The URL can be used to link to this page

Browse Search

Home My WebLink About20112582.tiff DBIA Design-Build Change Order Form For Use with DBIA Document No. 525, Standard Form of Agreement Between Owner and Design-Builder—Lump Sum (2010 Edition) and DBIA Document No. 530, Standard Form of Agreement Between Owner and Design-Builder— Cost Plus Fee with an Option for A Guaranteed Maximum Price (2010 Edition) Change Order Number: 004 Change Order Effective Date: (date when executed by both parties) Project Alternate Dispatch Center Design-Builder's Project No: 11467CO Date of Agreement: 3/1/2012 Owner: Weld County Design-Builder: Roche Constructors, Inc. COR#5— 1) Remove block retaining wall on west side of existing building; 2) Fix screen Scope of the Change: walls on east side of building; remaining walls will be repointed and patched; 3) Install new screen wall with foundation on east side of building; to be painted to match existing. Original Contract Price: $ 74,155 Net Change by Previous Change Order No(s): 0 to: 3 $ 698,545 This Change Order Increase/Decrease (attach breakdown): $ 7,140 New Contract Price: $ 779,840 Original Contract Completion Date: June 1 2012 Adjustments by Change Order No(s): 0 to: 3 98 (calendar days) This Change Order Contract Time Increase/Decrease: 0 (calendar days) Revised Substantial Completion Date: September 7 2012 By executing this Change Order, Owner and Design-Builder agree to modify the Agreement's Scope of Work, Contract Price and Contract Time as stated above. Upon execution, this Change Order becomes a Contract Document issued in accordance with DBIA Document No. 535, Standard Form of General Conditions of Contract Between Owner and Design- Builder, (2010 Edition). OWNER: DESIGN-BUILDER: By: t 2 By: Printed Name: Sean P. Conway Printed Name: �se Schuchman Title: Chair Board of Weld County Commissioners Title: Project Manager Date: JUN 1 1 2012 Date: June 1, 2012 DBIA Document No. 50002-Design-Build Change Order Form I. µj`t- D//_ 5f ©2001 Design-Build Institute of America 161-,A1 F/Doss ROCHE CONSTRUCTORS, INC. SUMMARY SHEET Alternate Dispatch Center Greeley, CO RCI Project#11467CO RCI's COR# 5 Date: May 31,2012 Description of Change: 1. Remove block retaining wall on west side of existing building all the way down to foundation. Foundation is to remain in place. 2. Weld County would like Roche to fix the screen walls that are on the east side of the building. This will be the new location of the generator. Two of the walls the top needs to be taken off and replaced with new block, the remaining walls will be repointed and patched. 3. A new screen wall with foundation will need to be installed on the east side of the building to block the west side of the generator. New screen wall will be painted to match existing. Company Amount Roberts Excavation Corp $1,790.00 Wintergreen Painting $300 C.Morgan Masonry $3,781 Christopher Concrete $500 Sub-Total $6,371.00 General Liability Insurance (.55%) 35.04 Builders Risk Insurance (.55%) 35.04 $6,441.08 Roche Constructors Breakdown: Material Sub/Equip Labor Sub-Totals $ $ $ 0 Taxes (0%matt 50.00%labor burden) 0 0 0 Sub-Total RCI Total $ - Summary: Subcontractor Totals $ 6,441.08 Mark-Up on Sub Work (10%) $ 644.11 Overhead (3%) on Roche Self Performed Work $ 0.00 Profit (2%) on Roche Self Performed Work $ 0.00 Sub-Total $ 7,085.19 Payment& Performance Bond (.775%) $ 54.91 Total: Total $ 7,140.00 This price is good for seven (7) days. Time extension required for this work: 0 Approved by Date • F.: z 7:7 :•:- • • •.1 avation CORPORATION • PROJECT NAME: WELD CTY COMMUNICATIONS CENTER Unft Descri Lion _ Sub total PER JESSE:PRICE TO DEMO&REMOVE DEBRIS FORM SITE 30LF X 6 FT HIGH BLOCK RETAINING WALL.NO FOOTER OR FOUNDATION REMOVAL INCLUDED IN PRICING ASSUME WE WILL HAVE EQUIPMENT ON SITE&NO MOBILIZATION WILL BE REQUIRED ASSUME BLOCK WALL IS NOT GROUTED WALL&HAS NO REBAR 1 EA HAUL OFF DEBRIS/DUMP FEE I LS BACKHOE/OPERATOR 1 LS NON EQUIPMENT OPERATOR TIME 1 HR FOREMAN/PICKUP TRAVEL TIME ADDED 5-31-12 PER JESSE 4 {-IRS MOBILIZATION OF EQUIPMENT 1 EA EXCAVATE&BACKFILL FOR SCREEN WALL 10 LF LONG 1 LS BACKHOE/OPERATOR!NON EQUIPMENT OPERATOR 1 LS FOREMAN/PICK UP TRAVEL TIME TOTAL COST FOR WALL REMOVAL $ 1,790.00 ASSUME WATER IS ON SITE FOR BACKFILL OPERATIONS NO HAUL OFF OF EXCESS SOILS FROM EXCAVATION OPERATIONS INCLUDED IN PRICING. ASSUME EXCAVATION FOR SCREEN WALL IS TO BE MAX.3.5 FT DEEP 4 FT WIDE& 10 LF LONG THANK YOU FOR THE OPPORTUNITY TO COMPLETE WORK REQUIRED I Sub Tota I PAGE 1 OF 1 TOTAL COST $1,790.00 WINTERGREEN CONSTRUCTION SERVICES Inc. 5293 Ward Road Phone: 303-936-8568 Unit#9 Fax: 303-937-3742 Arvada,CO 80002 jswintergreenconst@hotmail.com May 30, 2012 To:Jesse Schuchman—Roche Constructors Subject:Weld County Dispatch Center Re: Proposal Dear Jesse, This proposal is for painting screen wall on roof. Exclusions&Qualifications: 1. Substrate of screen wall is CMU/Block. Base Bid: $300.00 If you have any questions or concerns, please call my office at 303-936-8568 or cell at 720-763-5584. Thank You, 4 eel Sit c l4 Loren Epifano-Estimator Wintergreen Construction Services Jesse Schuchman From: Gregg Sumey <gregg@c-morgen.com> Sent: Wednesday, May 30, 2012 9:39 AM To: Jesse Schuchman Cc: eric@c-morgen.com Subject Alternate Comm Center - CMU Screen walls Jesse, Eric with CMMI has given me dimensions for 2 CMU stem walls that need to be priced . 1. Demo 90/sf of existing CMU, re-lay 90/sf of new CMU with a CMU cap. Material: $ 549.00 8" CMU: 102/ea CMU caps: 30/ea Grout: 1.5/cy Mortar: .4/cy Durowall: 60/If Rebar: 175/If Direct Labor: $ 936.00 Labor Burden: $ 374.00 Equipment: $ 327.00 Subtotal: $ 2,186.00 Profit and Overhead: $ 219.00 Total Extra Cost: $ 2,405.00 2. Provide new 8' long X 7'Tall CMU wall. Material: $ 287.00 8" CMU: 63ea CMU caps: 6/ea Grout: .6/cy Mortar: .2/cy Durowall:43/If Rebar: 51/If Direct Labor: $ 395.00 Labor Burden: $ 158.00 Equipment: $ 138.00 Subtotal: $ 978.00 Profit and Overhead: S 98.00 Total Extra Cost: $ 1,076.00 3OO 5Tet& w ACC. Please let me know if we should proceed with the work or if you have any questions or need additional information. Thanks Gregg A.Sumey President C. Morgen Masonry, Inc. 303-654-1742(o) 1 DBIA Design-Build Change Order Form For Use with DBIA Document No. 525, Standard Form of Agreement Between Owner and Design-Builder—Lump Sum (2010 Edition)and DBIA Document No. 530, Standard Form of Agreement Between Owner and Design-Builder— Cost Plus Fee with an Option forA Guaranteed Maximum Price(2010 Edition) Change Order Number: 003 Change Order Effective Date: (date when executed by both parties) Project: Alternate Dispatch Center Design-Builder's Project No: 11467CO Date of Agreement: 3/1/2012 Owner: Weld County Design-Builder. Roche Constructors Inc. COR#3—Add in to the contract the payment and performance bond which was included in Scope of the Change the original scope of work. Original Contract Price: $ 74,717 Net Change by Previous Change Order No(s): 0 to: 2 $ 699,107 This Change Order Increase/Decrease (attach breakdown). $ 0 772,700 New Contract Price: Stipulated Sum $ Original Contract Completion Date: June 1, 2012_ Adjustments by Change Order No(s) 0 to: 2 98 (calendar days) This Change Order Contract Time Increase/Decrease: 0 - (calendar days) Revised Substantial Completion Date: September 7, 2012_ By executing this Change Order, Owner and Design-Builder agree to modify the Agreement's Scope of Work, Contract Price and Contract Time as stated above. Upon execution, this Change Order becomes a Contract Document issued in accordance with DBIA Document No. 535, Standard Form of General Conditions of Contract Between Owner and Design- Builder, (2010 Edition). OWNER: ^ ESIGN- UIL .. By: N --- By: Printed Name: Sean P. Conway Printed Name: Jes Schuchman Title: Chair Title: Project Manager Date: APR 0 2 2012 Date: 03/26/2012 n 1 Dy. -ED Tab . 1t,Z-120BIA Document No-500D2-Design-Build Change Order Form � yC r pu ;kw- oS.Sy r� 1 c 2001 Design-Build Institute of America 4 - L-tZ f/ Oo53 ROCHE CONSTRUCTORS, INC. SUMMARY SHEET Alternate Dispatch Center Greeley,CO RCI Project N 11467OO RCI's COR# 3 Date: Moroi')26,2012 Description of Change: Change the contract to include the paument and performance bond that was In the original contract scope of work. Company Amount Roche Constructors. Inc. $0.00 Sub-Total $0.00 General I ohi!ity!nsuranc;e (.55%) Inc. Builders Risk Insurance (.55%) Inc. $0.00 Roche Constructors Breakdown: Material Jut2 Equip Lcabor Sub Totals $ $ S 0 Taxes (0%rnat'l:50.00%labor burden) 0 0 0 Sub-Total $ $ - $ - RCI Total $_ Summary: Subcontractor totals $ 0.00 Mark Up on Suo Work (10%) $ Inc. Overhead(3%) on Roche Self Performed Work $ 0.00 Profit (2%) on Roche Self Performed Work $ 0.00 Sub-Total $ 0.00 Payment&Performance Bond(.775%) $ Inc. Total: Total $ 0.00 This price is cd000 for seven(7) days. Time extension required for this work: 0 Approved by__—.. __ Dale ._ Article 10 Bonds and Insurance 10.1 Insurance. Design-Builder and Owner shall procure the insurance coverages set forth in the Insurance Exhibit attached hereto and in accordance with Article 5 of the General Conditions of Contract. 10.2 Bonds and Other Performance Security. Design-Builder shall provide the following performance bond and labor and material payment bond or other performance security. Performance Bond. (Check one box only. If no box is checked, then no bond is required.) ® Required: [i Not Required Payment Bond. (Check one box only. If no box is checked, then no bond is required) ® Required, ❑ Not Required Other Performance Security. (Check one box only. If no box is checked, then no other performance security is required. If the "Required"box is checked, identify below the specific performance security that is being required and all salient commercial terms associated with that security.) ❑ Required; Z Not Required Article 11 Other Provisions 11.1 Other provisions, if any, are as follows: (Insert any additional provisions) Roche Constructors, Inc., Request for Proposal Response dated September 29, 2011 fin lieu of Sections 10.3.1 through 10.3.3 of the General Conditions of Contract, the Parties may want to delete such sections and include the following alternative disputes proceeding clause.] Any claims, disputes, or controversies between the parties arising out of or related to the Agreement, or the breach thereof,which have not been resolved in accordance with the procedures set forth in Section 10.2 of the General Conditions of Contract shall be resolved in a court of competent jurisdiction in the state in which the Project is located. DBIA Document No.525 Standard Form of Agreement Page 10 Between Owner and Design-Builder- Lump Sum :02009 Design-Build Institute of America JS, 3/L6fiZ CO*k3 DBIA Design-Build Change Order Form For Use with DBIA Document No. 525, Standard Form of Agreement Between Owner and Design-Builder—Lump Sum (2010 Edition) and DBIA Document No. 530, Standard Form of Agreement Between Owner and Design-Builder— Cost Plus Fee with an Option forA Guaranteed Maximum Price (2010 Edition) Change Order Number: 002 Change Order Effective Date: (date when executed by both parties) Project: Alternate Dispatch Center Design-Builder's Project No: 11467CO Date of Agreement: 3/1/2012 Owner: Weld County Design-Builder: Roche Constructors Inc. COR#2—Adding in the stipulated sum for the construction drawings from Hauser Architects dated 1/31/2012 and specifications dated 1/12/2012. Scope of the Change: Original Contract Price: $ 74,717 Net Change by Previous Change Order No(s): 0 to: 1 $ 562.00 This Change Order Increase/Decrease (attach breakdown): $ 698,545 772,700 New Contract Price: Stipulated Sum $ Original Contract Completion Date: June 1, 2012_ Adjustments by Change Order No(s) 0 to: 1 0 (calendar days) This Change Order Contract Time Increase/Decrease: 98 (calendar days) Revised Substantial Completion Date: September 7, 2012_ By executing this Change Order, Owner and Design-Builder agree to modify the Agreement's Scope of Work, Contract Price and Contract Time as stated above. Upon execution, this Change Order becomes a Contract Document issued in accordance with DBIA Document No. 535, Standard Form of General Conditions of Contract Between Owner and Design- Builder, (2010 Edition). • DESIGN-B IL E' : By: ✓ BY Printed Name: Sean P Conway Printed Name: Jesse huchman Title: Chair Title: Project Manager Date: MAR 1 4 2912 Date: 03/06/2012 1 On9\DToby7 &11-i-la (90/// —a5&a DBIA Document No. 500D2-Design-Build Change Order Form at: 6wv ,C/ e'o. 3 ©2001 Design-Build Institute of America .3-/U-A2 ROCHE CONSTRUCTORS, INC. SUMMARY SHEET Alternate Dispatch Center Greeley,CO RC' Project #11467CO RCI's COR# 2 Date: March 6, 2012 Description of Change: This COR is to change the DBIA contract that is in place dated 11/16/2012 from the original scope of the RFP on design, original GC's,and Fee to a stipulated sum per the Construction Set of drawings from Hauser Architects dated January 31 and specifications dated 1/12/12. The proposal was sent to Weld County excluding the Generator on 2/23/2012 for a total amount of$698,545. The current schedule is changing the final completion date to September 7,2012. Company Amount Roche Constructors, Inc. $698,545.00 Sub-Total $698,545.00 General Liability Insurance (.55%) Inc. Builders Risk Insurance(.55%) Inc. $698,545.00 Roche Constructors Breakdown: Material Sub/Equip Labor Sub-Totals $ $ $ 0 Taxes (0%mat'I;50.00%labor burden) 0 0 0 Sub-Total - RCI Total $ - Summary: Subcontractor Totals $ 698,545.00 Mark-Up on Sub Work (10%) $ Inc. Overhead (3%) on Roche Self Performed Work $ 0.00 Profit (2%) on Roche Self Performed Work $ 0.00 Sub-Total $ 698,545.00 Payment& Performance Bond (.775%) $ Inc. $ Total: Total $ 698,545.00 This price is good for seven (7) days. Time extension required for this work: 0 Approved by Date ROCHE CONSTRUCTORS,INC. Bid Summary CO11073 Weld County Alternate Dispatch Addition, Greeley Bid Date&Time: Feb 16,2012 2pm [new] [renovated] Total building area,(sgft(: 3.336 2,015 I 1,321 Site area: 0.50 acres Duration[Specified],[As Bid]: 120 120 C Days Liquidated Damages: N/A Estimator: DZ/FB All# I Provide Card 4 Description BID Total $/SF %/Tot Generator CI Testing&Surveying $ 5,395 1.62 0.70% not in est. 02 Demolition/Earthwork/Utilities $ 30,430 9.12 3.94% not in est. 03 Paving:Asphalt 8.Concrete $ 485 0.15 0.06% not in est. 04 Utilities $ 3.500 1.05 0.45% nor in est. 05 Landscaping/Fence/Improvements $ 5,840 I 75 0.76% not in est. 06 Concrete $ 24,533 745 5fl not in est. 07 Selective Demolition $ 4,200 1.26 0.54% not in est. Q$ Masonry $ 45.400 IS 61 £55e not in est. 09 Steel $ 25.702 7.52 3.25% not in est. 10 Carpentry $ 9.100 2O3 1.19% not in est. 11 Damp/Waterproofing/Caulking $ 5.135 1.54 0.66% not in est. 12 Insulation/Fireproofing/Firestoping not in estimate - 0.00% not in est. 13 Rooting/Sheefinefal/Metal Siding $ 34,999 10.49 4.53% not in est. 14 Skylights&Roof Accessories not in estimate - 0.00% not in ed. I S Door/Frames/Hardware $ 12,885 3.86 1 67% not in est. 16 Overhead/Specialty Doors not in estimate - 0.00% not in est. 17 Storefront/Glass/Glazing $ 608 0.18 0.08% not in est. L4 Drywall/EFIS/Plaster/Acoustical $ 18.832 5 64 254% not in est. I9 Tile/Resilient/Carpet $ 15.365 4.61 1.99% not in est. 20 Paint&Wallcoyedng $ 7,748 ____ 32 I.QO% not'in est. 21 Specialties $ 1,663 0.50 0.22% not In est. 22 Equipment not in estimate - 0.00% not in est. 23 Furnishings not in estimate - 0.00% not in est. 24 Special Construction not in estimate - 0.00% not in en. 25 Elevators&Conveying Systems not in estimate - 0.00% not in est. L Plumbing 5 42500 1274 5.53.3$ not in est. 27 HVAC 5 94473 28.30 12.22% not in est. Lq Electrical 5 166.142 49 BQ 21 50°' 5 72.352 19 4?$Panels(A-30KW,8-60KW) 5 102.042 3059 r31155 not est- 30 Architect&Engineering Fees not in estimate - 0.30% not in est. 0.00% Cost of Work Sub Total $ 656.317 196.74 84.94% $ 71352 0.25%Warranty $ 1.641 0.49 0.21% $ 181 0.00% Bond to 300.000(Original)* $ 2,490 0.75 0.32% $ - 0.00%Bond from 300,000 to final price $ 5,010 1.50 0.65% $ General Conditions* $ 37.140 11.13 4.81% owner Permit by owner nvnulE. - $ 1% Builders Risk $ 1,284 0.39 0.17% $ 0.55%Gen Liability Insurance $ 3.907 1.17 0.51% $ 403 OH&Fee to 300.000(Original)' $ 15.000 4.50 1.94% $ OH&Fee 300,000 to final price $ 23635 7.08 3.06% $ - Arch&Eng Fee(Original(' $ 20,025 6.00 2.59% $ Arch&Eng Fee 300000 to final price I 6,050 1.81 0.78% $ Bid Total $ 772.499 231.56 100% $ 72,936 CUT/ADD: 5 $ . Actual Amount Bid $ 772,700 231.62 100% $ 73,000 General Condlliens $ 9.440 5%= $ 38,635 List OHaFee t 5.090 1%= $ 7,727 list FILE:2 BID DAY Summary Weld County Expansion 3/5/2012-1:22 PM Page: 1 of I • DBIA Design-Build Change Order Form For Use with DBIA Document No. 525, Standard Form of Agreement Between Owner and Design-Builder—Lump Sum (2010 Edition) and DBIA Document No. 530, Standard Form of Agreement Between Owner and Design-Builder— Cost Plus Fee with an Option for A Guaranteed Maximum Price(2010 Edition) Change Order Number: 001 Change Order Effective Date: (date when executed by both parties) Project: Alternate Dispatch Center Design-Builder's Project No: 11467CO Date of Agreement: 2/2/2012 Owner. Weld County Design-Builder. Roche Constructors Inc. COR#1 -Additional Design Services that were requested by Weld County on existing Scope of the Change: building. Original Contract Price: $ 74,155 Net Change by Previous Change Order No(s): 0 to: 1 $ 0 This Change Order Increase/Decrease (attach breakdown): $_562.00 74,717 New Contract Price: $ Original Contract Completion Date: June 1, 2012_ Adjustments by Change Order No(s) 0 to: 1 0 (calendar days) This Change Order Contract Time Increase/Decrease: 0 (calendar days) Revised Substantial Completion Date: — June 1 2012_ By executing this Change Order, Owner and Design-Builder agree to modify the Agreement's Scope of Work, Contract Price and Contract Time as stated above. Upon execution, this Change Order becomes a Contract Document issued in accordance with DBIA Document No. 535, Standard Form of General Conditions of Contract Between Ow r and Design- Builder, (2010 Edition). / (Ott? OWNER: /DDESIGN-BUI ER: By: �� By`--- Printed Name: Sean P. Conway a Printed Name: Jesse Schuchman Title: Chair, Board of Weld County Commissioners Title: Project Manager Date: FEB 2 7 2012 Date: 2/022/2012 I �i IoT h O DBI DocumertNo. 500D2-Design-Build Change Order Form i7/427 Ct, . 13`14--t ‘,190//— 25.47 O2001 Design-Build Institute of America eo L G��1 C" c /Dia' a-ail-11 F� DoJsr ROCHE CONSTRUCTORS, INC. SUMMARY SHEET Alternate Dispatch Center Greeley,CO RCI Project#11467CO RCI's COR# 1R Date: February 2,2012 Description of Change: 1. There has been a modification from the RFP for additional design services for the existing building. Structural needs to add$500 for new RTU being placed on existing roof framing. Company Amount Hauser Architect $500.00 Sub-Total $500.00 General Liability Insurance (.55%) 3.00 Builders Risk Insurance (.55%) 3.00 $506.00 Roche Constructors Breakdown: Material Sub/Equip Labor Sub-Totals $ $ $ 0 Taxes (0%mat'I;50.00%labor burden) 0 0 0 Sub-Total $ - $ - $ - RCI Total $ - Summary: Subcontractor Totals $ 506.00 Mark-Upon Sub Work(10%) $ 51.00 Overhead (3%) on Roche Self Performed Work $ 0.00 Profit (2%) on Roche Self Performed Work $ 0.00 Sub-Total $ 557.00 Payment& Performance Bond (.775%) $ 5.00 Total: Total $ 562.00 This price is good for seven (7) days. Time extension required for this work: 0 Approved by Date ill HAUSER February 1, 2012 Mr. Jesse Schuchman, Project Manager Roche Constructors, Inc. 361 71st Avenue Greeley, CO 80634 Re: Weld County Alternate Communications Center Request for Additional Structural Design Fees Dear Jesse: This letter is to request an increase in the structural engineering design fee for the above referenced project. Our original structural design fee for this addition was $1800 and included foundation, masonry wall and steel framed roof design for the addition. When the decision was made to provide new roof-top mechanical units for the existing building, it necessitated checking the existing steel bar joists for required field modification due to the new dead loads of the equipment. This task was not in our original structural engineering scope. The structural engineer has requested an addition $500 for the above change in scope. This is the only design change that is being requested. This will increase the structural engineering design fee to $2300 and the project total design fee to $18,275. Please contact me at your convenience if you have further questions with regard to this request. Sincerely, Alan Hauser, AIA LEER AP Hauser Architects, P.C. .LL 1100 H Street, Nw ' D B 1 A Suite 500 Washington, D.C.20005 202.682.0110 r �. e STANDARD FORM OF AGREEMENT BETWEEN OWNER AND DESIGN-BUILDER LUMP SUM b `u'Bn4i w .�.�',. " a Tit + y sP ' '� i ;r �" + „�a' • *5 et+n!r'r - f # F : :aa Document No 525 tik Second Edition, 20091Q' Design-Build Institute of America e� ► Washington DC WWW.DBIA.ORG QQL� /� 5- C%i CC �k °' 12� �� aoI/- 8� DBIA STANDARD FORM OF AGREEMENT BETWEEN OWNER AND DESIGN- BUILDER - LUMP SUM Document No. 525 Second Edition, 2009 ©Design-Build Institute of America Washington, DC 0.20//- 58a Fi 0o53 DBIA Standard Form of Agreement Between Owner and Design-Builder - Lump Sum This document has important legal consequences. Consultation with an attorney is recommended with respect to its completion or modification. This AGREEMENT is made as of the 16th day of November in the year of 2011, by and between the following parties, for services in connection with the Project identified below. OWNER: (Name and address) Weld County, Colorado 1111 H Street Greeley, CO 80631 DESIGN-BUILDER: (Name and address) Roche Constructors, Inc. 1235 W. 124th Avenue, Suite 100 Westminster, CO 80234 PROJECT: (Include Project name and location as it will appear in the Contract Documents) Weld County Alternate Communications Dispatch Center 3105 35th Avenue Greeley, CO 80634 In consideration of the mutual covenants and obligations contained herein,Owner and Design-Builder agree as set forth herein. DBIA Document No.525 Standard Form of Agreement Page 1 Between Owner and Design-Builder- Lump Sum ©2009 Design-Build Institute of America Article 1 Scope of Work 1.1 Design-Builder shall perform all design and pre-construction services, and provide all material, equipment, tools and labor, necessary to complete the Work described in and reasonably inferable from the Contract Documents. Cost of construction will be added at completion of design by change order. Article 2 Contract Documents 2.1 The Contract Documents are comprised of the following: .1 All written modifications, amendments, minor changes and Change Orders to this Agreement issued in accordance with DBIA Document No.535, Standard Form of General Conditions of Contract Between Owner and Design-Builder (2009 Edition) ("General Conditions of Contract"); .2 The Basis of Design Documents, including the Owner's Project Criteria, Design-Builder's Proposal and the Deviation List, if any, contained in the Design-Builder's Proposal, which shall specifically identify any and all deviations from Owner's Project Criteria; .3 This Agreement, including all exhibits and attachments, executed by Owner and Design- Builder (List for example, performance standard requirements, performance incentive requirements, markup exhibits, allowances, or unit prices); .4 Written Supplementary Conditions, if any, to the General Conditions of Contract; .5 The General Conditions of Contract; and .6 Construction Documents prepared and approved in accordance with Section 2.4 of the General Conditions of Contract Article 3 Interpretation and Intent 3.1 Design-Builder and Owner, prior to execution of the Agreement,shall carefully review all the Contract Documents, including the various documents comprising the Basis of Design Documents for any conflicts or ambiguities. Design-Builder and Owner will discuss and resolve any identified conflicts or ambiguities prior to execution of the Agreement. 3.2 The Contract Documents are intended to permit the parties to complete the Work and all obligations required by the Contract Documents within the Contract Time(s) for the Contract Price. The Contract Documents are intended to be complementary and interpreted in harmony so as to avoid conflict,with words and phrases interpreted in a manner consistent with construction and design industry standards. In the event inconsistencies, conflicts, or ambiguities between or among the Contract Documents are discovered after execution of the Agreement, Design-Builder and Owner shall attempt to resolve any ambiguity, conflict or inconsistency informally, recognizing that the Contract Documents shall take precedence in the order in which they are listed in Section 2.1 hereof. Conflicts existing within Section 2.1.2 shall be resolved by giving DBIA Document No.525 Standard Form of Agreement Page 2 Between Owner and Design-Builder- Lump Sum ©2009 Design-Build Institute of America precedence first to the Deviation List, if any,then the Owner's Project Criteria, and then the Design Builder's Proposal. 3.3 Terms,words and phrases used in the Contract Documents, including this Agreement,shall have the meanings given them in the General Conditions of Contract. 3.4 If Owner's Project Criteria contain prescriptive/design specifications:(a)Design-Builder is entitled to reasonably rely on the accuracy of the information represented in the prescriptive/design specfcations and its compatibility with other information set forth in Owner's Project Criteria, including any design performance specifications;and(b)Design-Builder shall be entitled to an adjustment in its Contract Price and/or Contract Time(s)to the extent Design-Builder's cost and/or time of performance have been adversely impacted by such inaccurate prescriptive/design specification. 3.5 The Contract Documents form the entire agreement between Owner and Design-Builder and by incorporation herein are as fully binding on the parties as if repeated herein. No oral representations or other agreements have been made by the parties except as specifically stated in the Contract Documents. 3.6 In the event of an ambiguity in the Contract Documents, the parties shall be deemed to have jointly authored them, and as such, nothing shall be construed against or in favor of one party based on its being deemed the sole author. Article 4 Ownership of Work Product 4.1 Work Product. All drawings, specifications and other documents and electronic data,including such documents identified in the General Conditions of Contract,furnished by Design-Builder to Owner under this Agreement ("Work Product") are deemed to be instruments of service and Design-Builder shall retain the ownership and property interests therein, including but not limited to any intellectual property rights,copyrights and/or patents, subject to the provisions set forth in Sections 4.2 through 4.5 below. 4.2 Owner's Limited License Upon Project Completion and Payment in Full to Design Builder. Upon Owner's payment in full for all Work performed under the Contract Documents,Design-Builder transfers to Owner all ownership and property interests, including but not limited to any intellectual property rights, copyrights and/or patents, in the Work Product. Such transfer is conditioned on Owner's express understanding that its alteration of the Work Product without the involvement of Design Builder is at Owner's sole risk and without liability or legal exposure to Design-Builder or anyone working by or through Design- Builder, including Design Consultants of any tier(collectively the"Indemnified Parties"), and on the Owner's obligations to provide the indemnity set forth in Section 4.5 herein. 4.3 Owner's Limited License upon Owner's Termination for Convenience or Design-Builder's Election to Terminate. If Owner terminates this Agreement for its convenience as set forth in Article 8 hereof,or if Design-Builder elects to terminate this Agreement in accordance with Section 11.4 of the General Conditions of Contract, Design-Builder shall, upon Owner's payment in full of the amounts due Design-Builder under the Contract Documents,grant Owner a limited license to use the Work Product to complete the Project and subsequently occupy the Project, and Owner shall thereafter have the same rights as set forth in Section 4.2 above, conditioned on the following: .1 Use of the Work Product is at Owner's sole risk without liability or legal exposure to any Indemnified Party and on the Owner's obligation to provide the indemnity set forth in Section 4.5 herein; and DBIA Document No.525 Standard Form of Agreement Page 3 Between Owner and Design-Builder- Lump Sum ©2009 Design-Build Institute of America .2 Owner agrees to pay Design-Builder the additional sum of Zero Dollars ($ 0.00 )as compensation for the right to use the Work Product to complete the Project and subsequently use the work Product in accordance with this Section 4.2 if Owner resumes the Project through its employees, agents, or third parties. 4.4 Owner's Limited License upon Design-Builder's Default. If this Agreement is terminated due to Design-Builder's default pursuant to Section 11.2 of the General Conditions of Contract,then Design-Builder grants Owner a limited license to use the Work Product to complete the Project and subsequently occupy the Project, and Owner shall thereafter have the same rights and obligations as set forth in Section 4.2 above. Notwithstanding the preceding sentence, if it is ultimately determined that Design-Builder was not in default, Owner shall be deemed to have terminated the Agreement for convenience, and Design-Builder shall be entitled to the rights and remedies set forth in Section 4.3 above. 4.5 Owner's Indemnification for Use of Work Product. If Owner is required to indemnify any Indemnified Parties based on the use or alteration of the Work Product under any of the circumstances identified in this Article 4,Owner shall defend, indemnify and hold harmless the Indemnified Parties from and against any and all claims,damages, liabilities, losses and expenses,including attorneys'fees,arising out of or resulting from the use or alteration of the Work Product. Article 5 Contract Time 5.1 Date of Commencement. The Work shall commence within five(5)days of Design-Builder's receipt of Owner's Notice to Proceed ("Date of Commencement") unless the parties mutually agree otherwise in writing. 5.2 Substantial Completion and Final Completion 5.2.1 Substantial Completion of the entire Work shall be achieved no later than June 1, 2012 . [At the parties'option, the following supplemental language may be inserted at the end of Section 5.2.1] ❑ The parties agree that the definition for Substantial Completion set forth in Section 1.2.18 of the General Conditions of Contract is hereby modified to read as follows: "Substantial Completion is the date on which the Work, or an agreed upon portion of the Work, is sufficiently complete in accordance with the Contract Documents so that Owner can occupy and use the Project or a portion thereof for its intended purposes, provided, however, that Substantial Completion shall be deemed to have been achieved no later than the date of issuance of a Temporary Certificate of Occupancy issued by the local building official, if a Temporary Certificate of Occupancy is applicable to the Project." 5.2.2 Interim milestones and/or Substantial Completion of identified portions of the Work shall be achieved as follows: (Insert any interim milestones("Scheduled Interim Milestone Dates') for portions of the Work with different scheduled dates for Substantial Completion) 5.2.3 Final Completion of the Work or identified portions of the Work shall be achieved as expeditiously as reasonably practicable. Final Completion is the date when all Work is complete pursuant to the definition of Final Completion set forth in Section 1.2.7 of the General Conditions of Contract. DBIA Document No.525 Standard Form of Agreement Page 4 Between Owner and Design-Builder- Lump Sum ©2009 Design-Build Institute of America 5.2.4 All of the dates set forth in this Article 5("Contract Time(s)")shall be subject to adjustment in accordance with the General Conditions of Contract. 5.3 Time is of the Essence. Owner and Design-Builder mutually agree that time is of the essence with respect to the dates and times set forth in the Contract Documents. 5.4 Liquidated Damages. Design-Builder understands that if Substantial Completion is not attained by the Scheduled Substantial Completion Date, Owner will suffer damages which are difficult to determine and accurately specify. Design-Builder agrees that if Substantial Completion is not attained by June 1,2012 , Designer-Builder shall pay Owner Zero Dollars ($0.00) as liquidated damages for each day that Substantial Completion extends beyond the LD Date. 5.5 Any liquidated damages assessed pursuant to this Agreement shall be in lieu of all liability for any and all extra costs, losses,expenses, claims, penalties and any other damages,whether special or consequential, and of whatsoever nature incurred by Owner which are occasioned by any delay in achieving Substantial Completion, Interim Milestone Dates or Final Completion. Owner and Design-Builder agree that the maximum aggregate liability Design-Builder has for any liquidated damages that may be assessed under this Agreement shall be Zero Dollars ($0.00). 5.6 Early Completion Bonus. If Substantial Completion is attained on or before N/A ( N/A ) days before the Scheduled Substantial Completion Date(the"Bonus Date"), Owner shall pay Design-Builder at the time of Final Payment under Section 7.3 hereof an early completion bonus of N/A Dollars ($ N/A )for each day that Substantial Completion is attained earlier than the Bonus Date. Owner and Design-Builder agree that the maximum aggregate amount that Design-Builder shall receive as the early Completion Bonus is Zero Dollars ($ 0.00 1 5.7 (The Parties may also desire to modify Article 8.2.2 of the General Conditions of Contract relative to compensability of delays that would cause the Contract Time(s) to be extended. In such case, the following option can be used.] O In addition to Design-Builder's right to a time extension for those events set forth in Section 8.2.1 above, Design-Builder shall also be entitled to an appropriate adjustment of the Contract Price for those events set forth in Section 8.2.1 above, provided, however, for Force Majeure Events, Design-Builder shall be entitled to an increase in the Contract Price providing that: (i) said events must exceed cumulative days before Design-Builder is entitled to additional compensation; and (ii)said additional compensation shall be limited to: [Check one box only] ❑ $ dollars a day for each day work is delayed beyond the Scheduled Substantial Completion Date. or ® the direct costs and expenses Design-Builder can demonstrate it has reasonably actually incurred as a result of such event. Article 6 Contract Price 6.1 Contract Price. Owner shall pay Design-Builder in accordance with Article 6 of the General Conditions of Contract the sum of Seventy-Four Thousand One Hundred Fiftv-Five Dollars ($74,155.00) ("Contract Price"), subject to adjustments made in accordance with the General Conditions of DBIA Document No.525 Standard Form of Agreement Page 5 Between Owner and Design-Builder- Lump Sum ©2009 Design-Build Institute of America Contract. Unless otherwise provided in the Contract Documents,the Contract Price is deemed to include all sales, use, consumer and other taxes mandated by applicable Legal Requirements. 6.2 Markups for Changes. If the Contract Price requires an adjustment due to changes in the Work,and the cost of such changes is determined under Sections 9.4.1.3 or 9.4.1.4 of the General Conditions of Contract, the following markups shall be allowed on such changes: .1 For additive Change Orders, including additive Change Orders arising from both additive and deductive items, it is agreed that Design Builder shall receive a Fee of Ten Percent(10%)of the additional costs incurred for that Change Order, plus any other markups set forth at Exhibit hereto. .2 For deductive Change Orders, including deductive Change Orders arising from both additive and deductive items, the deductive amounts shall include: [Check one box only] No additional reduction to account for Design-Builder's Fee or any other markup. or ❑ An amount equal to the sum of: (a) percent( %) applied to the direct costs of the net reduction(which amount will account for a reduction associated with Design-Builder's Fee); plus (b) any other markups set forth at Exhibit hereto applied to the direct costs of the net reduction. 6.3 Allowance Items and Allowance Values .1 Any and all Allowance Items, as well as their corresponding Allowance Values, are set forth in an Exhibit hereto. .2 Design-Builder and Owner have worked together to review the Allowance Items and Allowance Values based on design information then available to determine that the Allowance Values constitute reasonable estimates for the Allowance Item. Design-Builder and Owner will continue working closely together during the preparation of the design to develop Construction Documents consistent with the Allowance Values. Nothing herein is intended in any way to constitute a guarantee by Design-Builder that the Allowance Item in question can be performed for the Allowance Value. .3 No work shall be performed on any Allowance Item without Design-Builder first obtaining in writing advanced authorization to proceed from Owner. Owner agrees that if Design-Builder is not provided written authorization to proceed by the date set forth in the Project schedule,due to no fault of Design-Builder, Design-Builder may be entitled to an adjustment of the Contract Time(s) and Contract Price. .4 The Allowance Value includes the direct cost of labor, materials,equipment,transportation, taxes and insurance associated with the applicable Allowance Item. All other costs, including design fees, Design-Builder's overall project management and general conditions costs, overhead and fee, are deemed to be included in the original Contract Price, and are not subject to adjustment notwithstanding the actual amount of the Allowance Item. fin the Alternative, the parties may want to delete Section 6.3.4 and add the following provision.] ❑ In the event the actual direct cost of labor, materials, equipment, transportation, taxes and insurance associated with the applicable Allowance Item is N/A percent ( N/A %)greater than or less than the Allowance Value, Design-Builder and Owner agree that Design-Builder's right to Fee and markup shall be determined in accordance with Section 6.2. DBIA Document No.525 Standard Form of Agreement Page 6 Between Owner and Design-Builder- Lump Sum ©2009 Design-Build Institute of America .5 Whenever the actual costs for an Allowance Item is more than or less than the stated Allowance Value, the Contract Price shall be adjusted accordingly by Change Order, subject to Section 6.3.4. The amount of the Change Order shall reflect the difference between actual costs incurred by Design-Builder for the particular Allowance Item and the Allowance Value. 6.4 Performance Incentives 6.4.1 Owner and Design-Builder have agreed to the performance incentive arrangements set forth in Exhibit N/A /The parties are encouraged to discuss and agree upon performance incentives that will influence project success. These incentives may consist of Award Fees, incentives for safety,personnel retention, client satisfaction and similar items.] Article 7 Procedure for Payment 7.1 Progress Payments 7.1.1 Design-Builder shall submit to Owner on the First ( 1 ) day of each month, beginning with the first month after the Date of Commencement, Design-Builder's Application for Payment in accordance with Article 6 of the General Conditions of Contract. 7.1.2 Owner shall make payment within ten (10) days after Owner's receipt of each properly submitted and accurate Application for Payment in accordance with Article 6 of the General Conditions of Contract, but in each case less the total of payments previously made, and less amounts properly withheld under Section 6.3 of the General Conditions of Contract. 7.2 Retainage on Progress Payments 7.2.1 Owner will retain Ten percent ( 10 %) of each Application for Payment provided, however, that when fifty percent (50%) of the Work has been satisfactorily completed by Design- Builder and Design-Builder is otherwise in compliance with its contractual obligations,Owner will not retain any additional retention amounts from Design-Builder's subsequent Applications for Payment. Owner will also reasonably consider reducing retainage for Subcontractors completing their work early in the Project. [Design-Builder and Owner may want to consider substituting the following retainage provision] ❑ Owner will retain N/A percent ( N/A %)from Design-Builder's Applications for Payment, exclusive of General Conditions costs, and any amounts paid to Design-Builder's Design Consultant, from each Application for Payment provided, however, that when fifty percent(50%)of the Work has been satisfactorily completed by Design-Builder and Design-Builder is otherwise in compliance with its contractual obligations, Owner will not retain any additional amounts from Design- Builder's subsequent Applications for Payment. Owner will also reasonably consider reducing retainage for Subcontractors completing their work early in the Project. 7.2.2 Within fifteen(15)days after Substantial Completion of the entire Work or, if applicable, any portion of the Work, pursuant to Section 6.6 of the General Conditions of Contract, Owner shall release to Design-Builder all retained amounts relating,as applicable,to the entire Work or completed DBIA Document No.525 Standard Form of Agreement Page 7 Between Owner and Design-Builder- Lump Sum ©2009 Design-Build Institute of America portion of the Work, less an amount equal to(a)the reasonable value of all remaining or incomplete items of Work as noted in the Certificate of Substantial Completion and(b)all other amounts Owner is entitled to withhold pursuant to Section 6.3 of the General Conditions of Contract. 7.3 Final Payment. Design-Builder shall submit its Final Application for Payment to Owner in accordance with Section 6.7 of the General Conditions of Contract. Owner shall make payment on Design-Builder's properly submitted and accurate Final Application for Payment within thirty(30)days after Owner's receipt of the Final Application for Payment, provided that Design-Builder has satisfied the requirements for final payment set forth in Section 6.7.2 of the General Conditions of Contract and(b)Owner shall have the right to withhold all amounts to which Owner is entitled to withhold pursuant to Section 6.3 of the General Conditions of Contract. 7.4 Interest. Payments due and unpaid by Owner to Design-Builder,whether progress payments or final payment, shall bear interest commencing five(5) days after payment is due at the rate of Two percent ( 2 %) per month until paid. 7.5 Record Keeping and Finance Controls. With respect to changes in the Work performed on a cost basis by Design-Builder pursuant to the Contract Documents, Design-Builder shall keep full and detailed accounts and exercise such controls as may be necessary for proper financial management,using accounting and control systems in accordance with generally accepted accounting principles and as may be provided in the Contract Documents. During the performance of the Work and for a period of three(3)years after Final Payment, Owner and Owner's accountants shall be afforded access to,and the right to audit from time to time, upon reasonable notice, Design-Builder's records, books,correspondence,receipts, subcontracts,purchase orders, vouchers, memoranda and other data relating to changes in the Work performed on a cost basis in accordance with the Contract Documents, all of which Design-Builder shall preserve for a period of three(3) years after Final Payment. Such inspection shall take place at Design-Builder's offices during normal business hours unless another location and time is agreed to by the parties. Any multipliers or markups agreed to by the Owner and Design-Builder as part of this Agreement are only subject to audit to confirm that such multiplier or markup has been charged in accordance with this Agreement, but the composition of such multiplier or markup is not subject to audit. Article 8 Termination for Convenience 8.1 Upon ten (10) days' written notice to Design-Builder, Owner may, for its convenience and without cause, elect to terminate this Agreement. In such event, Owner shall pay Design-Builder for the following: .1 All Work executed and for proven loss, cost or expense in connection with the Work; .2 The reasonable costs and expenses attributable to such termination,including demobilization costs and amounts due in settlement of terminated contracts with Subcontractors and Design Consultants; and .3 (Choose one of the following:) ® The fair and reasonable sums for overhead and profit on the sum of items .1 and .2 above. or ❑ Overhead and profit in the amount of percent( %)en the sum of items .1 and .2 above. DBIA Document No.525 Standard Form of Agreement Page B Between Owner and Design-Builder- Lump Sum ©2009 Design-Build Institute of America 8.2 If Owner terminates this Agreement pursuant to Section 8.1 above and proceeds to design and construct the Project through its employees, agents or third parties, Owner's rights to use the Work Product shall be as set forth in Section 4.3 hereof. Such rights may not be transferred or assigned to others without Design-Builder's express written consent and such third parties' agreement to the terms of Article 4. (The following Article 9 should be used only if the Owner and Design-Builder agree to establish their respective representatives at the time the Agreement is executed rather than during the performance of the Project) Article 9 Representative of the Parties 9.1 Owner's Representatives 9.1.1 Owner designates the individual listed below as its Senior Representative("Owner's Senior Representative"), which individual has the authority and responsibility for avoiding and resolving disputes under Section 10.2.3 of the General Conditions of Contract: (Identify individual's name,title, address and telephone numbers) 9.1.2 Owner designates the individual listed below as its Owner's Representative,which individual has the authority and responsibility set forth in Section 3.4 of the General Conditions of Contract: (Identify individual's name, title, address and telephone numbers) Pat Persichino P.O. Box 758 Greeley, CO 80632 (970)356-4000 9.2 Design-Builder's Representatives 9.2.1 Design-Builder designates the individual listed below as its Senior Representative("Design- Builder's Senior Representative"), which individual has the authority and responsibility for avoiding and resolving disputes under Section 10.2.3 of the General Conditions of Contract: (Identify individual's name, title, address and telephone numbers) Thomas J. Roche, President P.O. Box 361 Greeley, CO 80632 (970) 356-3611 9.2.2 Design-Builder designates the individual listed below as its Design-Builder's Representative, which individual has the authority and responsibility set forth in Section 2.1.1 of the General Conditions of Contract: (Identify individual's name, title, address and telephone numbers) Jesse L. Schuchman Roche Constructors, Inc. 1235 W. 124th Avenue Westminster, CO 80234 DBIA Document No.525 Standard Form of Agreement Page 9 Between Owner and Design-Builder- Lump Sum ©2009 Design-Build Institute of America Article 10 Bonds and Insurance 10.1 Insurance. Design-Builder and Owner shall procure the insurance coverages set forth in the Insurance Exhibit attached hereto and in accordance with Article 5 of the General Conditions of Contract. 10.2 Bonds and Other Performance Security. Design-Builder shall provide the following performance bond and labor and material payment bond or other performance security: Performance Bond. (Check one box only. If no box is checked, then no bond is required.) ❑ Required; ® Not Required Payment Bond. (Check one box only. If no box is checked, then no bond is required) ❑ Required; ® Not Required Other Performance Security. (Check one box only. If no box is checked, then no other performance security is required. If the "Required"box is checked, identify below the specific performance security that is being required and all salient commercial terms associated with that security.) ❑ Required; ® Not Required Article 11 Other Provisions 11.1 Other provisions, if any, are as follows: (Insert any additional provisions) Roche Constructors, Inc., Request for Proposal Response dated September 29, 2011 (In lieu of Sections 10.3.1 through 10.3.3 of the General Conditions of Contract, the Parties may want to delete such sections and include the following alternative disputes proceeding clause.] ❑ Any claims, disputes, or controversies between the parties arising out of or related to the Agreement, or the breach thereof,which have not been resolved in accordance with the procedures set forth in Section 10.2 of the General Conditions of Contract shall be resolved in a court of competent jurisdiction in the state in which the Project is located. DBIA Document No.525 Standard Form of Agreement Page 10 Between Owner and Design-Builder- Lump Sum ©2009 Design-Build Institute of America In executing this Agreement, Owner and Design-Builder each individually represents that it has the necessary financial resources to fulfill its obligations under this Agreement, and each has the necessary corporate approvals to execute this Agreement, and perform the services described herein. OWNER: DESIGN-BUILDER: Weld County, Colorado ROCHE CONSTRUCTORS, INC. (Name of Owner) / {/ (Name of Design-Builder) } 1tit �2/q,�l' (i C � �H20-1 g✓nature) / (Signature) Barbara Kirkmeyer Thomas J. Roche (Printed Name) (Printed Name) Chair, Board of Weld County Commissioners President (Title) (Title) Date: DEC 0 52011 Date: November 29, 2011 Caution: You should sign an original DBIA document which has this caution printed in blue. An original assures that changes will not be obscured as may occur when documents are reproduced. DBIA Document No.525 Standard Form of Agreement Page 11 Between Owner and Design-Builder- Lump Sum //-0158 gi ©2009 Design-Build Institute of America Roche Constructors, Inc. September 29, 2011 Ms. Monica Mika Weld County Purchasing 1 150 O Street Greeley, CO 80631 Re: Addition to Alternate Communications Dispatch Center Dear Ms. Mika: Roche Constructors and Hauser Architects are very excited to be a part of your project team for the referenced project. Our recent and extensive local government project experience coupled with the leadership of our proposed project team will ensure a successful project for Weld County. We have selected Hauser Architects as our design partner. Hauser has established a successful history of providing architectural services for municipal, school district, governmental, and private sector clients. Roche and Hauser have a solid relationship and have worked together many times on design-build projects. In the past, Roche and Hauser have teamed together on four design-build projects. Hauser's design experience, coupled with our experience working with local governmental projects, will provide us with the necessary tools to successfully design and construct this project. As a team, we have experience working with Weld County.Two of our four design-build projects were completed for Weld County. This includes the $1.8 million North Business Park Administration Building and the$5.1 million Social/Human Services Building. Our other design-build team experience includes the $1.3 million Ashcroft Retail Building and the $4.7 million North Range Behavioral Health building. Our Project Manager Jesse Schuchman and Superintendent Eric Criswell have a great deal of remodel and addition experience. Our project staff is always available to help you refine the design with Hauser to meet your needs and to assist in value engineering to obtain the most space and amenities for the cost. I personally guarantee the success of this project. Our "open door" policy with owners allows total access to our senior management staff, including me. Call me at any time. I am confident that the project will be a success of which we can all be extremely proud. Sincerely, ROCHE CONSTRUCTORS, INC. HE Thomas J. Roche President and CEO /kjm •ir Vo,35Gao11 ,69oi 3€6.J69 i,i :'dOi',q_Atn Set it iAm;nur Room I''' ,p 172/ 00el21 ( lN.fnlnietlu ADDITION TO ALTERNATE COMMUNICATIONS DISPATCH CENTER Request No . B1100128 September 29 , 2011 ROCHE CONSTRUCTORS , INC . State of Incorporation : CO 361 71st Avenue , Greeley, CO 80634 (970 ) 356- 3611 avirec-roec Thomas J . Roche, President and CEO E: A S R ARCHITECTS , P . C . Aka " Zit loche 1 onstructors , Inc . TABLE OF CONTENTS Section One Firm Information: Contact Office Page 1 Section Two Firm Information: Project Staffing Staffing Chart Page 1 Résumés: Roche Constructors Pages 2-3 Résumés: Hauser Architects Pages 4-5 Résumé: Weeks a Associates Page 6 Résumé: Western States Engineering Page 7 Résumé: R.J . McNutt a Associates Page 8 Résumé: Ridgeline Consultants Pages 9-11 Section Three Firm Information: Banking Information Page 1 Section Four Firm Information: Certificate of Insurance Page 1 Section Five Firm Information: Similar Experience Introduction Pages 1 -2 Team Experience Pages 3-5 Roche Experience Pages 6-9 Hauser Experience Pages 1 0-1 3 Section Six Construction Methods: Self-Performed Work Page 1 Section Seven Fee Proposal Fee Information Page 1 General Conditions Page 2 Bonding Letter Page 3 iiiAusER all Roche ARCHITECTS , P . C . Constructors , Inc . SECTION ONE : Firm Information : Contact Office �l~ FA SER p\ Y � I • ARCHITECTS , P . C . a • Constructors , Inc . . FIRM INFORMATION : CONTACT OFFICE Contact Office The Weld County Addition to the Alternate Communications Dispatch Center will be handled by Roche Constructors' corporate office, which is located at: 361 71st Avenue, Greeley, CO 80634 Phone (970) 356-3611 Fax (970) 356-3619 The primary contact for this project will be Project Manager Jesse Schuchman . He can be reached at the above office number, on his cell at (303 ) 356-4758, or via email at jschuch - man@rocheconstructors. com . Design-Build The design-build process will be lead by Roche and will consist of the following team mem- ITeam bers: Architect Hauser Architects, P. C. Alan Hauser, AIA LEED AP 3780 E. 15th Street, Suite 201 , Loveland, CO 80538 (970) 669-8220 al@hauserarchitectspc.com Structural Weeks Et Associates, Inc. Engineer Gary Weeks, P. E. 4700 S. College Avenue, Suite 1 , Fort Collins, CO 80526 (970) 225-2422 gary.weeks@weeksinc.com Mechanical Western States Engineering, Inc. Engineer John Helin, P. E. 425 N . Wyndham Avenue, Greeley, CO 80634 (970) 346-9929 wsei@comcast. net Electrical R. J . McNutt & Associates, Inc. Engineer Ron Boone, Principal 1140 38th Avenue, Greeley, CO 80634 (970) 330-3266 rb@rjmcnutt.com Civil Engineer Ridgeline Consultants, Inc. Troy Campbell, P. E. 16911 Potts Place, Mead , CO 80542 (970) 535-0419 twc@ridgelineconsultants. com it. al AU SER 1111 Roche Page 1 ARCHITECTS , P . C . Constructors , Inc . SECTION TWO : Firm Information : Project Staffing AAUSER ARCHITECTS , P . C . 9 di Rothe Constructors , Inc . FIRM INFORMATION : PROJECT STAFFING 186 I - 20 11 -. 1. I � f21 N T Y Atei • Constructors , Inc . Thomas J. Roche President Et CEO AU- ER ARCHITECTS , P . C . Steven Fisbeck, Carlin Nafziger, Gary Culver, LEED AP Alan Hauser, LEED AP LEED AP VP of Operations/ AIA, LEED AP VP of Estimating/ VP/General Mountain Region Principal Chief Estimator Superintendent Eric Criswell Jesse Schuchman, Bryan DeForge Estimating Staff Project Superintendent LEED AP Architectural Designer/ Project Manager Project Manager Western States R.J. McNutt &t Ridgeline Weeks Et Associates Engineering, Inc. Associates, Inc. Consultants, Inc. Gary Weeks, P. E. John Helin, P.E. Ron Boone Troy Campbell, P.E. Structural Engineer Mechanical Engineer Electrical Engineer Civil Engineer Roche pose , ARCHITECTS , P . C . Constructors , Inc . JESSE SCHUCHMAN PROJECT MANAGER, LEED AP Roles it Responsibilities • Responsible for the overall success of the project • Point of contact for the Owner and design team during 8 Years of Experience preconstruction and construction with Roche • Coordinates bid packages, subcontractor qualifications, Cr and defines scopes of work • Establishes the project schedule and procedures for expediting shop drawings and materials • Controls the cost of materials, labor, and subcontrac- tors and submits documented progress payments • Schedules and conducts routine jobsite meetings with representatives of the Owner, design team , and major subcontractors • Monitors job progress information and determines its effects on overall proj - ect completion Education B. S . Construction Management, Colorado State University, Fort Collins, CO Certifications • LEED Accredited Professional • Certified in the OSHA 10-Hour Course for Occupational Construction Safety and Health Representative Public Works & Detention Project Experience • $63 . 3 MM, Aurora Processing Center Annex, Aurora, CO • $18 . 5 MM, State Veterans Nursing Home at Fitzsimons, Aurora, CO • $6 . 3 MM, Weld County North Jail Complex Phase II , Greeley, CO • $0. 87 MM, Aurora Processing Center Outdoor Recreation Yard , Aurora, CO Federal Government • $1 .7 MM, Denver Federal Center Bldg. 56 Second Floor Renov. , Denver, CO Education • $1 . 3 MM, Jefferson County Schools (CO) Window Replacement Retail • $89 MM, Orchard Town Center, Westminster, CO • $8 . 2 MM, SuperTarget Store No. T-1471 , Aurora, CO • $6 . 2 MM, Safeway Store No. 1873 & Fueling Center, Thornton, CO • $0. 82 MM, Target Store No. T-0256 Rightsize Remodel, Aurora, CO • $0.71 MM, Target Store No. T-2031 Rightsize Remodel, Albuquerque, NM • $0. 69 MM, Target Store No. T-0356 Rightsize Remodel, Albuquerque, NM References • Mr. Silas Campbell, General Services Administration Denver, Colorado, (303 ) 656-6846 • Mr. Paul Von Stein , Safeway, Inc. Centennial, Colorado, (303 ) 843-7600 Paget Constructers , Inn . ERIC CRISWELL PROJECT SUPERINTENDENT Roles Et Responsibilities • Assists in the constructability review, development of preliminary schedules, and site logistics planning 6 Years of Experience • Directs Roche's field forces, supervises subcontractors, with Roche and coordinates construction activities with represen- i tatives of the Owner and Architect • Implements schedules, expedites materials, and se- lects construction methods and techniques • Enforces the project schedule and quality standards Education B. S. Construction Management Colorado State University, Fort Collins, CO Certifications • Certified in the OSHA 30-Hour Course for Occupational Construction Safety and Health • Competent Person Professional Scaffolder's Training • Walmart Stormwater Professional • CPR and First Aid Certification Representative Federal Government Project Experience • $ 1 .7 MM, Denver Federal Center Bldg. 56 Second Floor Renov. , Denver, CO • $0. 89 MM, Fort Collins Federal Building Energy Upgrades, Fort Collins, CO • $0. 28 MM, Denver Federal Center Building 56 Elevator Hoistway, Denver, CO Public Works • $1 . 8 MM, Greeley Public Safety Facility Renovation, Greeley, CO • $0. 23 MM, Weld County Social / Human Services Building B Tenant Remodel, Greeley, CO Apartment & Housing • $4.7 MM, Poudre Trails Condominiums Sitework Et Segment 1 , Greeley, CO Retail & Related Sitework • $9 MM, Safeway Pharmacy Remodels, Various Locations in CO, NE, a SD • $0.78 MM, Whole Foods Rocky Mountain Bakehouse Expansion, Aurora, CO References Mr. Tim Kyer, General Services Administration Denver, Colorado, (303 ) 236-8000 ext. 2551 Mr. John Freeman , Freeman Architects Loveland , Colorado, (970) 667-3939 Mr. David Simmons, Plant Engineering Consultants Colorado Springs, Colorado, (719 ) 473-7077 R oche Page3 Cnn4tr11etnrs , Inr _ » Alan L. Hauser, AIA, LEED API Principal Education BS Architectural Studies, University of Illinois, 1974 Master of Architecture, University of Illinois, 1976 Registration Registered Architect in CO ( B- 1469), WY, NM, & NE NCARB Certificate Holder (25,952 ) American Institute of Architects LEED Accredited Professional Experience Alan Hauser is the founding principal of Hauser Architects, P. C. . He has been a Loveland resident since 1976 and prior to the formation of Hauser Architects, P. C. he was the owner of Architecture One, P.C. from 1984 through 2003 . Some of the more notable projects that Alan has been involved with include : > Banner Health Medical Clinics (Johnstown, Loveland, Eaton, Berthoud ) > Sunrise Community Health Center ( Evans) > North Range Behavioral Health (Greeley) > Loveland Urgent Care Clinic ( PVHS Loveland ) > Weld County Human/Social Services Building > Sunrise Dental Clinics( Loveland & Greeley) > Sunrise/McKee Community Health Center (Loveland ) > Rangeview II and Medical Center of the Rockies/Medical Office Building Tenant Improvements for Medical Space > Thompson R2-J Winona Elem . School & Monroe Early Childhood Center > Hospice of Larimer County > Loveland Boys & Girls Club As a principal of Hauser Architects, P.C. , Alan is fluent in the processes of design, construction documents and construction contract administration . His work includes design team leadership in new construction, additions and extensive remodeling projects. These projects have included work in the public and private sectors as well as various governmental agencies. Alan received the Larimer County Building Department's 2007 Recognition Award for Outstanding Professionalism through the Construction Process. Alan Hauser has completed the CSU Institute for the Green Building Certificate Program and is has been awarded LEED AP designation by the US Green Building Certification Institute. He has the critical knowledge needed to respond the emerging trends in commercial green building design and construction . In addition to his professional practice, Alan is actively involved with several civic organizations in Loveland . He has served on the City of Loveland Parks and Recreation Commission, is a member of the Loveland Sertoma Club, past president of the Loveland Chamber of Commerce, Board of Directors for Center for Adult Learning, and Vice President of the Loveland High Plains Arts Council . v. HAUSER Page 4 411: ap, - tar? 1 air Pa- • it ,yam » Bryan DeForge I Architectural Designer/Project Manager Education Associates Degree in Architectural Design ( 1996) Denver Institute of Technology Experience Following the completion of his degree, Bryan worked for Schmidt Engineering as a cad operator. In 2001 he started his architectural career as a designer for Architecture One . He transferred to Hauser Architects, PC when the company was formed in 2003 . Projects which Bryan has helped design and lead include : > North Range Behavioral Health Center > Colorado Sleep Center of the Rockies > Abound Solar > Sunrise Dental Clinic > Sunrise Monfort Family Clinic > Hospice of Larimer County > Westlake Family Practice > Loveland Rural Fire Protection Fire Station # 8 > Frederick Fire Station # 3 > Banner Eaton Medical Clinic > Arnold Machinery > Loveland Subaru > McWhinney Tenant Improvements for Rangeview Buildings Bryan 's responsibilities at Hauser Architects, PC include working with staff and consultants in completion of detailed construction documents and owner representation through the construction contract administration phase . mir IHAUSER Page 5 GARY G. WEEKS, P.E. WEEKS & ASSOCIATES, INC. EDUCATION PROFESSIONAL EXPERIENCE Bachelor of Science, Civil Engineering, 1979, Mr. Weeks is a structural engineer and President of Weeks &Associates, Colorado state University Inc. He is responsible for the operations of Weeks&Associates, Inc. Mr. Weeks has considerable experience in structural design, including design of residential, commercial and industrial buildings and structures. Mr. REGISTRATIONS Weeks has conducted numerous site inspections during the construction Professional Engineer Colorado, Wyoming, phase of masonry, steel, wood and concrete structures. In addition, Mr. Weeks is involved in the evaluation of existing structures to determine their structural soundness. He has given expert testimony in cases involving structural problems. AFFILIATIONS Mr. Weeks has performed geotechnical investigations in Colorado, Wyoming Member,ASCE and Nebraska. In conjunction with these investigations, Mr. Weeks has Member,AISC developed geotechnical reports and is knowledgeable in testing procedures for the analysis of soils and construction materials. Assoc.Member, IISA Prior to starting his engineering career, Mr. Weeks was employed in the construction industry where he was involved in commercial, industrial and residential construction. WORK HISTORY Mr. Weeks has attended engineering seminars with topics including Weeks&Associates,Inc. expansive soils, structural steel, light gage steel construction, concrete slabs Engineer/President, 1999 on grade, precast concrete, masonry and wind loads for buildings. Yerracon Engineer/Manager, 1992-1999 Empire Laboratories, Inc., Structural Engineer,Division Manager-Structural Department, 1988-1992;Engineer, 1980- PROJECT EXPERIENCE 1988 • Custom home design Structural design of numerous custom homes • Multi-Family housing Structural design of multi-family/apartment complexes Commercial Buildings (Colorado,Arizona, Nebraska, &Wyoming) Structural design of office, medical, industrial/commercial, and retail centers of timber, masonry, concrete, and steel construction • Governmental & Institutional Structural design of buildings for Colorado State University, City of Fort Collins, City of Loveland, Loveland School District, Poudre School District, Poudre Valley Fire Authority, Weld County, and the Catholic Archdiocese of Denver Page 6 WESTERN STATES ENGINEERING.INC. tftix-- Consulting mechanical engineers 425 N.Wyndham•t Avenue•930tl w CO 00634 omces p�9]0J4a9929 •t 9]0.3469930•ws.gscamustmr i JOHN A. HELIN, P.E. PH:970.346.9929 FX:970.346.9930 EMAIL:WSEI@COMCAST.NET MECHANICAL ENGINEER Expertise Comfort air conditioning and plumbing engineering for commercial, institutional, military and residential structures. Education Bachelor of Arts, Philosophy UC Santa Barbara 1971 Licensure Mechanical Engineer in Colorado, Wyoming, California, Utah(inactive), Oregon(inactive) and Nevada(inactive) Experience Summary Mr. Helin has been in the Mechanical Engineering business for over thirty years and has practiced in six states. He has owned his own firm for twenty-three of the last twenty-five years. A partial list of representative projects during the last several years would include: Weld County Alternative Programs Building, Greeley, CO; Weld County Community Corrections Building, Greeley, CO; CO; Weld County Social Services Building#3, Greeley, CO; North Range Behavioral Health Office Building, Greeley, CO and Sykes Weld County Commissioners Building Remodel, Greeley, CO. Professional Experience: Western States Engineering, Inc., Greeley,CO June 1994-Present President AE Associates, Greeley, CO Sept 1992-June 1994 Mechanical Engineer Coast Village Engineering Corp., Santa Barbara, CA March 1984-August 1992 President Memberships/Continuing Education Member American Society of Heating, Refrigeration and Air Conditioning Engineers, American Consulting Engineers Council Page 7 1140 38th Avenue 970-330-3266 R Nft I) Greeley,CO 80634—2570 303-654-1441 v — Suite 502 1912 Capital Avenue Cheyenne,WY 82001 307-635-1112 e-mail: rb@rjmcnutt.com Ronald Boone, Principal QUALIFICATIONS Education: Anoka-Hennipen District 11 Technical Center: Electrical Design Military Service: Minnesota Army National Guard 1970-1976 Duty: 1970-1974: 47th Infantry Division, Four Deuce Commander; 1974— 1976: 747'h Maintenance Battalion, Engine Generator Repairman Honorable Discharge January 1976: Grade Spec 5 Experienced in industrial, institutional, commercial, educational and water treatment facilities. These areas include lighting (interior and exterior), fire alarm and control systems. Additional experience includes, project management, purchasing and electrical construction product sales. Design team member of the following award winning projects: 2009 Design Award for K-12 Schools (Bear Creek High School Phase I) 2007 Top Design of an Educational Facility (Bear Creek K-8 School) 2007 Top Colorado Projects Award Winner (Greeley New Police Station) 2006 1"Place: ASID Commercial single space special function and 2005 ASLA Design Merit Award (Northern Colorado Water Conservancy District Headquarters) 2010 LEED Gold Award for Poudre Fire Authority Fire Station No. 4, Fort Collins, CO. Relevant Experience History Performm AArts Projects Island Grove New Community Building UNC Gray Hall Theatre Mountain View Academy Stage UNC Foundation Hall Dillon Amphitheater Strings in the Mountains—Steamboat Springs, CO Educational Phillips Wyman Hall Renovation—Sterling, CO Berthoud High School Renovation—Berthoud, CO Ponderosa Elementary School—Loveland, CO Ferguson New Alternative High School—Loveland, CO New Bear Creek High School—Lakewood, CO Coronado Hills Middle School Adams County, CO New Weld RE-4 Middle School —Windsor, CO Berthoud High School Remodel—Berthoud, CO Niwot High School—Niwot, CO Niwot Elementary School—Niwot, CO Municipal North Range Behavioral Health, CO Greeley Police Firing Range, CO Bella Rosa Golf Course Loveland Police and Courts Facility Loveland, CO New Greeley Police and Public Safety Buildings—Greeley, CO Weld County Alternatives Building, CO Golden Fire Station #1 —Golden, CO Weld County Detention Center, CO Park County 911 Communications Center North Range Behavioral Health, CO Peetz Community Center-CO Hudson Community Center-CO Health Care Colorado Plains Medical Center—Ft. Morgan, CO Skyline Medical Center—Loveland, CO Various Project Upgrades at NCMC—Greeley, CO McGee Medical Center Upgrades, Loveland, CO Various Kaiser Permanente Upgrade Projects-CO Page 8 Troy W. Campbell, PETrririrriT nit1 President/Project Manager It 1 ,I uLt ± Ridgeline Consultants, Inc. Consultants, Inc. EDUCATION: • BSCE, Gonzaga University • MBA, Colorado State University REGISTRATION: Professional Engineer, Colorado (#41159) EXPERIENCE: Troy has more than 15 years of civil engineering experience focusing on project management and design of site civil engineering improvements including utilities, grading, drainage, erosion control, and roadways. Troy's previous experience includes entitlement processing, preparation and coordination of residential, commercial and industrial site development plans, drainage reports, stormwater management plans, municipal roadway improvement plans and construction observation and administration. PROFESSIONAL MEMBERSHIPS: • American Society of Civil Engineers • Member of the Board of Directors for the Mead Chamber of Commerce • Member of the Town of Mead Parks and Recreation Committee • Member of the CAD, AEC and ALD Programs Advisory Board for Front Range Community College TRAILS AND MUNICIPAL PROJECTS Preliminary & Final Design for 3rd Street between Welker and WCR 34i ' - ya tt 1/i Mead, CO: Provided roadway r, { :) = ►i`.` ., _ -'0a ,1/4 design services for the Town of •'__ ;_ ._�_ . .` . =^' ��, `+ • • 1/2 Mead for approximately mile of ti• f• - i .� "'" • 3rd Street in the Town of Mead. • - _ � = Third Street is an important and 5 _1 strategic corridor for the Town andjris i - • s . ' !- ' " ' design services include roadway r _ (...*:Hut.._ design, utility coordination and drainage design. Greeley Family Funplex/Twin River Community Center, Greeley, CO: Provided design and resident engineer services for this 40-acre site in Greeley. The project included construction of a recreation center, ball fields, open areas, detention facility and site improvements including sidewalks and parking areas. Longmont Municipal Fire Training Facility, Longmont, CO: Project Engineer for this 135-acre fire training site at 1st Avenue and Martin Street. Design services included roadway plan and profiles, site grading and drainage, erosion control, stormwater quality, water and sanitary sewer design and layout. Page 9 Fox Run Pedestrian _ ` t " '' • Facility, Greeley, CO: r , ` ' �, ' Prepared grading plan and plan and profile . _ - construction drawings for approximately 1,500 linear =�-'- ' �...-� ,� �. :,.: r . t yi feet of 8' concrete trail and ' ' ' '" 1_ 'r '"� - 3 a f .I f - -1.r� J ; •-� . ' I . 1. t t. 4' pedestrian facility. Trail f i, _ , . . t+ elevation change of more _ ' cu, - than 30 feet and facilities were designed to be ADA compliant. In addition to the pedestrian facilities, the design included drainage facilities and improvements. Ace Hardware Bike Path, Grand Junction, CO: Prepared cross-sections and plan and profile construction drawings for approximately 500 linear feet of 10' concrete bike path adjacent to Highway 340 and Ace Hardware. Bike path connected to existing facilities and was designed to be ADA compliant. CHURCHES, COMMERCIAL, RETAIL & INDUSTRIAL Dayspring Christian Church, Windsor, CO: Project Manager/Engineer for this 2.5-acre church site in the Highland Meadows Subdivision. Project design services include site grading and drainage, erosion control, stormwater management plan, water and sanitary sewer design and layout. Coordinated with numerous subconsultants and review agencies. Faith Bible Baptist Church, Greeley, CO: Prepared Rezone, Minor Subdivision and Construction Drawings for this 3.5-acre site in Greeley. Project design services include site grading and drainage, erosion control, stormwater management plan, water and sanitary sewer design and layout. US Engineering Site, Frederick, CO: Prepared Preliminary and Final Construction Drawings for this 20-acre industrial site with the Eagle Business Park in Frederick. Design services included site grading and drainage, erosion control, stormwater management, water and sanitary sewer design and layout. St. Louis Catholic Church, Louisville, CO: Provided Opinion of Probable Construction Cost for this roughly 55-acre site located at 96th and Dillon Road. Infrastructure cost items included grading, streets, trails/ paths, storm drainage, water system and sanitary sewer. Flatiron Crossing Mall Reconstruction, Broomfield, CO Coordinated design and prepared grading plans for the reconstruction of portions of the Mall and the Village areas. Design requirements included ties to existing features and buildings as well as ensuring design of walks and accesses were compliant with ADA regulations. .._sr Peloton Cycles, Lot 5 Preston Center Third Filing, Fort Collins, CO: Prepared final civil engineering construction documents for this marquee project on a roughly 1.5-acre site within the Preston Center. Design included utilities, grading and drainage as well as close coordination with adjacent developments and consultants. Page 10 Kaufman & Robinson, Inc. (Evergreen Park Fourth Filing), Fort Collins, CO: Prepared Preliminary Development Plan (PDP) documents for this 1.76-acre site in an industrial park in north Fort Collins. The project consists of a single building, parking, landscaping and access areas. Project design includes utilities, grading, on-site detention and coordination with adjacent property owner for release of stormwater. Sherwin Williams, Loveland, CO: Prepared final civil engineering construction documents for the Sherwin Williams _ajlelirrnillkr relocation in Loveland. The site is approximately 0.7 acres and 'se seas • 4 required approval from the City of Loveland as well as the SHERWIN s _- --� PaiN VV1LLIAMS Colorado Department of Transportation (CDOT). Design ; included site layout, utilities, grading and drainage. Zwisler Car Wash (Fairlane Car Wash), Loveland, CO: Prepared final civil engineering construction documents for this car wash project. Design included utilities, grading, drainage and horizontal control. SUBDIVISIONS Hinkle Farm, Frederick, CO: Mr. Campbell provided project management and civil engineering services for this 120-acre site in Frederick. Services included preparation and coordination of rezone, preliminary and final plat as well as final civil engineering construction documents for this single family development. Lind Property, Phase I, Fort Collins, CO: Mr. Campbell was the project manager and also assisted in the preparation of preliminary and final civil engineering construction documents for this 40-acre residential development in north Fort Collins. Design included pedestrian underpass, as well as coordination with several local entities, adjacent landowners and numerous consultants. Diamond Valley, Diamond Valley Drive, Windsor, CO: Prepared roadway plan and profiles for the roads within the Diamond Valley development in east Windsor. Design included accommodating significant drainage as well as numerous site accesses on to the roadway. Windsor Tech Business Center II, First Filing, Technology Circle & Garden Drive, Windsor, CO: Mr. Campbell completed water and sanitary sewer system design for this industrial development in east Windsor. Site design services also included roadway and grading design as well as close coordination with adjacent property owners. Lorson Ranch, El Paso County, CO: Provided preliminary design for the master planning and roadway design of a 2,000 acre development located between Colorado Springs and Fountain, Colorado. The design and planning involved the determination of appropriate infrastructure improvements throughout the thirty+ year phased construction for the Lorson Ranch Special District. Clover Meadow Condos (now called Poudre Trails), Greeley, CO: Site civil engineer for the on-site design of this 30-acre parcel in northern Greeley. Design included providing ADA access to each entry into the multifamily buildings. The site was adjacent to the Greeley No. 3 Irrigation Ditch and a Regional Detention Pond. Page 11 SECTION THREE : Firm Information : Banking Information USER ARCHITECTS , P . C . iir ") Rr Cal elle Constructors , Inc . .w� FIRM INFORMATION : BANKING INFORMATION Bank Reference Bank of Choice Sarah Burchett 3780 W. 10th Street Greeley, CO 80634 (970) 392-5823 Credit Available $5 ,000, 000 mar IAUSER all Roche Page 1 ARCHITECTS , P . C . Constructors , Inc . SECTION FOUR: Firm Information : Certificate of Insurance I-{ A !ISER ARCHITECTS , P . C . " I \ ) , ft a r ‘4 t R• 1 ! ..Jche �� ' , Constructors , Inc . , DATE---**--1 ® CERTIFICATE OF LIABILITY INSURANCE 09/27/2011 ACORO 09/27/2011 `..-- THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER 1-303-534-4567 CONTACT NAME: IMA of Colorado, Inc. PHONE FAX IA/C N0,Eat): WC,Not: EMAIL 1550 17th Street ADDRESS: Suite 600 PRODUCER Denver, CO 80202 _4V£TOkERID N: INSURER(S)AFFORDING COVERAGE 1 NAIL N INSURED INSURER A: ZURICH AMER INS CO 16535 Roche Constructors, Inc. INSURER B: AMERICAN GUAR & LIAB INS , 26247 PO Box 1727 INSURER C: PINNACOL ASSUR 41190 INSURER D: Greeley, CO 80632 INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER: 23228224 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. I R AOOL SUBR POLICY EFF POLIOY EXP I LT LIMNS LTR' TYPE OF INSURANCE INBR WVQ POLICY NUMBER (MMIDDIYYYY) (MMIDDM'YY) A GENERAL LIABILITY JGL0534215106 12/01/10 12/01/11 EACH OCCURRENCE $ 1,000,000 DAMAGE TO RENTED X COMMERCIAL GENERAL LIABILITY 1, PREMISES(Ea occurrence) $ 300,000 —I CLAIMS-MADE X I OCCUR MED EXP(Any one person) $ 10,000 X BI & PD Ded:$25,000 • PERSONAL 8,ADV INJURY ', $ 1,000,000 L GENERAL AGGREGATE $ 2,000,000 I GEN'L AGGREGATE LIMIT APPLIES PER: PRODUCTS-COMP/OPAGG $ 2,000,000 I POLICY X 78-F _X LOC _.- $ A AUTOMOBILE LIABILITY BAP375771208 12/01/10 12/01/11', COMBINED SINGLE LIMIT $ 1,000,000 --I ' (Ea accident) X ANY AUTO I BODILY INJURY(Per person) $ ALL OWNED AUTOS BODILY INJURY(Per accident), $ _ SCHEDULED AUTOS i, PROPERTY DAMAGE $ HIRED AUTOS I X (Per accident) 'IX NON-OWNED AUTOS $ _.. . B X I UMBRELLA LIAB X IOCCUR AUC655848701 12/01/10 12/O1/llii EACH OCCURRENCE $ 1,000,000 EXCESS LIAB CLAIMS-MADE AGGREGATE $ 1,000,000 _] DEDUCTIBLE $I X I RETENTION s 0 S C WORKERS COMPENSATION 14063714 - CO ONLY 12/01/10 12/01/11 XI TORVLAMITS :W- AND EMPLOYERS'LIABILITY A I ANY PROPRIETOR/PARTNERIE%ECUTIVE YI N I I IWC463300300* 12/01/10 12/01/111 E EACH ACCIDENT $ 1,000,000 OFFICER/MEMBER EXCLUDED? N NIA• .L.'- - - (MandatoryinNH) E.L.DISEASE-EA EMPLOYEE $ 1,000,000 If yes.descnbe under 1,000,000 DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $ i*WC - All Other States incl '**AZ,NE,CA,IA,NM,NV,DC,TX,MD & I DESCRIPTION OF OPERATIONS/LOCATIONS I VEHICLES (Attach ACORD 101,Additional Remarks Schedule,If more space is required) CERTIFICATE HOLDER CANCELLATION RE: Addition to Alternate Communications Dispatch Center, Weld County Finance Department. SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE Monica Mika THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN Weld County Purchasing ACCORDANCE WITH THE POLICY PROVISIONS. 1150 0 Street AUTHORIZED REPRESENTATIVE �T Greeley, CO 80631 / //,�jf USA �A/�/� mwescue ©1988-2009 ACORD CORPORATION. All rights reserved. ACORD 25(2009/09) The ACORD name and logo are registered marks of ACORD 23228224 SECTION FIVE : Firm Information : Similar Experience HAUSER "s. „; - ARCHITECTS , P . C . � `1 di 11 4,chiti %: Constructors , Inc . FIRM INFORMATION : SIMILAR EXPERIENCE Team Experience Roche Constructors and Hauser Architects have worked together on three design-build proj - ects, two of which were completed for Weld County. Project sheets have been enclosed on the following pages for these projects: • $5 . 1 MM, Weld County Social/ Human Services Building, Greeley, CO • $1 . 8 MM, Weld County North Business Park Administration Building, Greeley, CO • $4.7 MM, North Range Behavioral Health , Greeley, CO Roche In the past ten years, Roche has constructed design-build projects totaling $240 million . Experience These projects have ranged from small remodels and additions to large detention projects. Project sheets have been enclosed for the following relevant projects: • $1 .7 MM, GSA Building 41 FAS Build-Out, Denver, CO • $0.74 MM, North Range Behavioral Health Addition Et Renovation , Fort Lupton , CO • $4. 6 MM, North Star Academy East Campus Expansion Et Renovation , Parker, CO • $0.65 MM, University Schools Addition , Greeley, CO Roche Weld County Social / Human Services Building Et North Business Park Administration Building References Pat Persichino, Weld County, CO 1111 H Street, Greeley, CO 80631 (970) 356-4000 ext. 3768, ppersichino@co.weld . co. us North Range Behavioral Health John Rattle, North Range Behavioral Health 1300 N . 17th Avenue, Greeley, CO 80631 (970) 347-2371 , john . rattle@northrange. org North Range Behavioral Health Addition Et Renovation Wayne Maxwell, North Range Behavioral Health 1300 N . 17th Avenue, Greeley, CO 80631 (970) 347-2371 , wayne. maxwell@northrange.org North Star Academy East Campus Expansion a Renovation Cynthia Haws, Principal, North Star Academy 16700 Keystone Boulevard , Parker, CO 80134 (720) 851 -7827, chaws@nstaracademy.org University Schools Addition Dr. Sherry Gerner, Director, University Schools 6525 W. 18th Street , Greeley, CO 80634 (970) 506-7001 ; sgerner@universityschools. org Li AU S 1111 Roche page , ARCHITECTS , P . C . Constructors , Inc . FIRM INFORMATION : SIMILAR EXPERIENCE Hauser Project sheets for the following projects have been enclosed on pages 10-13 of this section : Experience • New Vision Charter School Addition , Loveland , CO • Golden Fire Department Station No. 1 , Golden , CO • Pathways Hospice of Larimer County, Fort Collins, CO • Candlelight Dinner Theater, Johnstown, CO Hauser Pat Persichino, Director, Weld County Public Works References 1111 H Street, Greeley, CO 80631 (970) 304-6496 Cliff Trausch, Banner Health 1801 16th Street, Greeley, CO 80631 (970) 378-3837 Tom Hawkinson , CBO, City of Loveland , Building Division 500 E. Third Street, Loveland , CO 80537 (970) 962-2509 Tim Mangina, Thompson School District R2-J 535 North Douglas Avenue, Loveland , CO 80537 (970) 669-3940 Harry Devereaux, President. Home State Bank 935 N . Cleveland Avenue, Loveland , CO 80538 (970) 669-4040 Joe Gebhardt, Davidson-Gebhardt Chevrolet, Subaru of Loveland 388 Test Circle Drive, Loveland, CO 80538 (970) 667-3950 Ms. Mitzi Moran , CEO, Sunrise Community Health Centers 100 N . 11th Avenue, Greeley, CO 80631 (970) 304-2377 Mr. Don Marostica, Loveland Commercial Real Estate, LLC 1043 Eagle Drive, Loveland , CO 80538 (970) 667-7000 Tom Hall, McWhinney 2725 Rocky Mountain Ave. #200, Loveland , CO 80538 (970) 962-9990 poir , AusER F Roche Paget ARCHITECTS , P . C . Constructors , Inc . 11P-1 f a „ • r . i -- 0 ..- 11 1 rT r ,-, - ... gg �' r -", n : I . - 1 r I I t. ,won,- to r r. :,'+ L F : • I t" _ fat l_ a .� ' - ii .r, li sans - — 16 t WELD COUNTY SOCIAL/ HUMAN SERVICES BUILDING Roche teamed with Hauser Architects to complete this facility home include the Assistance Payments this design-build project for Weld County. Located Department, Temporary Assistance for Needy in the Weld County Social Services Complex, the Families (TANF), Medicaid , Low Income Energy three-story building is constructed on a load- Assistance Program ( LEAP), and Child Support bearing spread footing foundation system with a Services. The scope of work also included overlot steel frame/braced joist building frame system . grading, site infrastructure, parking lot paving, The building exterior is metal stud wall with EIFS / site lighting, and landscaping. masonry veneer. The building is home to adminis- trative offices, extensive lobby areas, and meet- ing/conference rooms. The programs that call Address: 315 North 11th Ave. , Greeley, CO • Owner: Weld County, CO • Architect: Hauser Architects, P. C. • Contract Method: CM/GC, Design-Build • Specs: 40, 827 SF; 1 Acre IIIAUSER Fiat Roche Page ARCEPTECTS , P . C . Constructors , Inc . Prer . . , sit * • tI1 . :1.4 , 4 fob 3r a i r / i h b-14 t% r ' 1 . 4. _ 4 » iiip , _4 . • Et 4. Siam 1 k �w • ge - -. _ -• i -. ._. . J . _-_I I --, ...._ .141 Wie „own' i iri v tr�- .. . _ - �__-diet . ,h w • �� NORTH BUSINESS PARK ADMINISTRATION BUILDING The North Business Park Administration Building elections. The building was designed to match the is constructed with a masonry load-bearing steel adjacent government office buildings. joist building frame system on a spread footing foundation system . The scope of work also included overlot grading, site infrastructure, parking lot paving, site light- The one-story, colored CMU structure houses ing, and landscaping. the county's expanded election department and geographic information systems. The county can now provide more access to residents for voting, and the building also houses a room to observe Address: 1401 North 17th Ave. , Greeley, CO • Owner: Weld County, CO • Architect: Hauser Architects, P. C . • Contract Method: CM/ GC, Design-Build • Specs: 17, 266 SF; 4 Acres AAUSER Fltn Roche Page ARCHITECTS , P . C . Constructors , Inc . S S I a . , 5 .. •S �1 jilli - a . • .N.,:,--: ca -- Incft.` t b&, S' • • I I P .4'•. - 7 :ID • - North Range - Behavioral Health _ "'"-=' ]tea. ' - - 1. .-X11 I '�\ , ' ' �' Hr1-}-mow , -i ‘ � 1 •1 _ -yi�'',�:A�`. W 1•C f` of a. - .t. f. i. `j� NORTH RANGE BEHAVIORAL HEALTH North Range Behavioral Health 's new building is ture, parking lot paving, site lighting, landscaping, located in the Weld County Business Park. The fa- and retaining walls. cility is a two-story structure built on a load-bear- ing spread footing foundation system . The building The interior features an on-site pharmacy, office frame system is masonry load-bearing steel joist space, common areas, and patient evaluation with a glazed curtain wall system . rooms. This facility allowed North Range Behav- ioral Health to consolidate its operations from Roche's scope of work also included sitework, several smaller structures located throughout which involved the decommissioning of an existing Greeley and enabled it to expand its treatment gas well system , overlot grading, site infrastruc- capacity by up to 175 additional clients. Address: 1300 N . 17th Ave. , Greeley, CO • Owner: North Range Behavioral Health • Architect: Hauser Architects, P. C . • Contract Method: CM/GC, Design-Build • Specs: 33 ,786 SF; 4.7 Acres FIAUSER AUSER illt R 0 c h e Page5 ARCHITECTS , P . C . Constructors , Inc . • ISM 11 Ati er her 00 / • V,\ \\%j i BUILDING 41 Roche Constructors , Inc . FAS BUILD OUT This project is a renovation of 24, 500 square feet break rooms that extend onto the new rooftop on two second-floor wings occupied by the Federal terrace and which will have doors that open to Acquisition Services Division (FAS) of the General the outside. Services Administration (GSA). The design pushes the bounds of the second floor exterior walls out Construction of the space involves working in an onto the roof of the first floor, connecting the occupied building and being sensitive to the daily space to the outdoors, enhancing internal layout, functions of the FAS, completing the two wings and creating a connection between the two wings individually to accommodate the various FAS work- with a rooftop terrace for additional work areas groups, abating asbestos and lead materials, and and gathering space. There will be visual inter- working with existing conditions of an 80-year-old est inside the space and provide the GSA with its building that was originally built to manufacture desire to create a workplace of the future with munitions during the Second World War. Construc- collaboration areas, a flexible workstation layout tion started concurrently with the finalization of that can change with the employees and their the design during the design-build process. Roche work requirements, areas for tele-workers to and Gensler have collaborated to develop the come and work in the office as needed , and cafe- design and budget to bring the whole project into style work areas for individuals. An unique feature reality. of the space will be the new conference room and Address: Denver Federal Center, W. 6th Ave. Et Kipling Street, Denver, CO • Owner: General Services Administration • Architect: Gensler • Contract Method: Design-Build • Specs: 24, 500 SF Page 6 -. SIIN Constructors , Inc . � . . la NORTH RANGE BEHAVIORAL i II • IMMO HEALTH RENOVATION & ADDITION a - _ •I ri," The design-build renovation and addition of North Range - Behavioral Health 's (NRBH ) Fort Lupton facility included , T; t m the demolition of a parking garage and one-story build- ing. Roche also removed the surrounding parking lot and r. I landscaping. When the demolition was complete, Roche •-• _ prepped and paved a new parking lot, relocated wet and dry utilities, and added landscaping. The interior of the existing 3,603-square-foot building was demolished and p>. then the building was expanded by 2,645-square-feet. The renovation and addition allowed all three NRBH divi- r; sions to consolidate from two locations to be under the _ • same roof and still have space for growth . � i, TY - s u - s Address: 145 1st Street, Fort Lupton, CO , illiiii Owner: Nathan Adelson Hospice Architect: Alter Lingle Massey Architects, P.C. r Contract Method: CM/GC, Design-Build 4 - Specs: 2, 645 SF Addition a 3,603 SF Renovation e - - . 7 — lig • Page 7 ' ` t - NORTH STAR tI I. 11 Roche 1 ce . Constructors , Inc . i- a ... . - _ _ `' NORTH STAR ACADEMY EAST I = con 4 CAMPUS EXPANSION & RENOVATION fah _11 `J r Li-getio _ ra �T. 8- l . . Renovations to the charter school included remodeling I. - \. the existing teaching spaces with new architectural and ..�i MEP upgrades. The addition included two new classroom wings with nine new classrooms. The addition also in- • s'.......w cluded a platform and serving area to enlarge the lunch- room space. A challenge for this project was that the school was occu- I, pied during the first half of construction . Once school was _ out for the summer, we completed the work for school to ,� start up again in the fall . i w. rat s t ■ IS itt V*: nt + t, w 1t r. IS la • kf. AIL b; :ter ,,"war_ Ingest � ar. • air tt, t Sitework included playing fields and exporting 17,000 1 , Et T. : L . . ,, ,, "1!Y ""d . al. - LLtt ;alALL cubic yards of dirt from the property that the addition .ti I .:: was built on . S _ A , Address: 16700 Keystone Boulevard , Parker, CO f .. Owner: North Star Academy Facility Corporation - Architect: SLATERPAULL Architects Contract Method: CM/ GC, Design-Build Specs: 30, 508 SF Renovation & 13,764 SF Expansion . _ A i . , ,, I . :. - `,. - tj il. +� . . ,, , . . . ,mI. en a i tr-..- aumm . ham. Page 8 �.. - _.,1..-'iippluli: i ___ _ _ , T 4 - 1j r er _ IC P' j �)..t* _f yy. +f+:4 r --I..-.�._ i i 5"- -_e 6 ':. • ►z .c=s.a ansatior ..- Ir.-- _eaR'.. - - .a..'a:— ~ - _ - - 1 UNIVERSITY Constructors , Inc . SCHOOLS ADDITION The University Schools Addition is a one-story, structural, mechanical, and electrical designs. 4, 365-square-foot addition to the existing All trade coordination required for the design 122,000-square-foot school, which was originally stage was done in-house. The design focus was to completed in 2002 . The addition is constructed on meet the program requirements, provide exterior a load-bearing spread footing foundation system elevations that would blend with the existing look with a structural metal stud and masonry load- of the building, and maintain the integrity of the bearing steel joist building frame system . Roche adjacent wetlands. A unique exterior feature of was responsible for complete interior finishes, the addition is the standing seam metal roof that which included classroom space, offices, and a was designed to match the existing roof as well as state-of-the-art computer lab. meet the City's requirement to shield the roof's mechanical equipment. This was a design-build project in which we contracted separately for site, architectural, Address: 6525 West 18th Street, Greeley, CO • Owner: University Schools Building Corp. Architect: Property Construction Services • Contract Method: CM/ GC, Design-Build • Specs: 4, 365 SF Page 9 me f - .; • rt -a I Ial. NEW VISION L- r MI > > New Vision Charter School Boys and Girls Club of Loveland Project Location > 2500 E. 1St Street, Loveland , Colorado Project Description > The New Vision Charter School Addition will be a shared facility with the Loveland Boys and Girls Club . The single story 24,000 SF building contains a gymnasium , kitchen , cafeteria , and four classrooms for New Vision Charter School . In addition it includes educational spaces for meeting rooms, art room , music room , computer room and game rooms for the Loveland Boys and Girls Club . The new addition is connected to the existing classroom building by an enclosed pedestrian walkway. •111r IHAUSER Page 10 - Jr- - ---. _ a tar .?"- tar • al Ain MOW a al is _ ...._ re ea _____ IL 410 MN 111111 a e . ,_ 1 > > Golden Fire Department Station No . 1 Project Location > Golden , Colorado Project Description > The new Golden Fire Station No . One is a two-story 14, 660 SF facility which contains a six- bay apparatus garage, watch office and ancillary functions on the main level . The second level contains administrative offices, a training facility and 4- bedroom quarters area . The station replaced the existing facility which was constructed in 1961 with an addition in 1973 . This was an urban site which was limited by many existing constraints for new development. .itir HAU S E R Page 11 pipouummirrr- ,. . ,,, , — 7 " - -. % \zit .. . i T _ amor , •w� ..eCe .. A • pill a. Hwy., ray' r a....r •' r r ice- 1 i k� _ Ail t , ilk.r_ _ "'� ' - . I ." 'an is _ w+ ISIMMIllar . I' i-a- -Alin- • , r,""en ` ►. t' f - r'•µ r'�4. ,ja" r• L.. •-.. Ca 1.. r.. >> Pathways Hospice of Larimer County Project Location > Fort Collins, Colorado Project Description > The building is a new 13 ,000 SF two story wood-framed structure containing administrative offices, counseling , educational and group meeting spaces. This building will be connected to the existing Hospice building with a two story fully enclosed corridor space. This was a design build project W HAUSER E R Page 12 Parri --- ------- - ip. . Pc - - - 1\ 7 ' \Nt.„ '7, - -‘,1 - ---; ' PA; 1. t' s re - Oil 40.. s - r • L CANDLE ,y Ai. ill.s.— * 1:- a r aw t :I-- -. - - # - lt dilitlit t,.. -- - I [ I 1 , 461; . 1 - , ,;, -- -iscr. . ,. lir_ „ • , ,..• _ ' 4. tz • • •'i�-_ _mow. ;; .. Ilibbft- �- .. --.�.-�-- . 44.1.1-k „.J li--. » Candlelight Dinner Theater Project Location > Johnstown , Colorado Project Description > This facility is a 22 ,000 SF dinner theater with main level and VIP balcony seating for 360 patrons . The building also includes a full commercial kitchen, general offices, stage, orchestra pit, tiered seating and backstage ancillary functions . This project utilized a pre-engineered steel building system liii. HAUSER Page13 SECTION SIX : Construction Methods : Self- Performed Work 72-1AVSER ARCHITECTS , P . C . Et I !ad ch. Constructors , In Co � E . CONSTRUCTION METHODS : SELF - PERFORMED WORK Self-Performed As a general contractor, Roche controls the cost of our work, the schedule by which the work Work is performed , and the quality of the work. We have the resources necessary to self-perform demolition ; excavation , backfill, and compaction ; rough carpentry; hardware and door in- stallation ; and equipment installation . Competitive Bids It is our policy that all areas of the project will be competitively bid, including the work Roche is capable of self-performing. This ensures the most competitive pricing for each scope of work. int Roche Page 1 ARCHITECTS , P . C . Constructors , Inc . SECTION SEVEN : Fee Proposal HAUSER ARCHITECTS , P . C . R @Joh. , Constructors , Inc . . FEE PROPOSAL Item A Architectural Fee $19, 525 Construction Fee $15.000 Total Fee $34, 525 Item B Please see the general conditions enclosed on the following page. Item C There will be no charge ($0) for preconstruction services. Item D Bond Rate/ $1000 Rate First $2, 500, 000 $8 . 30 Next $2, 500, 000 $6 .80 Please see the bonding letter enclosed at the end of this section . "iikusER au Roche Page 1 ARCHITECTS , P . C . Constructors , Inc . O O n g-' 23 P N m ^ N O O O O O n, O e n N N O n N n N ^ ^ N 0 ` P O N N Q N ^ M n M 0 ^ N o E .V N n n N p ty a N N N N N N N N N N N N N N N N N N N N N NC 0 E 0 4 C O P i 3 3 3 E E E E ov on E E E E E v E d O 0 t O o 0 e m 0000 .20000 0) y 0 0 0 0 0 4q o 0 0 0 R 999 0 0 C V O O O O 0 N aO N Xen N N N O O M P O 0 O L: 00 ,.., ^ d U = Y c N a y t Y 2 _ r C d d O Uf 3 0 O C a a. .0 n IO n o m CN 0 M Q ^ in N .- 1 a o - O E O O oN Od v., y N N N N N N U U t _ __. __ __.. __ _._ OJ O O O O O O O N O Va. O O O O O O O O O M N O O 0 p M p p P — C --- C C C C C C C C C N .- N 6 W CO en C „ N N E N N —c 4 O 0 i a O V 1- w 0 0 0 0 0 0 0 0 0 0 0 0 a 0 0 0 0 0 NCCCCCCCCECCC m CCCCC A` O 0 W y • C N n C E 41) 4 N N N U no N N ,C V 0 t0 -- Daewoo o a r o 0 0 0 0 0 a fi — C 0- -- --. --.C C C C L C C C — C C C C C C C 4 _ O C N R. N N P co N U N Q N M en — QOT. CN N N of N N WI 0000 0 /1♦ C * ^ a O O O O V— 0 V O O O O ,,9, „,0 m N O O O O C O O O C O a C C C C C C C C \ C C C 41, O j I M 0 V CDOO o C O O n0 ^ OO O P O N M = 01 EN N < O a N N in N N d O O 0 � ^ 0 0 0 O - 0 O O O O G Q U n N N c c c •c 0 0 0 0 c c c C C Cl N os 333EEEE � mEEEEEE „ Ev -0 -0 • U 0 P ^ ^ L0 M M M O ^ M M < M M M in M ^ Z O C N N 0 O H J C E re € O I- V — y e Z a t C m .^ 0 O a � `o o a c n u CO U o c o " = N ` ra ` C U v u O W O 6) O < o E = Sata ti. r^0- Y 0D• V •^ ` C Tj10 o v o m u o o a = —' E Y u o f " Li o — Cle O D a i E a 0` O yn C i u r i f U'0 m u U LL _U L .a ✓ m ._ N N CO e 0 0 0 ^ 0p.. ...- 0 0 0 0 0 v. .0 0 0 0 Cl COP m O C ^ O 0 O an 0 O N 0 O 0 0 0 0 0 0 0 0 0 N N M N 9 n U U H• Q I AAA 2 CONSIDER IT DONE September 23, 2011 Monica Mika Weld County Purchasing 1150 O Street Greeley, CO 80631 RE: ROCHE CONSTRUCTORS, INC. Design Build -Addition to Alternate Communications Dispatch Center Dear Ms. Mika: IMA of Colorado, Inc. handles the surety bonds for Roche Constructors, Inc. Their bonds are underwritten by Travelers Casualty and Surety Company of America and issued through our office. They have established a strong relationship with Travelers Casualty and Surety Company of America; a subsidiary of The Travelers Companies, Inc. Travelers Casualty and Surety Company of America is rated "A+ XIV" by A.M. Best and is listed as an approved surety by the Treasury Department with a limit of$180,222,000. While the surety has not established a maximum limit for either single bonds or an aggregate program, the surety would favorably consider bid, 100% performance and 100% payment bonds for single contracts of $125 million with an aggregate program of$250 million if requested by Roche Constructors, Inc. Any arrangements for issue of performance and payment bonds is a matter handled between Roche Constructors, Inc. and Travelers Casualty and Surety Company of America and is subject to review of the size, type and location of the project as well as a favorable review of the contract documents, bond forms, project financing and the contractor's current uncompleted work program. Neither the surety nor IMA assumes any liability to you, or third parties, if for any reason bonds are not executed. We are pleased to provide this letter of recommendation on behalf of Roche Constructors, Inc. Roche Constructors, Inc. is a premier General Contractor within Colorado and the Western United States. They maintain a fine relationship with owners, architects, suppliers and subcontractors. If you require additional information, you may contact me or Sue Wood at (303) 534-4567. Sincerely, Sarah Finn National Surety Senior Vice President cc: Roche Constructors, Inc. Travelers Casualty and Surety Company of America P: 303.534.4567 IMA of Colorado. Inc. 1550 17th Street, Suite 600 RISK MANAGEMENT. INSURANCE & F: 303.534.0600 Denver CO 80202-1657 EMPLOYEE BENEFITS SOLUTIONS www.lmaenrp.wm dpn IMA of Colorado lnwmnre Services anuinn,i�>:nix xez n;nuaeu,_ Calf forma I.ic R 0809724 To: Board of County Commissioners 1 8 6 i - 2 0 i i From: Pat Persichino Re: Bid #B1100128 Subject: Alternate communications dispatch center addition Design Build w EI - I0 N T Y Date: October 12`", 2011 Attached is my final tabulation for the Alternate Dispatch Center. I am recommending approval of the lou bid from Roche Constructors. The bid tabulation is based on a $200k and $300K budget. We will receiv a Guaranteed Maximum Price (GMP) after completion of the design phase of the project. Pat Persichino CONTRACTOR BID ITEMS $200K BUDGET $300K BUDGET Roche Constructors Architectural fee $19,525 $19,525 Construction Fee 15,000 15,000 General Conditions 37,140 37,140 Bond 1,660 2,490 Total $73,325 $74,155 Mishler Design Build 3.5% $ 7,000 $ 10,500 Pre Con Costs 34,058 34,058 General Conditions 36,938 36,938 Bond 2,280 3,420 Total $80,276 $84,916 Growling Bear Design Services $28,300 $28,300 Construction Services 8,000 12,000 General Conditions 47,700 47,700 Pre Construction 1,000 1,000 Bond 1,800 2,700 Total $86,800 $91,700 Fransen Pittman Pre Con $ 500 $ 750 Construction 2% 4,000 6,000 General Rqmts. 95,312 95,312 Design Fees 18,400 18,400 Bond 2,736 4,104 �7 Total $120,948 $124,566 107 ow/- iR5 c WELD COUNTY PURCHASING 1150 "O" Street, Greeley CO 80631 I 8 6 I - 2 0 I I E-Mail: mwalterseco.weld.co.us E-mail: reverettAco.weld.co.us Phone: (970) 356-4000, Ext 4222 or 4223 Fax: (970) 336-7226 W E L ' O U N T Y u DATE OF BID: September 29, 2011 REQUEST FOR: ALTERNATE COMMUNICATIONS DISPATCH CENTER ADDITION - DESIGN BID DEPARTMENT: Finance Department BID NO: #81100128 PRESENT DATE: OCTOBER 3R°, 2011 APPROVAL DATE: OCTOBER 17TH, 2011 VENDORS MISHLER BUILD STRONG 8475 W1-25 FRONTAGE ROAD SUITE #100 FREDERICK CO 80504 GROWLING BEAR COMPANY INC 2330 4TH AVENUE GREELEY CO 80631 ROCHE CONSTRUCTORS INC 361 71ST AVENUE GREELEY CO 80634 FRANSEN PITTMAN GENERAL CONTRACTORS 23 INVERNESS WAY EAST SUITE #250 ENGLEWOOD CO 80112 **BIDS ARE BEING REVIEWED AT THIS TIME. BID TABULATION TO FOLLOW. El oo53 Jo/yaw/ 2011-2582 Hello