The URL can be used to link to this page

Browse Search

Home My WebLink About820815.tiff re Wald COUNTY G?MMI_`il stlb Q JUL 191982GREELEY. coup. THE AMERICAN INSTITUTE OF ARCHITECTS AIA Document A107 Abbreviated Form of Agreement Between Owner and Contractor For CONSTRUCTION PROJECTS OF LIMITED SCOPE where the Basis of Payment is a STIPULATED SUM 1978 EDITION THIS DOCUMENT HAS IMPORTANT LEGAL CONSEQUENCES; CONSULTATION WITH AN ATTORNEY IS ENCOURAGED WITH RESPECT TO ITS COMPLETION OR MODIFICATION This document includes abbreviated General Conditions and should not be used with other General Conditions. It has been approved and endorsed by The Associated General Contractors of America. AGREEMENT made as of the ninth day of July in the year of Nineteen Hundred and Eighty-Two BETWEEN the Owner: Weld County, Colorado and the Contractor: Steve Royer Construction the Project: Remodel of Communication Center the Architect: Loren Bley and Associates The Owner and the Contractor agree as set forth below. Copyright 1936, 1951, 1958, 1961, 1963, 1966, 1974, © 1978 by the American Institute of Architects, 1735 New York Avenue, N.W., Washington, D.C. 20006. Reproduction of the material herein or substantial quotation of its provisions without permission of the AIA violates the copyright laws of the United States and will be subject to legal prosecution. AIA DOCUMENT A107 • ABBREVIATED OWNER-CONTRACTOR AGREEMENT • EIGHTH EDITION • APRIL 1978 • AIA® Cl 1978 • THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20006 fC Z 820815 ARTICLE 1 THE WORK 1.1 The Contractor shall perform all the Work required by the Contract Documents for (Here insert the caption descriptive of the Work as used on other Contract Documents.) Remodel of Weld County Communication Center as set forth in plans and specifications. • ARTICLE 2 TIME OF COMMENCEMENT AND SUBSTANTIAL COMPLETION 2.1 The Work to be performed under this Contract shall be commenced July 12, 1982, and, subject to authorized adjustments, Substantial Completion shall be achieved not later than (Here insert any special provisions for liquidated damages relating to failure to complete on time.) September 12, 1982, (contingent upon material suppliers barring shortages, bank orders and all circumstances beyond our control) ARTICLE 3 CONTRACT SUM 3.1 The Owner shall pay the Contractor in current funds for the performance of the Work, subject to additions and deductions by Change Order as provided in the Contract Documents, the Contract Sum of $ 24,744.00 3.2 The Contract Sum is determined as follows: (State here the base bid or other lump sum amount, accepted alternates,and unit prices,as applicable.) Base bid - $24,744.00 • MA DOCUMENT A107 • ABBREVIATED OWNER-CONTRACTOR AGREEMENT • EIGHTH EDITION • APRIL 1978 • AIA® A107-1978 2 © 1978 • THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, NM., WASHINGTON, D.C. 20006 ARTICLE 4 PROGRESS PAYMENTS 4.1 Based upon Applications for Payment submitted to the Architect by the Contractor and Certificates for Payment issued by the Architect, the Owner shall make progress payments on account of the Contract Sum to the Con- tractor as provided in the Contract Documents for the period ending the twenty—fifth day of the month as follows: • (Here insert payment procedures and provision for retainage, if any.) Payment by the tenth, ag.w11sis, 4.2 Payments due and unpaid under the Contract Documents shall bear interest from the date payment is due at the rate entered below, or in the absence thereof, at the legal rate prevailing at the place of the Project. (Here insert any rate of interest agreed upon.) (Usu y vs an requrremenis under the Federal Truth in Lending Act, similar state and local consumer credit laws and other regulations at the Owner's and Contractor's principal places of business, the location of the Project and elsewhere may affect the validity of this provision. Specific legal advice should be obtained with respect to deletion, modification, or other requirements such as written disclosure or waivers.) ARTICLE 5 FINAL PAYMENT 5.1 Final payment, constituting the entire unpaid balance of the Contract Sum, shall be paid by the Owner to the Contractor when the Work has been completed, the Contract fully performed,and a final Certificate for Payment has been issued by the Architect. ARTICLE 6 ENUMERATION OF CONTRACT DOCUMENTS 6.1 The Contract Documents, which constitute the entire agreement between the Owner and the Contractor, are listed in Article 7 and,except for Modifications issued after execution of this Agreement,are enumerated as follows: (List below the Agreement, the Conditions of the Contract (General, Supplementary, and other Conditions), the Drawings, the Specifications, and any Addenda and accepted alternates, showing page or sheet numbers in all cases and dates where applicable.) 1) Specifications by Loren Bley, Architect and Wilfred J. McGinley, Engineer. 2) Plans (two sheets) by above sources. See #1 3 A107-1978 AIA DOCUMENT A107 • ABI3REVIATED OWNER-CONTRACTOR AGREEMENT • EIGHTH EDITION • APRIL 1978 • AIA® © 1978 • THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N W., WASHINGTON, D.C. 20006 GENERAL CONDITIONS ARTICLE 7 tion of the Contractor's Applications for Payment, the CONTRACT DOCUMENTS Architect will determine the amounts owing to the Con- tractor and will issue Certificates for Payment in accord- 7.1 The Contract Documents consist of this Agreement ance with Article 15. with General Conditions, Supplementary and other Condi- 8.5 ..The Architect will be the interpreter of the require- tions, the Drawings, the Specifications, all Addenda issued ments the Contract Documents. He will make decisions prior to the execution of this Agreement, and all Modifi- on all claims, disputes or other matters in question be- cations issued by the Architect after execution of the tween the Contractor and the Owner, but he will not be Contract such as Change Orders, written interpretations liable for the results of any interpretation or decision ren- and written orders for minor changes in the Work. The dered in good faith. The Architect's decisions in matters intent of the Contract Documents is to include all items relating to artistic effect will be final if consistent with the necessary for the proper execution and completion of the intent of the Contract Documents. All other decisions of Work. The Contract Documents are complementary, and the Architect, except those which have been waived by what is required by any one shall be as binding as if re- the making or acceptance of final payment, shall be sub- quired by all. Work not covered in the Contract Docu- ject to arbitration upon the written demand of either rnents will not be required unless it is consistent therewith party and reasonably inferable therefrom as being necessary to 8.6 The Architect will have authority to reject Work produce the intended results. which does not conform to the Contract Documents. 7.2 Nothing contained in the Contract Documents shall 8.7 The Architect will review and approve or take other create any contractual relationship between the Owner or - • the Architect and any Subcontractor or Sub-subcontractor. appropriate action upon the Contractor's submittals such as Shop Drawings, Product Data and Samples, but only for 7.3 By executing the Contract, the Contractor represents conformance with the design concept of the Work and that he has visited the site and familiarized himself with with the information given in the Contract Documents. the local conditions under which the Work is to be performed. ARTICLE 9 7.4 The Work comprises the completed construction re- OWNER quired by the Contract Documents and includes all labor 91 The Owner shall furnish all surveys and a legal de- necessary to produce such construction, and all materials and equipment incorporated or to be incorporated in scription of the site. such construction. 9.2 Except as provided in Paragraph 10.5, the Owner shall secure and pay for necessary approvals, easements, ARTICLE 8 assessments and charges required for the construction, use or occupancy of permanent structures or permanent ARCHITECT changes in existing facilities. 8.1 The Architect will provide administration of the Con- 9.3 The Owner shall forward all instructions to the Con- tract and will be the Owner's representative during con- tractor through the Architect. struction and until final payment is due. 9.4 If the Contractor fails to correct defective Work or 8.2 The Architect shall at all times have access to the persistently fails to carry out the Work in accordance with Work wherever it is in preparation and progress. the Contract Documents, the Owner, by a written order, 8:3 The Architect will visit the site at intervals appropri- may order the Contractor to stop the Work, or any por- ate to the stage of construction to familiarize himself gen- tion thereof, until the cause for such order has been erally with the progress and quality of the Work and to eliminated; however, this right of the Owner to stop the determine in general if the Work is proceeding in accord- Work shall not give rise to any duty on the part of the Con- ance with the Contract Documents. However, the Archi- Owner to exercise this right for the benefit of the tect will not be required to make exhaustive or continu_ tractor or any other person or entity. ous on-site inspections to check the quality or quantity of ARTICLE 10 the Work. On the basis of his on-site observations as an CONTRACTOR architect, he will keep the Owner informed of the prog- ress of the Work, and will endeavor to guard the Owner 10.1 The Contractor shall supervise and direct the Work, against defects and deficiencies in the Work of the Con- using his best skill and attention and he shall be solely tractor. The Architect will not have control or charge of responsible for all construction means, methods, tech- and will not be responsible for construction means, meth- niques, sequences and procedures and for coordinating ods, techniques, sequences or procedures, or for safety all portions of the Work under the Contract. precautions and programs in connection with the Work, 10.2 Unless otherwise specifically provided in the Con- and he will not be responsible for the Contractor's failure tract Documents, the Contractor shall provide and pay for to carry out the Work in accordance with the Contract all labor, materials, equipment, tools, construction equip- Documents. ment and machinery, water, heat, utilities, transportation, 8.4 Based on the Architect's observations and an evalua- and other facilities and services necessary for the proper AIA DOCUMENT MOT • ABBREVIATED OWNER-CONTRACTOR AGREEMENT • EIGHTH EDITION • APRIL 1978 • AIAS © 1976 • THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20006 A107-1978 4 • • execution and completion of the Work, whether tempo- obligation of indemnity which would otherwise exist as to rary or permanent and whether or not incorporated or to any party or person described in this Paragraph 10.11. In be incorporated in the Work any and all claims against the Owner or the Architect or 10.3 The Contractor shall at all times enforce strict dis- any of their agents or employees by any employee of the cipline and good order among his employees and shall Contractor, any Subcontractor, anyone directly or indi- not employ on the Work any unfit person or anyone not rectly employed by any of them or anyone for whose acts skilled in the task assigned to him. any of them may be liable, the indemnification obligation 10.4 The Contractor warrants to the Owner and the under this Paragraph 10.11 shall not be limited in any Architect that all materials and equipment incorporated way by any limitation on the amount or type of damages, in the Work will be new unless otherwise specified, and compensation or benefits payable by or for the Contractor th, all Work will be of good quality, free from faults and or any Subcontractor under workers' or workmen's com- defects and in conformance with the Contract Documents. pensation acts, disability benefit acts or other employee All Work not conforming to these requirements may be benefit acts. The obligations of the Contractor under this considered defective. Paragraph 10.11 shall not extend to the liability of the Architect, his agents or employees, arising out of (1) the 10.5 Unless otherwise provided in the Contract Docu- preparation or approval of maps, drawings, opinions, re- ments, the Contractor shall pay all sales, consumer, use and other similar taxes which are legally enacted at the (2)ports, surveys, ofch or the il designs give specifications,onso in- time o- bids are received, and shall secure and pay for the structions the giving the Architect,r failure gt directions s by his agents or employees pro- building permit and for all other permits and govern- vided such giving or failure to give is the primary cause mental fees, licenses and inspections necessary for the of the injury or damage. proper execution and completion of the Work. 10.6 The Contractor shall give all notices and comply ARTICLE 11 with all laws, ordinances, rules, regulations, and lawful SUBCONTRACTS orders of any public authority bearing on the performance 11.1 A Subcontractor is a person or entity who has a of the Work, and shall promptly notify the Architect if the direct contract with the Contractor to perform any of the Drawings and Specifications are at variance therewith. Work at the site. 10.7 The Contractor shall be responsible to the Owner 11.2 Unless otherwise required by the Contract Docu- for the acts and omissions of his employees, Subcontrac- ments or in the Bidding Documents, the Contractor, as tors and their agents and employees, and other persons soon as practicable after the award of the Contract, shall performing any of the Work under a contract with the furnish to the Architect in writing the names of Subcon- Contractor. tractors for each of the principal portions of the Work. 10.8 The Contractor shall review, approve and submit all The Contractor shall not employ any Subcontractor to Shop Drawings, Product Data and Samples required by whom the Architect or the Owner may have a reasonable the Contract Documents. The Work shall be in accord- objection. The Contractor shall not be required to con- ance with approved submittals. tract with anyone to whom he has a reasonable objection. 103 The Contractor at all times shall keep the premises Contracts between the Contractor and the Subcontractors free from accumulation of waste materials or rubbish shall (1) require each Subcontractor, to the extent of the caused by his operations. At the completion of the Work Work to be performed by the Subcontractor, to be bound he shall remove all his waste materials and rubbish from to the Contractor by the terms of the Contract Docu- and about the Project as well as his tools, construction ments, and to assume toward the Contractor all the obli- equipment, machinery and surplus materials. gations and responsibilities which the Contractor, by these Documents,assumes toward the Owner and the Architect, 1010 The Contractor shall pay all royalties and license and (2) allow to the Subcontractor the benefit of all rights, fees. He shall defend all suits or claims for infringement remedies and redress afforded to the Contractor by these of any patent rights and shall save the Owner harmless Contract Documents. from loss on account thereof. 10.11 To the fullest extent permitted by law, the Con- ARTICLE 12 tractor shall indemnify and hold harmless the Owner and WORK BY OWNER OR BY the Architect and their agents and employees from and SEPARATE CONTRACTORS against all claims, damages, losses and expenses, including 12.1 The Owner reserves the right to perform work re- but not limited to attorneys' fees arising out of or result- lated to the Project with his own forces, and to award ing from the performance of the Work, provided that any separate contracts in connection with other portions of such claim, damage, loss or expense (1) is attributable to the Project or other work on the site under these or simi- bodily injury, sickness, disease or death, or to injury to or lar Conditions of the Contract. If the Contractor claims destruction of tangible property (other than the Work it- that delay or additional cost is involved because of such self) including the loss of use resulting therefrom, and action by the Owner, he shall make such claim as pro- (2) is caused in whole or in part by any negligent act or vided elsewhere in the Contract Documents. omission of the Contractor, any Subcontractor, anyone 12.2 The Contractor shall afford the Owner and separate directly or indirectly employed by any of them or anyone contractors reasonable opportunity for the introduction for whose acts any of them may be liable, regardless of and storage of their materials and equipment and the whether or not it is caused in part by a party indemnified execution of their work, and shall connect and coordinate hereunder. Such obligation shall not be construed to his Work with theirs as required by the Contract Docu- negate, abridge, or otherwise reduce any other right or ments. 5 A107-1978 AIA DOCUMENT A107 • ABBREVIATED OWNER-CONTRACTOR AGREEMENT • EIGHTH EDITION • APRIL 1978 • AIA® © 1978 • THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20006 12.3 Any costs caused by defective or ill-timed work 15.2 Payments may be withheld on account of (1) defec- shall be borne by the party responsible therefor. tive work not remedied, (2) claims filed, (3) failure of the Contractor to make payments properly to Subcontractors ARTICLE 13 or for labor, materials, or equipment, (4) damage to the MISCELLANEOUS PROVISIONS Owner or another contractor, or (5) persistent failure to 13.1 The Contract shall be governed by the law of the carry out the Work in accordance with the Contract place where the Project is located. Documents. 13.2 All claims or disputes between the Contractor and 15.3 When the Architect agrees that the Work is sub- the Owner arising out of, or relating to, the Contract stantially complete, he will issue a Certificate of Substan- Documents or the breach thereof shall be decided by tial Completion. arbitration in accordance with the Construction Industry 15.4 Final payment shall not be due until the Contractor Arbitration Rules of the American Arbitration Association has delivered to the Owner a complete release of all liens arising out of this Contract or receipts in full covering ali then obtaining unless the parties mutually agree other- wise. Notice of the demand for arbitration shall be filed labor, materials and equipment for which a lien could be in writing with the other party to the Owner-Contractor filed, or a bond satisfactory to the Owner indemnifying Agreement and with the American Arbitration Association him against any lien. If any lien remains unsatisfied after and shall be made within a reasonable time after the dis- all payments are made, the Contractor shall refund to the pute has arisen. The award rendered by the arbitrators Owner all moneys the latter may be compelled to pay in discharging such lien, including all costs and reasonable shall be final, and judgment may be entered upon it in accordance with applicable law in any court having juris- attorneys' fees. diction thereof. Except by written consent of the person 15.5 The making of final payments shall constitute a or entity sought to be joined, no arbitration arising out waiver of all claims by the Owner except those arising of or relating to the Contract Documents shall include, from (1) unsettled liens, (2) faulty or defective Work ap- by consolidation, joinder or in any other manner, any pearing after Substantial Completion, (3) failure of the person or entity not a party to the agreement under which Work to comply with the requirements of the Contract such arbitration arises, unless it is shown at the time the Documents, or (4) terms of any special warranties re- demand for arbitration is filed that (1) such person or quired by the Contract Documents. The acceptance of entity is substantially involved in a common question of final payment shall constitute a waiver of all claims by the fact or law, (2) the presence of such person or entity is Contractor except those previously made in writing and required if complete relief is to be accorded in the arbi- identified by the Contractor as unsettled at the time of the tration, (3) the interest or responsibility of such person or final Application for Payment. entity in the matter is not insubstantial, and (4) such per- son or entity is not the Architect or any of his employees ARTICLE 16 or consultants. The agreement herein among the parties PROTECTION OF PERSONS AND PROPERTY to the Agreement and any other written agreement to 16.1 The Contractor shall be responsible for initiating, arbitrate referred to herein shall be specifically enforce- maintaining, and supervising all safety precautions and able under the prevailing arbitration law. programs in connection with the Work. He shall take all ARTICLE 14 reasonable precautions for the safety of, and shall provide TIME all reasonable protection to prevent damage, injury or loss to (1) all employees on the Work and other persons 14.1 All time limits stated in the Contract Documents who may be affected thereby, (2) all the Work and all are of the essence of the Contract. The Contractor shall materials and equipment to be incorporated therein, and expedite the Work and achieve Substantial Completion (3) other property at the site or adjacent thereto. He shall within the Contract Time. give all notices and comply with all applicable laws, ordi- 14.2 The Date of Substantial Completion of the Work is nances, rules, regulations and orders of any public author- the date certified by the Architect when construction is ity bearing on the safety of persons and property and their protection from damage, injury or loss. The Contractor sufficiently complete so that the Owner can occupy or utilize the Work for the use for which it is intended. shall promptly remedy all damage or loss to any property caused in whole or in part by the Contractor, any Sub- 14.3 If the Contractor is delayed at any time in the contractor, any Sub-subcontractor, or anyone directly or progress of the Work by changes ordered in the Work, by labor disputes, fire, unusual delay in transportation, indirectly employed by any of them, or by anyone for adverse weather conditions not reasonably anticipatable, whose acts any of them may be liable, except damage or loss attributable to the acts or omissions of the Owner or unavoidable casualties, or any causes beyond the Con- tractor's control, or by any other cause which the Archi- Architect or anyone directly or indirectly employed by tect determines may justify the delay, then the Contract either of them or by anyone for whose acts either of them Time shall be extended by Change Order for such reason- may be liable, and not attributable to the fault or negli- gence of the Contractor. The foregoing obligations of the able time as the Architect may determine. Contractor are in addition to his obligations under Para- ARTICLE 15 graph 10.11. PAYMENTS AND COMPLETION ARTICLE 17 151 Payments shall be made as provided in Article 4 and INSURANCE Article 5 of this Agreement. 17.1 Contractor's liability insurance shall be purchased AlA DOCUMENT A107 • ABBREVIATED OWNER-CONTRACTOR AGREEMENT • EIGHTH EDITION • APRIL 1978 • AIA® O 1978 • THE AMERICAN INSTITUTE OF ARCHITECTS, 1733 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20006 A107-1978 6 and maintained by the Contractor to protect him from 18.2 The Contract Sum and the Contract Time may be claims under workers' or workmen's compensation acts changed only by Change Order. and other employee benefit acts, claims for damages be- 18.3 The cost or credit to the Owner from a change in cause of bodily injury, including death, and from claims the Work shall be determined by mutual agreement. for damages, other than to the Work itself, to property which may arise out of or result from the Contractor's - - ARTICLE 19 operations under this Contract, whether such operations CORRECTION OF WORK be by himself or by any Subcontractor or anyone directly or indirectly employed by any of them. This insurance 19.1 The Contractor shall promptly correct any Work shall be written for not less than any limits of liability rejected by the Architect as defective or as failing to con- specified in the Contract Documents, or required by law, form to the Contract Documents whether observed before whichever is the greater, and shall include contractual or after Substantial Completion and whether or not fabri- liability insurance applicable to the Contractor's obliga- cated, installed or completed, and shall correct any Work tions under Paragraph 10.11. Certificates of such insur- found to be defective or nonconforming within a period ance shall be filed with the Owner prior to the tom- of one year from the Date of Substantial Completion of mencement of the Work. the Contract or within such longer period of time as may 17.2 The Owner shall be responsible for purchasing and be prescribed by law or by the terms of any applicable maintaining his own liability insurance and, at his option, special warranty required by the Contract Documents. The may maintain such insurance as will protect him against provisions of this Article 19 apply to Work done by Sub- claims which may arise from operations under the Con- contractors as well as to Work done by direct employees tract. of the Contractor. 17.3 Unless otherwise provided, the Owner shall pur- chase and maintain property insurance upon the entire ARTICLE 20 Work at the site to the full insurable value thereof. This TERMINATION OF THE CONTRACT insurance shall include the interests of the Owner, the Contractor, Subcontractors and Sub-subcontractors in the 20.1 If the Architect fails to issue a Certificate for Pay- Work and shall insure against the perils of fire and ex- ment for a period of thirty days through no fault of the tended coverage and shall include "all risk" insurance for Contractor,or if the Owner fails to make payment thereon physical loss or damage including, without duplication of for a period of thirty days, the Contractor may, upon coverage, theft, vandalism, and malicious mischief. seven additional days' written notice to the Owner and 17.4 Any loss insured under Paragraph 17.3 is to be ad- the Architect, terminate the Contract and recover from justed with the Owner and made payable to the Owner the Owner payment for all Work executed and for any as trustee for the insureds, as their interests may appear, proven loss sustained upon any materials, equipment, subject to the requirements of any mortgagee clause. tools, and construction equipment and machinery, includ- 17.5 The Owner shall file a copy of all policies with the ing reasonable profit and damages applicable to the Contractor before an exposure to loss may occur. Project. 20.2 If the Contractor defaults or persistently fails or 17.6 The Owner and Contractor waive all rights against each other for damages caused by fire or other perils to Contractneglects Documentso carry out the Work ei accordance rmanyr with the or fails to perform any provision of the extent covered by insurance obtained pursuant to the Contract, the Owner may, after seven days' written this Article or any other property insurance applicable to notice to the Contractor and without prejudice to any the Work, except such rights as they may have to the pro- other remedy he may have, make good such deficiencies ceeds of such insurance held by the Owner as trustee. and may deduct the cost thereof, including compensation The Contractor shall require similar waivers in favor of the for the Architect's additional services made necessary Owner and the Contractor by Subcontractors and Sub- thereby, from the payment then or thereafter due the subcontractors. Contractor or, at his option, and upon certification by the Architect that sufficient cause exists to justify such action, ARTICLE 18 may terminate the Contract and take possession of the CHANGES IN THE WORK site and of all materials, equipment, tools, and construc- tion equipment and machinery thereon owned by the 18.1 The Owner, without invalidating the Contract, may Contractor and may finish the Work by whatever method order Changes in the Work consisting of additions, dele- he may deem expedient, and if the unpaid balance of the tions, or modifications, the Contract Sum and the Con- Contract Sum exceeds the expense of finishing the Work, tract Time being adjusted accordingly. All such changes such excess shall be paid to the Contractor, but if such in the Work shall be authorized by written Change Order expense exceeds such unpaid balance, the Contractor signed by the Owner and the Architect. shall pay the difference to the Owner. 7 A107-1978 AIA DOCUMENT A107 • ABBREVIATED OWNER-CONTRACTOR AGREEMENT • EIGHTH EDITION • APRIL 1978 • AIA® © 1978 • THE AMERICAN INS1ikilt Ur nnLniitLls, ,,i NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20006 ARTICLE 21 OTHER CONDITIONS OR PROVISIONS Any additions or subtractions to work involved in this contractual agreement shall be executed by change order. Amounts involved to be added to contractual amount agreed upon in this document. • This Agreement entered into as of the day and year first written above. OWNER CONTRACTOR l� < �Z t% %.�YA./l - /t� {� - -O. 46/476___ Steve Royer Construction AIA DOCUMENT A107 • ABBREVIATED OWNER-CONTRACTOR AGREEMENT • EIGHTH EDITION • APRIL 1978 • AIA® O 1978 • THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W., WASHINGTON, D.C. 20006 A107-1978 8 Hello