HomeMy WebLinkAbout990973.tiff ACQRD„ CERTIFICATE OF LIABILITY INSURANCE PAGE , QF z 2i APR 1999
PRODUCER 27689 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION
Willis Corroon Corporation of Kansas ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE
3OO West Douglas HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR
P.O. Box 2697 ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.
Wichita KS 672O1-2697 COMPANIES AFFORDING COVERAGE
(316)264-5311
COMPANY National Union Fire Insurance Company of Pitt
Leeanna Herman,AU,CISR,CPIW A
INSURED COMPANY United States Fire Insurance Company
B
COMPANY New Hampshire Insurance Company
Dustrol,Inc.
PO Box 3O9
Towanda KS 67144O3O9 COMPANY
I 0
COVERAGES
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED, NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
CO POLICY EFFECTIVE POLICY EXPIRATION
LTR TYPE OF INSURANCE POLICY NUMBER DATE(MMIDD/YV) DATE(MM/DD/VY) LIMITS
A GENERAL LIABILITY GL9330052 01-MAY-1998 O1-MAY-1999 GENERAL AGGREGATE $ 2.000,000
X COMMERCIAL GENERAL LIABILITY PRODUCTS-COMP/OP AGG $ 2,000,000
__f CLAIMS MADE X OCCUR PERSONAL S ADV INJURY $ 1,000,000
OWNER'S&CONTRACTOR'S PROT EACH OCCURRENCE $ 1.000,000
FIRE DAMAGE(Any one tire( $ 100,000
I MED EXP(Any one person) $ 5,000
A I AUTOMOBILE LIABILITY CA826OO32 TX O1-MAY-1998 O1-MAY-1999
COMBINED SINGLE LIMIT $ 1,000,000
A X ANY AUTO CA826OO3O O1-MAY-1998 O1-MAY-1999 _ALL OWNED AUTOS BODILY INJURY
r _ SCHEDULED AUTOS (Per person)
X HIRED AUTOS BODILY INJURY $
X NON-OWNED AUTOS (Per accident)
- PROPERTY DAMAGE I$
GARAGE LIABILITY AUTO ONLY-EA ACCIDENT $
ANY AUTO OTHER THAN AUTO ONLY.
EACH ACCIDENT
AGGREGATE $
B EXCESS LIABILITY 553060894 01-MAY-1998 O1-MAY-1999 EACH OCCURRENCE $ 2.000.000
X UMBRELLA FORM AGGREGATE $ 2.000.000
OTHER THAN UMBRELLA FORM $
C WORKERS COMPENSATION AND RMWC7O81811 O1-MAY-1998 O1-MAY-1999 WCRVUM(ITS 0TH-
EMPLOYERS'LIABILITY EL EACH ACCIDENT $ 500.000
THE HERS/ XECU X INCL EL DISEASE-POLICY LIMIT $ 500.000
PARTNERS/EXECUTIVE
OFFICERS ARE: EXCL EL DISEASE-EA EMPLOYEE $ 500,000
OTHER
DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES/SPECIAL ITEMS
SEE ATTACHED
CERTIFICATE HOLDER CANCELLATION EXa*P110 Days For Nonpaynram
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE
EXPIRATION DATE THEREOF, THE ISSUING COMPANY WILL IE%Gdpab,LY VW MAIL
3O DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT,
The Board of Weld County Commissioners BUT FAI TO I N TICE SH L IMPOSE NO OBLIGATION OR LIABILITY
P.O.Box 758 ANY U N E PA ITS AGENTS OR REPRESENTATIVES.
Greeley CO 80632 A TH•: R ES TAT E
AC0RD 25-S 01195) G EN ERAIAI ',4
/Z„,,„e„$ £2t24ncte,, os/0.3/RR 990973
Lus WCDAIRDON CERTIFICATE OF INSURANCE - ISSUE DATE(MM/DDNY)
I mut 2OF 2 21-APR-1999
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE
HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.
INSURED 27689
PRODUCER
Willis Corroon Corporation of Kansas
300 West Douglas
P.O. Box 2697
Dustrol,Inc. Wichita KS 67201-2697
PO Box 309 (316)264-5311
Towanda KS 67144-0309
Leeanna Herman,AU,CISR,CPIW
COVERAGES
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED, NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS MAY HAVE BEEN REDUCED BY PAID CLAIMS.
POLICY EFFECTIVE POLICY EXPIRATION TYPE OF INSURANCE POLICY NUMBER DATE(MM/DD/YY) DATE(MM/DD/VV) LIMITS
DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES/SPECIAL ITEMS
RE: 1999 Asphalt Milling Contract
Weld County, Colorado , by and through the Board of County Commissioners of
Weld County, its employees and agents are additional insureds as respects to
the general liability policy. This is regarding work performed by the named
insured on the above referenced project .
CERTIFICATE HOLDER CANCELLATION E%cepl 10 Days For Nonpayment
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE
EXPIRATION DATE THEREOF, THE ISSUING COMPANY WILL natIVVOIX* MAIL
30 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT,
The Board of Weld County Commissioners BUT FAIL TO N TICE SH L IMPOSE NO OBLIGATION OR LIABILITY
P.0.Box 758 ANY M NV, S AGENTS OR REPRESENTATIVES.
Greeley CO 60632 UTH N! RE T IV
I ..
WILLIS CORROON 25WO1 i9p95) cGENERAIAI WILLIS CORROON 1995
•
THE AMERICAN INSTITUTE OF ARCHITECTS
•.fY:'jj•u. Bond if: 82933445
AIA Document A312
Performance Bond
Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable.
CONTRACTOR (Name and Address): SURETY (Name and Principal Place of Business):
Dustrol, Inc. Reliance Insurance Company
P.O. Box 75190 Three Parkway
Colorado Springs, CO 80907 Philadelphia, PA 19102
OWNER (Name and Address):
The Board Of Weld County
Commissioners
P.O. Box 758
Greeley, CO 80632
CONSTRUCTION CONTRACT
Date: April 14, 1999
Amount: $14,204.10
Description (Name and Location): 1999 Asphalt Milling Contract.
BOND
Date (Not earlier than Construction Contract Date): April 21, 1999
Amount:Fourteen Thousand Two-Hundred Four and 10/100
Modifications to this Bond: None See Page 3
CONTRACTOR AS PRINCIPAL SURETY
Company: (Corporate Seal) Company: (Corporate Seal)
Dustrol, Inc. /" Reliance Insurance Company
Signature: rf� " l/O-p`n---a- --- Signature:
Name and Title: Brian Hansen Name and Titl -
Vice-Pres. Operations Kathleen A. Snyder , Attorney-In-Fact
(Any additional signatures appear on page 3)
(FOR INFORMATION ONLY-Name,Address and Telephone)
AGENT or BROKER: OWNER'S REPRESENTATIVE (Architect, Engineer or
Willis Corroon Corporation of other party):
Kansas
300 West Douglas
P. O. Box 2697
Wichita, KS 67201-2697
WC-1852A ' PERFORMANCE BOND AND PAYMENT BOND • DECEMBER 1984 ED. - AIA
THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE., N.W., WASHINGTON, D.C. 20006 A312-1984 1
THIRD PRINTING • MARCH 1967
1 The Contractor and the Surety, jointly and severally, .1 After investigation, determine the amount for
bind themselves, their heirs, executors, administrators,suc- which it may be liable to the Owner and, as soon
cessors and assigns to the Owner for the performance of as practicable after the amount is determined,
the Construction Contract, which is incorporated herein by tender payment therefor to the Owner;or
reference.
.2 Deny liability in whole or in part and notify the
2 If the Contractor performs the Construction Contract, Owner citing reasons therefor.
the Surety and the Contractor shall have no obligation
under this Bond, except to participate in conferences as 5 If the Surety does not proceed as provided in
provided in Subparagraph 3.1. Paragraph 4 with reasonable promptness, the Surety shall
be deemed to be in default on this Bond fifteen days after
3 If there is no Owner Default, the Surety's obligation receipt of an additional written notice from the Owner to the
under this Bond shall arise after: Surety demanding that the Surety perform its obligations
under this Bond, and the Owner shall be entitled to enforce
3.1 The Owner has notified the Contractor and the any remedy available to the Owner. If the Surety proceeds
Surety at its address described in Paragraph 10 below as provided in Subparagraph 4.4, and the Owner refuses
that the Owner is considering declaring a Contractor the payment tendered or the Surety has denied liability, in
Default and has requested and attempted to arrange a whole or in part, without further notice the Owner shall be
conference with the Contractor and the Surety to be entitled to enforce any remedy available to the Owner.
held not later than fifteen days after receipt of such
notice to discuss methods of performing the Construc- 6 After the Owner has terminated the Contractor's right to
Lion Contract. If the Owner, the Contractor and the complete the Construction Contract, and if the Surety elects
Surety agree, the Contractor shall be allowed a to act under Subparagraph 4.1, 4.2, or 4.3 above, then the
reasonable time to perform the Construction Contract, responsibilities of the Surety to the Owner shall not be
but such an agreement shall not waive the Owner's greater than those of the Contractor under the Construction
right, if any, subsequently to declare a Contractor Contract, and the responsibilities of the Owner to the
Default; and Surety shall not be greater than those of the Owner under
the Construction Contract. To the limit of the amount of this
3.2 The Owner has declared a Contractor Default and Bond, but subject to commitment by the Owner of the
formally terminated the Contractor's right to complete Balance of the Contract Price to mitigation of costs and
the contract. Such Contractor Default shall not be damages on the Construction Contract, the Surety is
declared earlier than twenty days after the Contractor obligated without duplication for:
and the Surety have received notice as provided in
Subparagraph 3.1; and 6.1 The responsibilities of the Contractor for correction
of defective work and completion of the Construction
3.3 The Owner has agreed to pay the Balance of the Contract;
Contract Price to the Surety in accordance with the
terms of the Construction Contract or to a contractor 6.2 Additional legal, design professional and delay
selected to perform the Construction Contract in ac- costs resulting from the Contractor's Default, and result-
cordance with the terms of the contract with the Owner. ing from the actions or failure to act of the Surety under
Paragraph 4;and
4 When the Owner has satisfied the conditions of
Paragraph 3, the Surety shall promptly and at the Surety's 6.3 Liquidated damages, or if no liquidated damages
expense take one of the following actions: are specified in the Construction Contract, actual
damages caused by delayed performance or nonperfor-
4.1 Arrange for the Contractor, with consent of the mance of the Contractor.
Owner, to perform and complete the Construction Con-
tract; or 7 The Surety shall not be liable to the Owner or others for
obligations of the Contractor that are unrelated to the Con-
4.2 Undertake to perform and complete the Construc- struction Contract, and the Balance of the Contract Price
tion Contract itself, through its agents or through inde- shall not be reduced or set off on account of any such unre-
pendent contractors;or lated obligations. No right of action shall accrue on this
Bond to any person or entity other than the Owner or its
4.3 Obtain bids or negotiated proposals from qualified heirs,executors,administrators or successors.
contractors acceptable to the Owner for a contract for
performance and completion of the Construction Con- 8 The Surety hereby waives notice of any change,includ-
tract, arrange for a contract to be prepared for execu- ing changes of time, to the Construction Contract or to re-
tion by the Owner and the contractor selected with the lated subcontracts,purchase orders and other obligations.
Owner's concurrence, to be secured with performance
and payment bonds executed by a qualified surety 9 Any proceeding, legal or equitable, under this Bond
equivalent to the bonds issued on the Construction may be instituted in any court of competent jurisdiction in
Contract, and pay to the Owner the amount of damages the location in which the work or part of the work is located
as described in Paragraph 6 in excess of the Balance of and shall be instituted within two years after Contractor
the Contract Price incurred by the Owner resulting from Default or within two years after the
the Contractor's default; or Contractor ceased working or within two years after the
Surety refuses or fails to perform its obligations under this
4.4 Waive its right to perform and complete, arrange Bond, whichever occurs first. If the pro-
for completion, or obtain a new contractor and with visions of this Paragraph are void or prohibited by law, the
reasonable promptness under the circumstances: minimum period of limitation avail-
WC-1652B • PERFORMANCE BOND AND PAYMENT BOND • DECEMBER 1984 ED. • AIA OB
THE AMERICAN INSTITUTE OF ARCHITECTS,1735 NEW YORK AVE.,N.W.,WASHINGTON. D.C.20006 A312-1984 2
THIRD PRINTING • MARCH 1987
able to sureties as a defense in the jurisdiction of the suit any amounts received or to be received by the Owner in
shall be applicable. settlement of insurance or other claims for damages to
which the Contractor is entitled, reduced by all valid and
10 Notice to the Surety, the Owner or the Contractor shall proper payments made to or on behalf of the Contractor
be mailed or delivered to the address shown on the signa- under the Construction Contract.
ture page.
12.2Construction Contract: The agreement between the
11 When this Bond has been furnished to comply with a Owner and the Contractor identified on the signature
statutory or other legal requirement in the location where page, including all Contract Documents and changes
the construction was to be performed, any provision in this thereto.
Bond conflicting with said statutory or legal requirement
shall be deemed deleted herefrom and provisions conform- 12.3Contractor Default: Failure of the Contractor, which
ing to such statutory or other legal requirement shall be has neither been remedied nor waived, to perform or
deemed incorporated herein. The intent is that this Bond otherwise to comply with the terms of the Construction
shall be construed as a statutory bond and not as a com- Contract.
mon law bond.
12.4Owner Default: Failure of the Owner, which has
12 DEFINITIONS neither been remedied nor waived, to pay the Contrac-
tor as required by the Construction Contract or to per-
12.1 Balance of the Contract Price: The total amount form and complete or comply with the other terms
payable by the Owner to the Contractor under the Con- thereof.
struction Contract after all proper adjustments have
been made, including allowance to the Contractor of
MODIFICATIONS TO THIS BOND ARE AS FOLLOWS:
(Space is provided below for additional signatures of added parties,other than those appearing on the cover page.)
CONTRACTOR AS PRINCIPAL SURETY
Company: (Corporate Seal) Company: (Corporate Seal)
Signature: Signature:
Name and Title: Name and Title:
Address: Address:
WC-1853A • PERFORMANCE BOND AND PAYMENT BONG • DECEMBER 1984 ED. • AIA OB
THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE., N.W., WASHINGTON, D.C. 20006 A312-1984 3
THIRD PRINTING • MARCH 1987
THE AMERICAN INSTITUTE OF ARCHITECTS
*il��,lj�
d\,:,4 . L
�- -,f.=i.. Bond#: B2933445
...�uPlyf--
AIA Document A312
Payment Bond
Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable.
CONTRACTOR (Name and Address): SURETY (Name and Principal Place of Business):
Dustrol, Inc. Reliance Insurance Company
P.O. Box 75190 Three Parkway
Colorado Springs, CO 80907 Philadelphia, PA 19102
OWNER (Name and Address):
The Board Of Weld County
Commissioners
P.O. Box 758
Greeley, CO 80632
CONSTRUCTION CONTRACT
Date: April 14, 1999
Amount: $14,204.10
Description (Name and Location): 1999 Asphalt Milling Contract.
BOND
Date (Not earlier than Construction Contract Date): April 21, 1999
Amount;Fourteen Thousand Two-Hundred Four and 10/100
Modifications to this Bond: n None n See Page 6
CONTRACTOR AS PRINCIPAL SURETY
Company: (Corporate Seal) Company: (Corporate Seal)
Dustxol, Inc. Reliance Insurance Company
Signature: / < t Signature:
Name an 1 itle: Brian Hansen Name and Title
Vice-Pres. 0era1107�S Kathleen A. Snyder / Attorney-In-Fact
(Any additional signatures appear oh page l)
(FOR INFORMATION ONLY-Name,Address and Telephone)
AGENT or BROKER: OWNER'S REPRESENTATIVE (Architect, Engineer or
Willis Corroon Corporation of other party):
Kansas
300 West Douglas
P. O. Box 2697
Wichita, KS 67201-2697
WC-1853B ' PERFORMANCE BOND AND PAYMENT BOND • DECEMBER 1984 ED. - AIA
THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE., N.W., WASHINGTON, D.C. 20008 A312-1984 4
THIRD PRINTING • MARCH 1987
1 The Contractor and the Surety, jointly and severally, 6 When the Claimant has satisfied the conditions of
bind themselves, their heirs, executors, administrators,suc- Paragraph 4, the Surety shall promptly and at the Surety's
cessors and assigns to the Owner to pay for labor, expense take the following actions:
materials and equipment furnished for use in the perfor-
mance of the Construction Contract, which is incorporated 6.1 Send an answer to the Claimant, with a copy to the
herein by reference. Owner, within 45 days after receipt of the claim, stating
the amounts that are undisputed and the basis for chal-
2 With respect to the Owner, this obligation shall be null lenging any amounts that are disputed.
and void if the Contractor:
6.2 Pay or arrange for payment of any undisputed
2.1 Promptly makes payment, directly or indirectly, amounts.
for all sums due Claimants, and
7 The Surety's total obligation shall not exceed the
2.2 Defends, indemnifies and holds harmless the amount of this Bond, and the amount of this Bond shall
Owner from claims, demands, liens or suits by any be credited for any payments made in good faith by the
person or entity whose claim, demand, lien or suit is Surety.
for the payment for labor, materials or equipment fur-
nished for use in the performance of the Construction 8 Amounts owed by the Owner to the Contractor under
Contract, provided the Owner has promptly notified the Construction Contract shall be used for the perfor-
the Contractor and the Surety (at the address mance of the Construction Contract and to satisfy claims,
described in Paragraph 12) of any claims, demands, if any, under any Construction Performance Bond. By the
liens or suits and tendered defense of such claims, Contractor furnishing and the Owner accepting this Bond,
demands, liens or suits to the Contractor and the they agree that all funds earned by the Contractor in the
Surety, and provided there is no Owner Default. performance of the Construction Contract are dedicated
to satisfy obligations of the Contractor and the Surety
3 With respect to Claimants, this obligation shall be null under this Bond, subject to the Owner's priority to use
and void if the Contractor promptly makes payment, directly the funds for the completion of the work.
or indirectly, for all sums due.
9 The Surety shall not be liable to the Owner,
4 The Surety shall have no obligation to Claimants under Claimants or others for obligations of the Contractor that
this Bond until: are unrelated to the Construction Contract. The Owner
shall not be liable for payment of any costs or expenses
4.1 Claimants who are employed by or have a direct of any Claimant under this Bond, and shall have under
contract with the Contractor have given notice to the this Bond no obligations to make payments to, give
Surety (at the address described in Paragraph 12) notices on behalf of, or otherwise have obligations to
and sent a copy, or notice thereof, to the Owner, Claimants under this Bond.
stating that a claim is being made under this Bond
and, with substantial accuracy, the amount of the 10 The Surety hereby waives notice of any change, in-
claim. cluding changes of time, to the Construction Contract or
to related subcontracts, purchase orders and other
4.2 Claimants who do not have a direct contract with obligations.
the Contractor:
11 No suit or action shall be commenced by a Claimant
.1 Have furnished written notice to the Contractor under this Bond other than in a court of competent juris-
and sent a copy, or notice thereof, to the diction in the location in which the work or part of the
Owner, within 90 days after having last per- work is located or after the expiration of one year from
formed labor or last furnished materials or the date (1) on which the Claimant gave the notice re-
equipment included in the claim stating, with quired by Subparagraph 4.1 or Clause 4.2.3, or (2) on
substantial accuracy, the amount of the claim which the last labor or service was performed by anyone
and the name of the party to whom the or the last materials or equipment were furnished by
materials were furnished or supplied or for anyone under the Construction Contract, whichever of (1)
whom the labor was done or performed; and or (2) first occurs. If the provisions of this Paragraph are
void or prohibited by law, the minimum period of limita-
.2 Have either received a rejection in whole or in tion available to sureties as a defense in the jurisdiction
part from the Contractor, or not received within of the suit shall be applicable.
30 days of furnishing the above notice any
communication from the Contractor by which 12 Notice to the Surety, the Owner or the Contractor
the Contractor has indicated the claim will be shall be mailed or delivered to the address shown on the
paid directly or indirectly; and signature page. Actual receipt of notice by Surety, the
Owner or the Contractor, however accomplished, shall
.3 Not having been paid within the above 30 be sufficient compliance as of the date received at the
days, have sent a written notice to the Surety address shown on the signature page.
(at the address described in Paragraph 12)
and sent a copy, or notice thereof, to the 13 When this Bond has been furnished to comply with
Owner, stating that a claim is being made a statutory or other legal requirement in the location
under this Bond and enclosing a copy of the where the construction was to be performed,
previous written notice furnished to the Con- any provision in this Bond conflicting with said stet-
tractor. utory or legal requirement shall be deemed deleted
herefrom and provisions conforming to such statutory or
5 If a notice required by Paragraph 4 is given by the other legal requirement shall be deemed incorporated
Owner to the Contractor or to the Surety, that is sufficient herein. The intent is that this
compliance.
WC-1853C • PERFORMANCE BOND AND PAYMENT BOND • DECEMBER 1984 ED. • AIA®
THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE., N.W., WASHINGTON, D.C. 20006 A312-1984 5
Bond shall be construed as a statutory bond and not as a architectural and engineering services required for per-
common law bond. formance of the work of the Contractor and the Contrac-
tor's subcontractors, and all other items for which a
14 Upon request by any person or entity appearing to be a mechanic's lien may be asserted in the jurisdiction
potential beneficiary of this Bond, the Contractor shall where the labor, materials or equipment were furnished.
promptly furnish a copy of this Bond or shall permit a copy
to be made. 15.2 Construction Contract: The agreement between
the Owner and the Contractor identified on the signa-
15 DEFINITIONS ture page, including all Contract Documents and
changes thereto.
15.1 Claimant: An individual or entity having a direct
contract with the Contractor or with a subcontractor of 15.3 Owner Default: Failure of the Owner, which has
the Contractor to furnish labor, materials or equipment neither been remedied nor waived, to pay the Contrac-
for use in the performance of the Contract. The intent of tor as required by the Construction Contract or to per-
this Bond shall be to include without limitation in the form and complete or comply with the other terms
terms "labor, materials or equipment"that part of water, thereof.
gas, power, light, heat, oil, gasoline, telephone service
or rental equipment used in the Construction Contract,
MODIFICATIONS TO THIS BOND ARE AS FOLLOWS:
(Space is provided below for additional signatures of added parties,other than those appearing on the cover page.)
CONTRACTOR AS PRINCIPAL SURETY
Company: (Corporate Seal) Company: (Corporate Seal)
Signature: Signature:
Name and Title: Name and Title:
Address: Address:
WC-1853D ' PERFORMANCE BOND AND PAYMENT BOND • DECEMBER 1984 ED. ' AIA
THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVE„ N.W., WASHINGTON. D.C. 20006 A312-1984 6
THIRD PRINTING MARCH 1987
THE FACE •FTHIS I•CUMENTH,SAC•L•-E• -ACKG••UN• •N WHITE •A•E-
RELIANCE SURETY COMPANY RELIANCE INSURANCE COMPANY
UNITED PACIFIC INSURANCE COMPANY RELIANCE NATIONAL INDE I Y COMPANY
ADMINISTRATIVE OFFICE, PHILADELPHIA, PENNSYLVANIA
POWER OF ATTORNEY
KNOW ALL MEN BY THESE PRESENTS, that RELIANCE SURETY COMPANY is corporation duly organized under the laws of the State of Del-
aware, and that RELIANCE INSURANCE COMPANY,and,UNITED PACIFIC"I�lSURANCE COMIIANY,;ere corporations duly organized under the laws
of the Commonwealth of Pennsylvania and that RELIANCE NATIONAL.inoem ICOMPANY is a,corporation duly organized under the laws of
the state of Wisconsin therein collectively oalled *the Companies") and that the C es by,,vj a of signature end seals do hereby make,
constitute end appoint David W. Danner, Dorothea,p Hanleon Kathleen 4, Snyder, Bald D Deutsch,Tim H. HeffN,Marcia Frazier, Marilyn A.
Dugan, Donald R. Wesson., of Wichita. Kaneas their true and lawful Attorney(shin- act, to make, execute, seal and deliver for and on their
behalf, and as their act and deed any end ell bonds and undertakings of suretyship end to bind the Companies thereby as fully and to the same
extent as if such bonds and undertakings end other writings obligatory in the nature thereof were signed by an Executive Officer of the Companies
and sealed and attested by one other of such officers,end,hereby ratifies and confirms all that their said Attorney(sl-in.Fact may do in pursuance
hereof.
This Power of Attorney is granted unndper,end by the authority of Article VII of the B of Illy-Laws RE IANCE SURETY COMPANY,
RELIANCE INSURANCE COMPANY, UNITED PACIFIC INSURANCE COMPANY, and RELIANCE NATIONAL INDEMNITY COMPANY which
provisions are now in full force and effect, reeding as follows:
ARTICLE VII•EXECUTION OF"ONO"AND.teDERTAIONOS
1. The Coed cf Directors,the President,the Chairman of the Bed,any senor Vice Prlelds t.atg(lie:..llr}•idee o Aeeetent Vrce Pre ideal or other officer Senate by the Board of
Onectore lace here pews end ashore to fill aeponl AttomeyteHnFeet and to autheve Or to execute on Shelf d*ti Co n•a,,bone aid udonakines,recodnitencee,armada of weenie
end other vit4tlei obligatory in the nature thereof,and IS to remove any such AttareleheFeft atfiry time ed steep the power lord etatenty given to then.
2. AttarneyaHnFect shed have Power WS authority,sublet to the terms end beetles of the Power af Attorney Se to them, to execute deliver an behef of the Company,bonds
and undertakings. rseagneencss,linen of h,dern ity and other writings°bea ty in the nature thereat. The creme eea a net necessary for the validity of enY bads ad undertakes.
rseagw;MCes,contracts of indemnity and other weeps in the Mtlee thereof.
3. Attemel*l•inFed Mai have peer end akhane:to execlad anid •FJnie retie t to p nyaid to bands resoreaaweo careen d e r,wiry ecede tion the e or eolgatav
undptNWlq oral they eriveahee nee Pmvr end e;Aftarhty to a..tlfy ae snanF'a tt°a'drr,ex of the Company and to aeon of the fly-Laws a the Centime a only artieyr or section Mae..
This Pow..Attorney is seed and Sere by fatenile Liner And by sinhenty of the following resolution Sowed by the.Exeoubve and Penes Convene of the beds of Directors of Rolience
Inerear,ce Company, United Pacific Insurance Convert and Rohn,*National Indemnity Company by Unanimous Cement dieted is of February 2e, lee and by the Executive and Finance
Committee of the board of DkMare of Reline Surety Company by Uneemow Carwerd dated as of Such 91.1994.
'Restated that the agnetrses of such deers ant officers aid the sea of the Xemerpt•may Dtligniei to sr air eted,Power ii Attorney Or any certalcates relating theme by
feamlg.ad any such Peer of Attorney et certifies'beer. KC facuimde egne�tteed��r fat mile ieee th d be pee el binder an nd any such Company owh Power se
executed
d certified by facsimile
signatures end Imes seal shall be valid end Wdlt1,upon the Convey m 1 tehutrie with repot to any bond or unseen,"to wtech it is
MN WITNESS WHEREOF, the Companies have caused these presents to be signed and their corporate seals to be hereto affixed, this May 27,
RELIANCE SURETY COMPANY
e_Y.P H INSURANCE COMPANY
J' '�r• " r a UN 'PACIFICNATIONAL
C FIC INSURANCE COMPANY
Y �L e` H''4�t RELIANCE NATT/IIOONALaINNDE�MNITITYCOMPANY
M•J
STATE OF Pannsyl enie
COUNTY OF.Philedelphia I SS.
On this, May 27, 1998, before me, Valencia Wartham, personally appeared David T. Akers, who acknowledged himself to be the Senior Vice
President of the Reliance Surety Company, and the Vice President of Reliance Insurance Company, United Pacific Insurance Company, and
Reliance National Indemnity Company end that as such, being authorized to do so, executed the foregoing instrument for the"purpose therein
contained by signing the.,,name of the';corporeario'by himself as,its duly authorized officer.
In witness whereof, I herepnto set my;hand and official seal.
re
Nc arlal Sep ir aT F! C
iL���J
Valence'Ingham.Notary PublicpP1' the E Y�
Phdadeiphia,Philadelphia County ) Notary Public in and for the State of Pennsylvania
My Com*wRbn Expires Nov. 18.2000 Residing at^Ph ladelphia
I, Anita Lippert. Secretary of RELIANCE S I- • COMPANY, RELIANCE INSURANCE'COM'PANY, 'UNITED PACIFIC INSURANCE COMPANY, and
RELIANCE NATIONAL INDEMNITY COMPANY do hereby certify that the above and foregoing is a'true and correct copy of the Power of Attorney
executed by said Companies, which is still in full force and effect.
IN WITNESS WHEREOF,I have hereunto set my hand end affixed the seal*not said Companies thisairdaY f 'fin,1f, 119,9•
,tdreeare ,y.late4 `sdk wagay 4"../ I.°. Secretary
• SEAL ,> .• :7.
Asae e
3 � � � SEAL A
e
�•' ak p
4...0' ee.....
THE =ACK •F THIS e•CUMENT C•NTAINS AN A-TIFICIAL WATE-MA•K-H II L 1 AT AN ANGLE T• VIEW
Hello