALr aESL T :i BOXES ci Ae:• PF;PP' T T D CONFIRM MOUNTING are C.4HTs .W !';C ARCHITECT. I3o DEEtCEES--`P<EEF'.ArkEss (or) SNAIL BE; T"SE0T, SPE'4f>F 4 ON GRADE; GROUNDING Tk'I"E'r, BRYANT 525a WHERE ;NO4CAlYi:'D a:o WALKER KE.R 5i3 AL.-DPS--G HIGH isostO- F TTaRG AND brhLr,ER 5O$ Ate Low T NSiow FITTING. S'' n TCF E5 SHALL BE; ftt`;.C, QtH C' OPERATING TYPE EOUAL TO BRYANT #'8o So -;R S IVORY. DEVICE PLATES SHALL BE IVORY C RACC.L'� METAL. j o 1.. GH7 iG f XT'CrRBS--F[RNISH AND NST'rL nCw i{GtiTiNG ittleTFRFS COMPETE W ifs LAMPS WHERE SHOWN ON TH DRAWINGS AND. AS DCSCR tl`.6EQ IN THE !XSurc scnnik.D-4/Lt AND/OR WOTESt PROVIDE PLASTER FRAME'S FOR RECESSED F'?XTtiRE'S•, REMOVE AND RE-1NST ,LL EXIS7I G LIGHTING FIX" ' TURES HERE INDI4 i"Oo 5. MEc HANtcak:: EQU y'ME≥:JT WIRIUG ANO CO ti ? CY IONS-- CCRAMICF':s, EQUIPP WT MOTORS AND CONTROLS FURNIS4s6'E= WITH V, CHAN4CPl. h:QUIPMF'FfT. INSTAL FEEDER C ? RCt f TS TO MFCRAP 'r• GAF. rat) PNE:NT AND a4, 1" E ALL COr — NfC T iOIiS. FURNISH AND f. NST,f4 E T''P tvC.a SAFES`•` S'ik @ ac4+.F'S hNO/OR Tk► RM4L OVERLOAD S ' T C 4 S AS R2QuhRD, eb E+NaERGE�aG''ca.'�iA EXIT S^.'SE,::.q{ f;: EEN5 E, IS7aNG ,Fri.Ca'.SrHC.a' . ND EXIT `7 i S YTEm m m0QCLOci s"S H}'O fly A WARRANT a,<H TE mr! A ' e X «n> FCIOF kt S w,wva«: w»m TF DA7 o »: » c: cvn *604 a « «, w «E, PENS, :a aw wwa, Tnvr aE CUP FCTS a « aw;s » ar rc OTRS. s Du F w«:ae rcw<DOES ow 7 w y: r« E a,a seer,« (2 x:m , Al THE HRt « s VF WORK, /4,a c OUNNG OTSS mr:ase,C Hello