HomeMy WebLinkAbout800846.tiff RESOLUTION
RE: APPROVAL OF AGREEMENT FOR PROFESSIONAL SERVICES BETWEEN
WELD COUNTY, COLORADO AND ARIX CONCERNING TECHNICAL ASSIS-
TANCE FOR ENERGY CONSERVATION MEASURES AND AUTHORIZATION
FOR CHAIRMAN TO SIGN THE SAME.
WHEREAS, the Board of County Commissioners of Weld County,
Colorado, pursuant to Colorado statute and the Weld County Home
Rule Charter, is vested with the authority of administering the
affairs of Weld County, Colorado, and
WHEREAS, an Agreement for Professional Services between
Weld County, Colorado and ARIX concerning technical assistance
for energy conservation measures has been presented to the Board
of County Commissioners for approval, and
WHEREAS, the total fee for such services shall be $17 ,400 . 00,
and
WHEREAS, the Board of County Commissioners has studied said
Agreement and deems it advisable to approve the same.
NOW, THEREFORE, BE IT RESOLVED by the Board of County Com-
missioners of Weld County, Colorado that the Agreement for Pro-
fessional Services between Weld County, Colorado and ARIX con-
cerning technical assistance for energy conservation measures
be, and hereby is, approved.
BE IT FURTHER RESOLVED by the Board of County Commissioners
of Weld County, Colorado that the Chairman of the Board be, and
hereby is, authorized to sign said Agreement.
The above and foregoing Resolution was, on motion duly made
and seconded, adopted by the following vote on the 17th day of
December, A.D. , 1980.
/) v BOARD OF COUNTY COMMISSIONERS
ATTEST: nialawv17GUI/Litirl WELD COUNTY, COLORADO
Wel County Clerk and Recorder 1:27. 4-- (Aye)
d C rk to the Bo d C. Kirby, airman
By: ABSENT DATE SIGNED (Aye)
Deputy Coun Clerk Leonard L. Roe, Pro-Tem
/ APPROV AS TO FORM: )24-0-""^-.4‘...— (144 (Aye)
(\ Norman Carlson
County Attorney �� (Aye)
L Dun n5ar
Aye)
ne K. St inmark
800846
DATE PRESENTED: DECEMBER 22, 1980
n n
President
arpenter, A Professional Corporation
R.bKent Baker ARIX
Eugene R.Brauer
Architects Planners
Gordon W.Bruchner
Patrkk C.Dv yer
Robert J.Shreve
Dale J.Steichen
Robert D.Thomas 2021 Clubhouse Drive
Gary R.Wkdolph Post Office Box 2021
Greeley,Colorado 80631
303 330 2749
December 12, 1980
Mr. Donald D. Warden
Director
Finance and Administration
Weld County, Colorado
Office of Finance and Administration
Post Office Box 758
Greeley, Colorado 80632
Dear Mr. Warden:
SUBJECT: WELD COUNTY CENTENNIAL COMPLEX/COURTHOUSE TECHNICAL
ASSISTANCE AUDIT
SERIAL LETTER NO. 1.00
Attached please find three copies of the executed and signed contract
for the subject project. The time schedule has been coordinated with
Andy Petruzzi as requested. Please review and return one signed copy
to our office.
Thank you for your time and cooperation on this project.
Respectfully,
ARIX, A Professio al Corporation
Jer ' C. Hami .E.
JCH: f
Enclosure
AGREEMENT FOR PROFESSIONAL SERVICES
THIS AGREEMENT, made this 15th day of December, 1980 by and between
WELD COUNTY, COLORADO
hereinafter called the Client, and ARIX, A Professional Corporation, hereinafter
called the Consultant, collectively referred to as the Parties.
WITNESSETH: That for and in consideration of the mutual covenants and agreements
hereinafter contained, the Parties hereto have mutually agreed and do agree as
follows:
ARTICLE 1. SERVICES BY THE CONSULTANT - The consultant agrees to perform all
services, hereunder, using reasonable skill and judgment in accordance with
sound business and professional standards. He agrees to keep the Client
thoroughly informed of his progress and to maintain accurate records relating
to his services in connection with this project.
The Consultant agrees to provide the following basic services:
1.1 Professional services in accordance with the Colorado Office of Energy
Conservation Institutional Buildings Grants Program, Phase II application
package, Section IIIB for Weld County Centennial Building, including the
detached courthouse. Services to be provided will be in accordance with
the request for proposal made by Weld County for technical assistance for
energy conservation measures for the Centennial Complex/Courthouse and the
approved proposal submitted by ARIX in response to the request for proposal
dated March 21, 1980, attached hereto and incorporated as a part of this
agreement. Both parties agree to exclude from the request for proposal :
1) part 3 of the SCOPE OF WORK--any remodeling associated with the energy
conservation measures and 2) second paragraph of ADDITIONAL INSTRUCTIONS/
INFORMATION--a hold harmless clause from this agreement as cited in the
request for proposal but excluded in the cover letter dated March 20, 1980
submitted with the response from ARIX.
1.2 A total of six copies of the final report will be prepared by ARIX.
ARTICLE 2. RESPONSIBILITIES OF THE CLIENT
2.1 The Client shall provide and make available to the Consultant, for his use,
all maps, property descriptions, surveys, previous reports, historical data,
and other information within its knowledge and possession relative to the
services to be furnished hereunder, and shall provide full programming
requirements. Data so furnished to the Consultant shall remain the property
of the Client and will be returned upon completion of its services.
2.2 The Client shall guarantee access and make provisions for the Consultant to
enter upon public and private properties as required for the Consultant to
perform its services hereunder.
-1-
r� n
ARTICLE 3. TIME OF PERFORMANCE - The services to be provided under this Agreement
shall , unless otherwise provided, be commenced upon execution of this Agreement
and be performed in general accordance with the following schedule:
Commence Work 12/15/80
Preliminary Report 2/16/81
Final Report 3/ 2/81
Presentation to State by County 3/13/81
ARTICLE 4. REMUNERATION FOR SERVICES - The Client agrees to compensate the
Consultant in accordance with the following schedule, and the Terms and
Conditions of this Agreement:
4.1 For Basic Services as described in Article 1, remuneration shall be made
on the following basis:
All payments for services will be made monthly in proportion to
services performed.
The total fee shall be $17,400.00
4.2 Unless otherwise provided herein, all payments for Basic Services shall be
due and payable at the Consultant's office at the address hereinafter des-
ignated upon presentation by the Consultant in accordance with this Agreement.
Payments not made within 30 days of the billing date shall bear interest at
the rate of 11% per month which is an annual interest rate of 18%.
4.3 No deductions shall be made, nor any amounts retained from the Consultant's
compensation on account of delays, penalties, liquidated damages, or other
sums withheld from payment to Contractors.
ARTICLE 5. DELAYS - If the Consultant is delayed at any time in the progress of
work by any act or neglect of the Client or its agents, employees, or contractors,
or by changes in the work, or by labor disputes, unavoidable material delivery
delays, fire, unavoidable casualties, or by any causes beyond the Consultant's
control , the time schedule shall be extended for a reasonable length of time,
and the remuneration schedule shall be subject to renegotiation for increased
expenses due to escalation of prices, extended services, relocation or other
expenses incidental to such delays.
ARTICLE 6. OWNERSHIP OF DOCUMENTS - All drawings, specifications, reports, records,
and other work product developed by the Consultant in connection with this project
are instruments of service for this project only and shall remain the intellectual
property of the Consultant whether the project is complete or not. The
Consultant shall furnish originals or copies of such work product to the Client
in accordance with the services required hereunder. Reuse of any of the work
product of the Consultant by the Client on extension of this project or on any
other project without the written permission of the Consultant shall be at the
Client's risk and the Client agrees to defend, indemnify and hold harmless the
Consultant from all claims, damages and expenses including attorneys fees arising
out of such unauthorized reuse by the Client or by others acting through the
Client. Any reuse or adaptation of the Consultant's work product shall entitle
the Consultant to further equitable compensation.
-2-
(-N
ARTICLE 7. INSURANCE - The Consultant shall purchase and maintain insurance to
protect himself from claims under workmen's compensation acts; claims for
damages because of bodily injury including personal injury, sickness or
disease, or death of any of his employees or of any person other than his
employees; and from claims for damages because of injury to or destruction of
tangible property including loss of use resulting therefrom.
ARTICLE 8. DISPUTES - As a condition precedent to the right to bring any action
in court pertaining to any claim, dispute or other matter in question between
the parties to this Agreement, arising out of, or relating to this Agreement or
the breach thereof, the party having such claim or dispute shall first make a
written offer to the other party to arbitrate the question(s) in accordance
with the Construction Industry Arbitration Rules of the American Arbitration
Association then obtaining. If within ten days after receipt of said offer,
the party to whom the offer is made does not affirmatively agree in writing
to such arbitration, then the claiming party shall have no obligation to
arbitrate and may pursue other remedies for relief.
ARTICLE 9. GOVERNING LAW - Unless otherwise agreed in writing, this Agreement and
the interpretation thereof shall be governed by the law in effect at the location
of the offices of the Consultant as hereinafter designated.
ARTICLE 10. SUCCESSORS AND ASSIGNS — The Client and the Consultant each binds
himself and his partners, successors, executors, administrators and assigns to
the other party of this Agreement and to the partners, successors, executors,
administrators and assigns of such other party with respect to all covenants
of this Agreement. Neither party shall assign or transfer his interest in this
Agreement without the written consent of the other.
ARTICLE 11. EXTENT OF AGREEMENT - This Agreement represents the entire and inte-
grated agreement between the parties and supersedes all prior negotiations and
representations. Nothing herein shall be deemed to create any contractual
relationship between the Consultant and any other Consultant or contractor or
material supplier on the project, nor to furnish any notices required under
other such contracts, nor shall anything herein be deemed to give anyone not a
party to this Agreement any right of action against a party which does not
otherwise exist without regard to this Agreement.
ARTICLE 12. ACCURACY OF SERVICES AND LIMITATION OF LIABILITY
12.1 The Consultant shall use reasonable professional skill and judgment in
connection with services hereunder, but does not warrant that such services
are without error and/or omissions. If, as a result of the authorized use
and prudent interpretation of documents or advice erroneously furnished by
the Consultant, an error or omission is discovered within a reasonable time,
the Consultant shall be responsible for correction of any work which must be
removed or altered to meet the project requirements, provided that the
Consultant is given a reasonable opportunity to make remedial recommendations
and to correct or arrange for the correction of the work itself. The Con-
sultant will not be liable for the cost of procurement of work or services
performed in correcting errors and/or omissions where such work or services
result in a value to the Project over and above that which the original work
or services provided.
-3-
rte,
12.2 Notwithstanding the above, the Client agrees to limit the Consultant
liability to the Client and to its agents and assigns, due to the Consultant's
professional negligent acts, errors or omissions, such that the total aggregate
liability of the Consultant to those named shall not exceed the Consultant's
total fee for services hereunder.
ACKNOWLEDGEMENT OF COMPLETE AGREEMENT: This Agreement includes this and the
preceding pages consecutively numbered 1 through 4, and the Request for
Proposal made by Weld County for Technical Assistance for Energy Conservation
Measures for the Centennial Complex/Courthouse, which is attached.
IN WITNESS WHEREOF, the parties hereto have executed this Agreement the day and
year first written above.
CLIENT: CONSULTANT:
ARIX, A Professional Corporation
Engineers Architects Planners
[�A By 1/1 +' By /C/�Gl/
Board of County By_�l ' t—
TitleChairman,
Commissioners
Address915 10th Street, Greeley, ;CO Address 2021 Clubho Drive
Greeley, Colorado 80631
-4-
AticiLX
REQUEST FOR PROPOSAL MADE By WELD COUNTY r c tS 2 5 1980 .'
FOR TECHNICAL ASSISTANCE FOR ENERGY CONSERVATION MEASURES
FOR THE CENTENNIAL COMPLEX/COURTHOUSE
•
SCOPE
This is a Request for Proposal for providing technical assistance for
evaluating the Centennial Complex/Courthouse, located at 915 10th Street,
for Energy Conservation Measures in accordance with Federal rules for
the Energy Conservation Program.
Technical assistance, for the purposes of this Request for Proposal,
means a program or activity for (1) a conduct of specialized studies to
identify and specify energy savings and related cost savings that are
likely to be realized as a result of either modifying maintenance and
operating procedures in a building, or both; (2) the planning or adminis-
tration of such specialized studies; and /3), the planning or adminis-
trating of specific remodeling, renovation, repair, replacement or
installation projects related to the installation of energy conservation
measures in the buildings involved.
RE On—ANTS
The technical assistance project covered by this Request for Proposal
shall be conducted by a qualified technical, assistance analyst (as
specified below) , who shall consider all possible energy conservation
measures for the buildings involved, including both the building enve-
lope and the building's energy-using systems. The technical assistance
program shall include a detailed engineering analysis to identify the
estimated costs of, and the energy cost savings likely to be realized
from, implementing each identified energy conservation maintenance and
operating procedure. The technical assistance program shall also identify
the estimated cost of, and the energy and cost savings likely tote
realized from, acquiring and installing each energy conservation measure
that indicate a significant potential for saving energy based upon the
technical assistance analyst's initial consideration.
In accordance with Federal rules (lOCFR 455.42) , at the conclusion of
the technical assistance program, the technical assistance analyst shall
prepare a final report which shall include:
1. A description of building characteristics and energy data
including:
a. The results of the preliminary-energy
audit (or its a gs and energy
equivalent) of the buildings;
•
Z
/.4"` em
b. The operating characteristics of energy using systems;
and
c. The estimated remaining useful life of a building.
2. An analysis of the estimated energy consumption of. the build-
ings, by fuel type (in total Btu's and Btu/sq. ft./yr.) , at
optimum efficiency (assuming implementation of all energy
conservation.maintenance and operating procedures) .
3. An evaluation of the building's potential for solar conver-
sion, particularly for water heating systems.
4. A listing of any known local zoning ordinances and building
codes which may restrict the installation of solar systems.
5. A description and analysis of all recommendations, if any, for
acquisition and installation of energy conservation measures,
including solar and other renewable resource measures, setting
forth:
a. A description of each recommended energy conservation
measure;
b. An estimate of the cost of design, acquisition and
installation of each energy conservation measure;
C c. An estimate of the useful life of each energy conser-
vation measure;
d. An estimate of increases or decreases in maintenance and
operating costs that would result from each energy con-
servation measure, if any;
e. An estimate of the annual energy and energy cost savings
(using current energy prices) expected from the acquisi-
tion and installation of each energy conservation measure.
In calculating the potential energy cost savings of each
recommended energy conservation measure, including solar
or other renewable resource measure, technical assistance
analysts shall:
1) Assume that all energy savings obtained from energy
conservation maintenance and operating procedures
have been realized;
2) Calculate the total energy and energy cost savings,
by fuel type, expected to result from the acquisition
and installation of all recommended energy conservation
measures, taking into account the interaction among
the various measures; and,
3) Calculate that portion of the total energy and
energy cost savings, as determined in (2) above,
attributable to each individual energy conservation
measure.
3
f. The simple payback period of each recommended energy
conservation measure, taking into account the inter-
actions among the various measures. The simple payback
period is calculated by dividing the estimated total cost
of the measure, as determined pursuant to 5 (b) of this
section. For the purposes of ranking applications, the
simple payback period shall be calculated using the cost
savings resulting from energy savings only, determined on
the basis of current energy prices. The estimated cost
of the measure shall be the total cost for design and
other professional services (excluding costs of a technical
assistance program), if any, and acquisition and instal-
lation costs. Other economic analyses, such as life-
cycle costing, which consider all costs and cost savings,
such as maintenance costs and/or savings, resulting from
an energy conservation measure, are recommended, but not
required, for use by the institution in its decision
making process.
6. A listing of energy use and cost data for each fuel type used
for the prior 12-month period.
7. A signed and dated certification that the technical assistance
program has been conducted in accordance with the requirements
of this section and that the data presented is accurate to the
best of the technical assistance analyst's knowledge.
QUALIFICATIONS FOR TECHNICAL ASSISTANCE ANALYST UNDER'THIS REQUEST FOR
PROPOSAL
To qualify as a technical assistance analyst for the Request for Proposal,
the OEC and Weld County require that such analysts:
1. have experience in energy conservation* and be a registered
professional engineer licensed under the regulatory authority
of the State of Colorado; or
2. have experience in energy conservation and be a licensed
architect under the regulatory authority of the State of
Colorado; or
3. be an architect-engineer team, the principal members of which
have experience in energy conservation and are licensed under
the regulatory authority of the State; and
4. be free from financial interests which conflict with the
proper performance of their duties.**
* "Energy conservation experience" can mean a) demonstrated
experience in conducting professional energy audits, and/or b)
experience in the design of energy efficient systems commonly
found in the building(s) selected for the analysis. Archi-
tects and engineers must meet the same criteria for energy
conservation experience.
Y
** "Free from financial conflict of interest" means free of
financial interests in the products or equipment which would
be acquired or installed under this program. The term is not
intended to prohibit technical assistance analysts from per-
forming the detailed design work which may be necessary as
part of grant awards for ECM's.
BIDDER QUALIFICATIONS
The County must have evidence of the bidder's ability to provide the
• services described in this Request for Proposal. The bidder must answer
the following questions:
1. How many years has your firm been in the business?
2. Are you able to provide the technical assistance as described
above?
3. The successful bidder must be able to provide a Performance ,f/c
Bond in the full amount of the contract award.
SCHEDULE
March 6, 1980 - Pre-bid conference.
March 21, 1980 - Submittal of bid.
March 26, 1980 - Submit bid to Board of County Commissioners.
March 27, 1980 - Interview firms submitting proposals.
March 31, 1980 - Work session with Board.
April 7, 1980 - Award of contract.
PROCEDURES FOR SUBMITTAL
All proposals should be submitted to the Director of Purchasing on or
before March 21, 1980 at 1:00 p.m.
EVALUATION OF PROPOSALS
Upon receipt of all proposals, an evaluation team shall evaluate the
firms proposals and then shall interview the firms that, in the County's
opinion, can accomplish the task outlined in the Request for Proposal.
After interviewing the selected firm or firms, the Board shall take one
of two courses of action:
1. Request a firm to perform the tasks outlined in the Request
for Proposal.
2. Notify all parties submitting proposals that the constraints
identified in the interview process or in evaluating the pro-
posals makes it impossible to select any of the firms.
n
AGREEMENT FOR PROFESSIONAL SERVICES
THIS AGREEMENT, made this 15th day of December, 1980 by and between
WELD COUNTY, COLORADO
hereinafter called the Client, and ARIX, A Professional Corporation, hereinafter
called the Consultant, collectively referred to as the Parties.
WITNESSETH: That for and in consideration of the mutual covenants and agreements
hereinafter contained, the Parties hereto have mutually agreed and do agree as
follows:
ARTICLE 1. SERVICES BY THE CONSULTANT - The consultant agrees to perform all
services, hereunder, using reasonable skill and judgment in accordance with
sound business and professional standards. He agrees to keep the Client
thoroughly informed of his progress and to maintain accurate records relating
to his services in connection with this project.
The Consultant agrees to provide the following basic services:
1.1 Professional services in accordance with the Colorado Office of Energy
Conservation Institutional Buildings Grants Program, Phase II application
package, Section IIIB for Weld County Centennial Building, including the
detached courthouse. Services to be provided will be in accordance with
the request for proposal made by Weld County for technical assistance for
energy conservation measures for the Centennial Complex/Courthouse and the
approved proposal submitted by ARIX in response to the request for proposal
dated March 21, 1980, attached hereto and incorporated as a part of this
agreement. Both parties agree to exclude from the request for proposal :
1) part 3 of the SCOPE OF WORK--any remodeling associated with the energy
conservatidn measures and 2) second paragraph of ADDITIONAL INSTRUCTIONS/
INFORMATION--a hold harmless clause from this agreement as cited in the
request for proposal but excluded in the cover letter dated March 20, 1980
submitted with the response from ARIX.
1.2 A total of six copies of the final report will be prepared by ARIX.
ARTICLE 2. RESPONSIBILITIES OF THE CLIENT
2.1 The Client shall provide and make available to the Consultant, for his use,
all maps, property descriptions, surveys, previous reports, historical data,
and other information within its knowledge and possession relative to the
services to be furnished hereunder, and shall provide full programming
requirements. Data so furnished to the Consultant shall remain the property
of the Client and will be returned upon completion of its services.
2.2 The Client shall guarantee access and make provisions for the Consultant to
enter upon public and private properties as required for the Consultant to
perform its services hereunder.
-1-
e
ARTICLE 3. TIME OF PERFORMANCE - The services to be provided under this Agreement
shall , unless otherwise provided, be commenced upon execution of this Agreement
and be performed in general accordance with the following schedule:
Commence Work 12/15/80
Preliminary Report 2/16/81
Final Report 3/ 2/81
Presentation to State by County 3/13/81
ARTICLE 4. REMUNERATION FOR SERVICES - The Client agrees to compensate the
Consultant in accordance with the following schedule, and the Terms and
Conditions of this Agreement:
4.1 For Basic Services as described in Article 1, remuneration shall be made
on the following basis:
All payments for services will be made monthly in proportion to
services performed.
The total fee shall be $17,400.00
4.2 Unless otherwise provided herein, all payments for Basic Services shall be
due and payable at the Consultant's office at the address hereinafter des-
ignated upon presentation by the Consultant in accordance with this Agreement.
Payments not made within 30 days of the billing date shall bear interest at
the rate of 11% per month which is an annual interest rate of 18%.
4.3 No deductions shall be made, nor any amounts retained from the Consultant's
compensation on account of delays, penalties, liquidated damages, or other
sums withheld from payment to Contractors.
ARTICLE 5. DELAYS - If the Consultant is delayed at any time in the progress of
work by any act or neglect of the Client or its agents, employees, or contractors,
or by changes in the work, or by labor disputes, unavoidable material delivery
delays, fire, unavoidable casualties, or by any causes beyond the Consultant's
control , the time schedule shall be extended for a reasonable length of time,
and the remuneration schedule shall be subject to renegotiation for increased
expenses due to escalation of prices, extended services, relocation or other
expenses incidental to such delays.
ARTICLE 6. OWNERSHIP OF DOCUMENTS - All drawings, specifications, reports, records,
and other work product developed by the Consultant in connection with this project
are instruments of service for this project only and shall remain the intellectual
property of the Consultant whether the project is complete or not. The
Consultant shall furnish originals or copies of such work product to the Client
in accordance with the services required hereunder. Reuse of any of the work
product of the Consultant by the Client on extension of this project or on any
other project without the written permission of the Consultant shall be at the
Client's risk and the Client agrees to defend, indemnify and hold harmless the
Consultant from all claims, damages and expenses including attorneys fees arising
out of such unauthorized reuse by the Client or by others acting through the
Client. Any reuse or adaptation of the Consultant's work product shall entitle
the Consultant to further equitable compensation.
-2-
ARTICLE 7. INSURANCE - The Consultant shall purchase and maintain insurance to
protect himself from claims under workmen's compensation acts; claims for
damages because of bodily injury including personal injury, sickness or
disease, or death of any of his employees or of any person other than his
employees; and from claims for damages because of injury to or destruction of
tangible property including loss of use resulting therefrom.
ARTICLE 8. DISPUTES - As a condition precedent to the right to bring any action
in court pertaining to any claim, dispute or other matter in question between
the parties to this Agreement, arising out of, or relating to this Agreement or
the breach thereof, the party having such claim or dispute shall first make a
written offer to the other party to arbitrate the question(s) in accordance
with the Construction Industry Arbitration Rules of the American Arbitration
Association then obtaining. If within ten days after receipt of said offer,
the party to whom the offer is made does not affirmatively agree in writing
to such arbitration, then the claiming party shall have no obligation to
arbitrate and may pursue other remedies for relief.
ARTICLE 9. GOVERNING LAW - Unless otherwise agreed in writing, this Agreement and
the interpretation thereof shall be governed by the law in effect at the location
of the offices of the Consultant as hereinafter designated.
ARTICLE 10. SUCCESSORS AND ASSIGNS - The Client and the Consultant each binds
himself and his partners, successors, executors, administrators and assigns to
the other party of this Agreement and to the partners, successors, executors,
administrators and assigns of such other party with respect to all covenants
of this Agreement. Neither party shall assign or transfer his interest in this
Agreement without the written consent of the other.
ARTICLE 11. EXTENT OF AGREEMENT - This Agreement represents the entire and inte-
grated agreement between the parties and supersedes all prior negotiations and
representations. Nothing herein shall be deemed to create any contractual
relationship between the Consultant and any other Consultant or contractor or
material supplier on the project, nor to furnish any notices required under
other such contracts, nor shall anything herein be deemed to give anyone not a
party to this Agreement any right of action against a party which does not
otherwise exist without regard to this Agreement.
ARTICLE 12. ACCURACY OF SERVICES AND LIMITATION OF LIABILITY
12.1 The Consultant shall use reasonable professional skill and judgment in
connection with services hereunder, but does not warrant that such services
are without error and/or omissions. If, as a result of the authorized use
and prudent interpretation of documents or advice erroneously furnished by
the Consultant, an error or omission is discovered within a reasonable time,
the Consultant shall be responsible for correction of any work which must be
removed or altered to meet the project requirements, provided that the
Consultant is given a reasonable opportunity to make remedial recommendations
and to correct or arrange for the correction of the work itself. The Con-
sultant will not be liable for the cost of procurement of work or services
performed in correcting errors and/or omissions where such work or services
result in a value to the Project over and above that which the original work
or services provided.
-3-
n fl
12.2 Notwithstanding the above, the Client agrees to limit the Consultant
liability to the Client and to its agents and assigns, due to the Consultant's
professional negligent acts, errors or omissions, such that the total aggregate
liability of the Consultant to those named shall not exceed the Consultant's
total fee for services hereunder.
ACKNOWLEDGEMENT OF COMPLETE AGREEMENT: This Agreement includes this and the
preceding pages consecutively numbered 1 through 4, and the Request for
Proposal made by Weld County for Technical Assistance for Energy Conservation
Measures for the Centennial Complex/Courthouse, which is attached.
IN WITNESS WHEREOF, the parties hereto have executed this Agreement the day and
year first written above.
CLIENT: CONSULTANT:
ARIX, A Professional Corporation
Engineers Architects Planners
By fliv By
Title chairman, ElOard of County By
Commissioners
Address915 10th Street Greeley, Co Address 2021 Clubho Drive
Greeley, Colorado 80631
-4-
IAr( IX
REQUEST FOR PROPOSAL MADE BY WELD COUNTY t c tl 2 5 f960
s•
Y, y
FOR TECHNICAL ASSISTANCE FOR ENERGY CONSERVATION MEASURES
FOR THE CENTENNIAL COMPLEX/COURTHOUSE _ ,
•
SCOPE OF WORK
This is a Request for Proposal for providing technical assistance for
evaluating the Centennial Complex/Courthouse, located at 915 10th Street,
for Energy Conservation Measures in accordance with Federal rules for
the Energy Conservation Program.
Technical assistance, for the purposes of this Request for Proposal, •
means a program or activity for (1) a conduct of specialized studies to
identify and specify energy savings and related cost savings that are
likely to be realized as a result of either modifying maintenance and
operating procedures in a building, or both; (2) the planning or adminis-
tration of such specialized studies; and /(3)' the planning or adminis-
trating of specific remodeling, renovation, repair, replacement or
installation projects related to the installation of energy conservation
measures in the buildings involved.
REQUi IREMENTS
The technical assistance project covered by this Request for Proposal
shall be conducted by a qualified technical assistance analyst (as
specified below) , who shall consider all possible energy conservation
measures for the buildings involved, including both the building enve-
lope and the building's energy-using systems. The technical assistance
program shall include a detailed engineering analysis to identify the
estimated costs of, and the energy cost savings likely to be realized
from, implementing each identified energy conservation maintenance and
operating procedure. The technical assistance program shall also identify
the estimated cost of, and the energy and cost savings likely to be
realized from, acquiring and installing each energy conservation measure
that indicate a significant potential for saving energy based upon the
technical assistance analyst's initial consideration.
In accordance with Federal rules (10CFR 455.42) , at the conclusion of
the technical assistance program, the technical assistance analyst shall
prepare a final report which shall include:
1. A description of building characteristics and energy data
including:
a. The results of the prelimin
audit (or its equivalent) of the builldings and energy
;ergy audit
• b. The operating characteristics of energy using systems;
and
c. The estimated remaining useful life of a building.
2. An analysis of the estimated energy consumption of. the build-
ings, by fuel type (in total Btu's and Btu/sq. ft./yr.) , at
optimum efficiency (assuming implementation of all energy
• conservation.maintenance and operating procedures) .
3. An evaluation of the building's potential for solar conver-
sion, particularly for water heating systems.
4. A listing of any known local zoning ordinances and building
codes which may restrict the installation of solar systems.
5. A description and analysis of all recommendations, if any, for
acquisition and installation of energy conservation measures,
including solar and other renewable resource measures, setting
forth:
a. A description of each recommended energy conservation
measure;
b. An estimate of the cost of design, acquisition and
installation of each energy conservation measure;
C c. An estimate of the useful life of each energy conser-
vation measure;
d. An estimate of increases or decreases in maintenance and
operating costs that would result from each energy con-
servation measure, if any;
e. An estimate of the annual energy and energy cost savings
(using current energy prices) expected from the acquisi-
tion and installation of each energy conservation measure.
In calculating the potential energy cost savings of each
recommended energy conservation measure, including solar
or other renewable resource measure, technical assistance
analysts shall:
1) Assume that all energy savings obtained from energy
conservation maintenance and operating procedures
have been realized;
.2) Calculate the total energy and energy cost savings,
by fuel type, expected to result from the acquisition
and installation of all recommended energy conservation
measures, taking into account the interaction among
the various measures; and,
3) Calculate that portion of the total energy and
• energy cost savings, as determined in (2) above,
attributable to each individual energy conservation
measure.
3
• f. The simple payback period of each recommended energy
conservation measure, taking into account the inter-
actions among the various measures. The simple payback
period is calculated by dividing the estimated total cost
of the measure, as determined pursuant to 5 (b) of this
section. For the purposes of ranking applications, the
simple payback period shall be calculated using the cost
savings resulting from energy savings only, determined on
the basis of current energy prices. The estimated cost
of the measure shall be the total cost for design and
• other professional services (excluding costs of a technical
assistance program), if any, and acquisition and instal-
lation costs. Other economic analyses, such as life-
cycle costing, which consider all costs and cost savings,
such as maintenance costs and/or savings, resulting from
an energy conservation measure, are recommended, but not
required, for use by the institution in its decision
making process.
6. A listing of energy use and cost data for each fuel type used
for the prior 12-month period.
7. A signed and dated certification that the technical assistance
program has been conducted in accordance with the requirements
of this section and that the data presented is accurate to the
best of the technical assistance analyst's knowledge.
QUALIFICATIONS FOR TECHNICAL ASSISTANCE ANALYST UNDER'THIS REQUEST FOR
{ PROPOSAL
To qualify as a technical assistance analyst for the Request for Proposal,
the OEC and Weld County require that such analysts:
1. have experience in energy conservation* and be a registered
professional engineer licensed under the regulatory authority
of the State of Colorado; or
2. have experience in energy conservation and be a licensed
architect under the regulatory authority of the State of
Colorado; or
3. be an architect-engineer team, the principal members of which
have experience in energy conservation and are licensed under
the regulatory authority of the State; and
4. be free from financial interests which conflict with the
proper performance of their duties.**
•
* "Energy conservation experience" can mean a) demonstrated
experience in conducting professional energy audits, and/or b)
experience in the design of energy efficient systems commonly
found in the building(s) selected for the analysis. Archi-
tects and engineers must meet the same criteria for energy
conservation experience.
. . ** "Free from financial conflict of interest" means free of
financial interests in the products or equipment which would
be acquired or installed under this program. The term is not
intended to prohibit technical assistance analysts from per-
forming the detailed design work which may be necessary as
part of grant awards for ECM's.
BIDDER QUALIFICATIONS
•
The County must have evidence of the bidder's ability to provide the
services described in this Request for Proposal. The bidder must answer
the following questions:
1. How many years has your firm been in the business?
2. Are you able to provide the technical assistance as described
above?
3. The successful bidder must be able to provide a Performance n
Bond in the full amount of the contract award.
SCHEDULE
March 6, 1980 - Pre-bid conference.
March 21, 1980 - Submittal of bid.
March 26, 1980 - Submit bid to Board of County Commissioners.
March 27, 1980 - Interview firms submitting proposals.
March 31, 1980 - Work session with Board.
April 7, 1980 - Award of contract.
PROCEDURES FOR SUBMITTAL
•
All proposals should be submitted to the Director of Purchasing on or
before March 21, 1980 at 1:00 p.m.
EVALUATION OF PROPOSALS
Upon receipt of all proposals, an evaluation team shall evaluate the
firms proposals and then shall interview the firms that, in the County's
opinion, can accomplish the task outlined in the Request for Proposal.
After interviewing the selected firm or firms, the Board shall take one
of two courses of action:
1. Request a firm to perform the tasks outlined in the Request
for Proposal.
2. Notify all parties submitting proposals that the constraints
identified in the interview process or in evaluating the pro-
posals makes it impossible to select any of the firms.
`J
e
If the Board does not make a selection, it may request additional pro-
posals from other sources or determine that the restraints identified in
the evaluation process disallow the selection of any firm to perform the.
( task outlined in the proposal.
ADDITIONAL INSTRUCTIONS/INFORMATION
• It is understood that the Board of County Commissioners reserves the
right to reject any and all of the proposals, to waive any informalities
in the proposal process, and to accept the proposal that, in the opinion
of the Board, is in the best interest of the Board and of the County of
Weld, State of Colorado.
Successful firm shall indemnify and hold-harmless Weld County against
all claims for royalties, for patents, or for suits for infringement
thereon, which may be involved in providing the services requested.
Cost will not be the determining factor. The County reserves the right
to refuse the lowest bid, and select the overall best qualified bidder.
All factors relating to the bid will be carefully weighed.
Project coordination will be accomplished through the Superintendent of
Buildings and Grounds of Weld County, Colorado.
The proposal shall be sent in a sealed envelope furnished by the Pur-
chasing Department of Weld County, Colorado. Six copies of the proposal
must be submitted.
In snhm{tting the proposal, the vendor agrees that the acceptance of any
or all of the bid by the County within a reasonable time or period
constitutes a contract. No delivery of service or payment for service
shall take place unless a contract has first been issued by the Purchasing
Director of Weld County, Colorado, or the Board of County Commissioners.
Weld County reserves the right to request additional information from
all bidders in the evaluation process if clarification of proposal is •
necessary.
•
•
•
•
Hello